F5 Waiver F5.1 The failure of either Party to insist upon strict performance of any provision of the Contract, or the failure of either Party to exercise, or any delay in exercising, any right or remedy shall not constitute a waiver of that right or remedy and shall not cause a diminution of the obligations established by the Contract.
F2 Waiver F2.1 The failure of either Party to insist upon strict performance of any provision of the Contract, or the failure of either Party to exercise, or any delay in exercising, any right or remedy shall not constitute a waiver of that right or remedy and shall not cause a diminution of the obligations established by the Contract.
Xx Waiver Neither a failure nor a delay on the part of either the Trustee or the Holders in exercising any right, power or privilege under this Article 11 shall operate as a waiver thereof, nor shall a single or partial exercise thereof preclude any other or further exercise of any right, power or privilege. The rights, remedies and benefits of the Trustee and the Holders herein expressly specified are cumulative and not exclusive of any other rights, remedies or benefits which either may have under this Article 11 at law, in equity, by statute or otherwise.
Limited Waiver of Sovereign Immunity Ex Contractu Contractor acknowledges and agrees that Owner is an agency or instrumentality of the State of Georgia, and as such is entitled to the protection of sovereign immunity. As set forth in Article I, Section II, Paragraph IX of the 1983 Georgia Constitution, sovereign immunity is waived “as to any action ex contractu for the breach of any written contract.” Contractor specifically acknowledges the constitutional and contractual requirements that written changes, modifications, and waivers to this Contract must be specifically executed by the Owner as set forth in the Contract Documents. Accordingly, Contractor specifically acknowledges the constitutional prohibitions against claims against Owner based solely upon oral statement, course of conduct, customs of the trade, quasi-contract, quantum meruit, or O.C.G.A § 13-4-4 (mutual departure from contract terms).
Enforcement of Settlement Agreement 11.1 Any party may file suit before the Superior Court of the County of Los Angeles, consistent with the terms and conditions set forth in paragraphs 11.2 and
When Delay Claim Deemed Waived Any claim to extend the Contract Time and Material Completion and Occupancy Date not made in writing to Owner within the above time periods shall be deemed waived and shall not thereafter be valid. In the case of a continuing delay as a result of a single event, only one claim submission is necessary.
Effective and Ending Dates This is a multi-year subcontract for 36 months, with an effective date of July 1, 2019. It shall end at midnight, local time in Orlando, Florida, on June 30, 2022.
Extension; Waiver At any time prior to the Effective Time any party hereto may, to the extent legally allowed, (i) extend the time for the performance of any of the obligations or other acts of the other parties hereto, (ii) waive any inaccuracies in the representations and warranties made to such party contained herein or in any document delivered pursuant hereto and (iii) waive compliance with any of the agreements or conditions for the benefit of such party contained herein. Any agreement on the part of a party hereto to any such extension or waiver shall be valid only if set forth in an instrument in writing signed on behalf of such party.
COMPLETE AGREEMENT AND WAIVER OF BARGAINING 22.1 This Agreement shall represent the complete Agreement between the Union and the County.
Effective Date of Agreement The provisions of the agreement will come into full force and effect on the date of ratification, unless specified otherwise.
