Design Professional The architect or engineer or architectural or engineering firm selected by Owner (i) for the design and preparation of Contract Documents governing the construction of a Project, or (ii) for construction contract administration under the Contract Documents, or (iii) for both, all such services and the scope thereof to be set forth in the Design Professional Contract. The Design Professional is not an employee of the Owner but is engaged or retained by it for the purpose of performing design and construction administration services for the project. The term “Design Professional” includes architects, engineers, surveyors, designers, and other consultants retained by the Design Professional.
Preparation; Reasonable Investigation In connection with the ------------------------------------- preparation and filing of each registration statement under the Securities Act pursuant to this Agreement, the Company will give the holders of Registrable Securities registered under such registration statement, their underwriters, if any, and their respective counsel and accountants, the opportunity to participate in the preparation of such registration statement, each prospectus included therein or filed with the Commission, and each amendment thereof or supplement thereto, and will give each of them such access to its books and records and such opportunities to discuss the business of the Company with its officers and the independent public accountants who have certified its financial statements as shall be necessary, in the opinion of such holders' and such underwriters' respective counsel, to conduct a reasonable investigation within the meaning of the Securities Act.
Agent Professionals Agent may perform its duties through agents and employees. Agent may consult with and employ Agent Professionals, and shall be entitled to act upon, and shall be fully protected in any action taken in good faith reliance upon, any advice given by an Agent Professional. Agent shall not be responsible for the negligence or misconduct of any agents, employees or Agent Professionals selected by it with reasonable care.
Scope of Professional Services 3.1 On the terms and conditions set forth in this Agreement, COUNTY hereby engages CONTRACTOR to provide all labor, materials and equipment to complete the Project/Service in accordance with the Scope of Services, attached hereto and incorporated herein as Attachment A, as modified or clarified by Addendum(s) # , dated , attached hereto and incorporated herein by reference as Attachment B. It is understood that the Scope of Services may be modified by change order as the Project/Service progresses, but to be effective and binding, any such change order must be in writing, executed by the parties, and in accordance with the COUNTY’s Purchasing Policies and Procedures. A copy of these policies and procedures shall be made available to the CONTRACTOR upon request. 3.2 The term of this Agreement shall be as follows (please check box): The parties acknowledge that this is a project specific agreement and that the single Project/Service shall be completed by the CONTRACTOR within ( ) calendar days after the Notice to Proceed is issued. The CONTRACTOR and COUNTY acknowledge that this Agreement is for a twelve (12) month term and that the CONTRACTOR shall complete the work as specified in the Scope of Services. The COUNTY has the option to renewal this Agreement for four (4) additional one (1) year period(s). The prices set forth in this Agreement shall prevail for the full duration of the initial contract term unless otherwise indicated elsewhere in this document. Prior to completion of each exercised contract term, the COUNTY may consider an adjustment to price based on changes in the following pricing index: CPI. It is the CONTRACTOR’s responsibility to request any pricing adjustment in writing under this provision. The CONTRACTOR’s written request for adjustment should be submitted thirty (30) calendar days prior to expiration of the then current contract term and clearly substantiate the requested increase. The written request for adjustment should not be in excess of the relevant pricing index change. If no adjustment request is received from the CONTRACTOR, the COUNTY will assume that the CONTRACTOR has agreed that the optional term may be exercised without pricing adjustment. Any adjustment request received after the commencement of a new option period shall not be considered. The COUNTY reserves the right to reject any written price adjustments submitted by the CONTRACTOR and/or to not exercise any otherwise available option period based on such price adjustments. Continuation of the contract beyond the initial period, and any option subsequently exercised, is a COUNTY’s prerogative, and not a right of the CONTRACTOR. This prerogative will be exercised only when such continuation is clearly in the best interest of the COUNTY. All work shall be performed in accordance with good commercial practice. The work schedule and completion dates shall be adhered to by the CONTRACTOR except in such cases where the completion date will be delayed due to acts of God, strikes, or other causes beyond the control of the CONTRACTOR. In these cases, the CONTRACTOR shall notify the COUNTY of the delays in advance of the original completion so that a revised delivery schedule can be appropriately considered by the COUNTY. No additional days shall be granted for rain delays. 3.3 The CONTRACTOR shall be solely responsible for obtaining all necessary approvals and permits to complete the Project/Service. 3.4 The CONTRACTOR shall remain appropriately licensed and/or employ the services of a subcontractor who is appropriately licensed throughout the course of the Project/Service. Failure to maintain all required licenses shall entitle the COUNTY, at its option, to terminate this Agreement. 