Prerequisites to Board Approval and Proceed Order. Prior to acceptance of a Component Change Order by the Board the requirements set forth in Section 2.1.2 must be met.
Prerequisites to Board Approval and Proceed Order Sample Clauses
Related to Prerequisites to Board Approval and Proceed Order
ROAD WORK PHASE APPROVAL Purchaser shall obtain written approval from the Contract Administrator upon completion of each of the following phases of road work: Drainage installation Subgrade compaction Rock compaction SUBSECTION RESTRICTIONS
New Project Approval Consultant and District recognize that Consultant’s Services may include working on various projects for District. Consultant shall obtain the approval of District prior to the commencement of a new project.
FAA APPROVAL This Agreement may be subject to approval of the FAA. If the FAA disapproves this Agreement, it will become null and void, and both Parties will bear their own expenses relative to this Agreement, up to the date of disapproval.
City Approval Wherever any approval or consent of the City, or of any of its departments, officials or employees, is called for under this Agreement, the same shall not be unreasonably withheld or delayed.
Final Approval Order 62. The Parties shall jointly seek entry of a Final Approval Order, the text of which the Parties shall agree upon. The dismissal orders, motions or stipulation to implement this Section shall, among other things, seek or provide for a dismissal with prejudice and waiving any rights of appeal.
Project Approval The County may issue a Job Order Authorization for the Work, to include the firm-fixed-price of the Job Order and the project duration. Contractor agrees that all clauses of this Contract are applicable to any Job Order issued hereunder. The County reserves the right to reject a Contractor’s Quote based on unjustifiable quantities and/or methods, performance periods, inadequate documentation, or other inconsistencies or deficiencies on the Contractor’s part in the sole opinion of the County. The County reserves the right to issue a unilateral Job Order authorization for the Work if a Quote price cannot be mutually agreed upon. This is based upon unjustifiable quantities in the sole opinion of the County. The County also reserves the right to not issue a Job Order Authorization if the County’s requirement is no longer valid or the project is not funded. In these instances, the Contractor has no right of claim to recover Quote expenses. The County may pursue continuing valid requirements by other means where Contract was not reached with the Contractor.
Seller’s Approval Buyer must obtain Seller’s approval, in writing, to any change to the letter described in Section IV(c) regarding the financial institution, type of financing, or allocation of closing costs; and
Final Approval Hearing “Final Approval Hearing” shall mean the hearing at which the Court will consider and finally decide whether to enter the Final Judgment.
Technical Objections to Grievance No grievance will be defeated or denied by any minor technical objection.
Review and Approval Documents specified above must be submitted for review and approval by CITY Purchasing and Contracts prior to the commencement of work by CONTRACTOR. Neither approval by CITY nor failure to disapprove the insurance furnished by CONTRACTOR shall relieve CONTRACTOR of CONTRACTOR’S full responsibility to provide the insurance required by this Contract. Compliance with the insurance requirements of this Contract shall not limit the liability of CONTRACTOR or its sub-contractors, employees or agents to CITY or others, and shall be in addition to and not in lieu of any other remedy available to CITY under this Contract or otherwise. CITY reserves the right to request and review a copy of any required insurance policy or endorsement to assure compliance with these requirements.