3.5 Although this Agreement identifies specific facilities to be serviced, it is hereby agreed and understood that any County department or agency facility may be added to this Agreement at the option of the County. When required by the pricing structure of the Agreement, the CONTRACTOR shall be invited to submit price quotes for these additional facilities. The additional site(s) shall be added to this Agreement by formal modification. The COUNTY may obtain price quotes for the additional facilities from other vendors in the event that fair and reasonable pricing is not obtained from the CONTRACTOR or for other reasons at the County’s discretion. Although this Agreement identifies specific facilities to be serviced, it is hereby agreed and understood that any County department or agency may delete service for any facility when such service is no longer required, upon fourteen (14) calendar days written notice. 3.6 The CONTRACTOR acknowledges that it has sufficient understanding of the nature and location of the work; the general and local conditions, including but not limited to, those bearing upon transportation, disposal, handling and storage of materials; availability of labor, water, electric power, and roads; and uncertainties of weather or similar physical conditions at the site; the character of equipment and facilities needed preliminary to and during the completion of the Project/Service. The CONTRACTOR further acknowledges that the CONTRACTOR has satisfied itself as to the character, quality and quantity of surface and subsurface materials, obstacles or conditions of the site. Any failure by the CONTRACTOR to acquaint itself with any aspect of the work or with any of the applicable conditions shall not relieve the CONTRACTOR from responsibility for adequately evaluating the difficulty or cost of successfully performing the work required, nor shall it be considered a basis for any claim for additional time or compensation. The COUNTY assumes no responsibility for any conclusions or interpretations made by the CONTRACTOR on the basis of the information made available by the COUNTY. The COUNTY also assumes no responsibility for any understanding or representations made by its officers or agents during or prior to the execution of this contract, unless such understanding or interpretations are made in writing and incorporated herein by reference. 3.7 If required, the Contractors shall attend a mandatory pre-bid meeting. Whether or not there is a mandatory or non-mandatory pre-bid, the contractor shall be required to carefully examine any supplied drawings and/or specifications and be thoroughly aware regarding any and all conditions that may in any manner affect the work to be performed under the contract. If a pre-bid meeting is not required the Contractor shall visit the site to familiarize themselves with the Project/Service, see existing conditions, and take measurements. No additional allowances will be made for lack of knowledge of these conditions. 3.8 In the event of any conflict between the drawings and specifications contained within this Agreement, the following shall govern: A. Addenda shall supersede all other contract documents to the extent specified in the addenda. Subsequent addenda shall supersede prior to addenda only to the extent specified therein. B. Drawings and specifications are intended to agree and be mutually complete. Any item not contained within the drawings, but contained in the specifications, or vice-versa, shall be provided and/or executed as shown in either the drawing or specification at no extra costs to the COUNTY. Should anything not included in either the drawing and/or the specifications be necessary for the proper construction and/or operation of the Project/Service as herein specified, or should any error or disagreement between the specifications and drawings exist or appear to exist, the CONTRACTOR shall not derive unjust benefit thereby, or use such disagreement counter to the best interests of the COUNTY. The CONTRACTOR shall immediately notify the COUNTY’s Project Manager of any discrepancy and await the Project Manager’s direction before proceeding with the work in question. 3.9 CONTRACTOR acknowledges and agrees that CONTRACTOR shall utilize the U.S. Department of Homeland Security’s E-Verify system in accordance with the terms governing use of the system to confirm the employment eligibility of: A. All persons employed by the CONTRACTOR during the term of this Agreement to perform employment duties within Lake County; and B. All persons, including subcontractors, assigned by the CONTRACTOR to perform work pursuant to the contract. 3.10 CONTRACTOR acknowledges and agrees that, in accordance with Section 255.099, Florida Statutes, if the Project/Service assigned to CONTRACTOR is being supported in whole or in part by State funding the CONTRACTOR shall give preference to the employment of state residents in the performance of the work on the Project/Service if state residents have substantially equal qualifications to those of non- residents. If the CONTRACTOR is required to employ state residents, the CONTRACTOR shall contact the Department of Economic Opportunity to post the employment needs in the State’s job bank system. However, in work involving the expenditure of federal aid funds, this section may not be enforced in such a manner as to conflict with or be contrary to federal law prescribing a labor preference to honorably discharged soldiers, sailors, or marines, or prohibiting as unlawful any other preference or discrimination among the citizens of the United States.
Professional Dues The school district will pay the annual dues for the Superintendent’s membership in the American Association of School Administrators, Association for Supervision and Curriculum Development, and Nebraska Council of School Administrators. The Superintendent’s membership in other professional organizations will be considered annually and may be approved at the discretion of the school board.
PROFESSIONAL BEHAVIOR Teachers are expected to comply with reasonable rules, regulations, and directions adopted by the Board, or its representatives, which are not inconsistent with the provisions of this Agreement, provided that a teacher may reasonably refuse to carry out an order which threatens physical safety or well being or is professionally demeaning.
Preparation Awarded vendor shall not begin a project for which TIPS Member has not prepared the site, unless awarded vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in a purchase order. Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre-installation requirements. Registered sex offender restrictions: For work to be performed at schools, awarded vendor agrees that no employee of a sub-contractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present. Awarded vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the purchase order at the TIPS Member’s discretion. Awarded vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety measures: Awarded vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Awarded vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage.
Professionals For projects involving installation or construction services, the Grantee agrees that only licensed professionals will be used to perform services under this Grant Agreement where such services are called for and licensed professionals are required for those services under State law.
Reasonable Cooperation By accepting the Restricted Stock, the Employee acknowledges and agrees that, during the course of the Employee’s employment with the Company, the Employee will be involved in, and may have information or knowledge of, business matters that may become the subject of legal action, including threatened litigation, investigations, administrative proceedings, hearings or disputes. As such, upon reasonable notice, both during the Employee’s employment with the Company and thereafter, the Employee agrees to cooperate fully with any investigation into, defense or prosecution of, or other involvement in, claims to which the Employee has personal and relevant knowledge that are or may be made by or against the Company. This agreement to cooperate includes talking to or meeting with such persons at times and in such places as the Company and the Employee reasonably agree to, as well as giving truthful evidence and truthful testimony. The Company shall reimburse the Employee for reasonable out-of-pocket expenses actually incurred in connection with such assistance. The Employee also promises to notify the Company within five (5) days if the Employee is subpoenaed or contacted by a third party seeking information about Company activities.
Outside Professional Activities 27.01 Outside professional activities conducted with professional and academic responsibility can enhance the reputation of the University and the abilities of its academic staff and librarians. This article applies only to outside professional activities that involve the application of special skills and knowledge within the member’s particular professional expertise. While a member has a primary obligation to fulfil their University responsibilities, they have the right to engage in outside professional activities subject to the following conditions: 27.01.01 A member shall notify the Xxxx/University Librarian in writing of the type, time commitment, and location of any such proposed professional activity. If the proposed activity involves the teaching at another educational institution of a course related to the faculty member's professional expertise, the faculty member shall obtain the prior written permission of the Xxxx/University Librarian, and such permission shall not be unreasonably withheld; 27.01.02 Such activities shall not require the commitment of a block of time on a regular basis which might interfere with the faculty member's normal timetable for teaching activities or a librarian's performance of normal professional responsibilities. For faculty, such activities shall not require the member to devote more than an average of one working day per five-day week on an annual basis. For librarian members, such activities shall not require the member to devote more than 20 working days per calendar year. 27.01.03 Such activities shall not hinder the fulfilment of the member's obligations to the University; 27.01.04 The name of the University and University letterhead shall not be used in such activities unless agreed to in advance by the President, although nothing shall prevent a member from stating the nature and place of employment, rank, and title in connection with such professional activities, provided that they shall not purport to represent the University or to speak for it, or to have its approval, unless such approval has been given in advance in writing by the Xxxx/University Librarian; 27.01.05 Use of University facilities, equipment, supplies, services or other personnel shall require prior written authorization from the member's Xxxx/University Librarian or from the appropriate administrative officer. Financial arrangements for such use shall be made in advance. University activities shall have priority in the use of such facilities, equipment, supplies, services and personnel; 27.01.06 A member engaged in outside professional activities shall hold the University harmless against any loss or damage that the University may suffer from such activities; and, 27.01.07 In preparing their Annual Report, each member shall include a statement of their outside professional activities in the previous year. 27.02 If the Xxxx/University Librarian has cause for concern, the Xxxx/University Librarian has the right to review a member's current or proposed outside professional activities and may require the member to provide information concerning the time devoted to current and past outside professional activities. The Xxxx/University Librarian shall inform the member in writing of the results of the review and, if necessary, of any corrective action which might be required of the member.
