Warranty Claims 8.1 The Supplier shall be obliged to inspect the quantity and the quality of the goods before delivery. 8.2 We shall have no duty to inspect the goods nor to notify any detected defects within a specific time period. In any event, a warranty claim will be timely made if raised prior to the expiration of the warranty period set forth in sub- clause 8.7 hereof. 8.3 We are entitled to demand, at our discretion, that the Supplier either replace defective goods or remedy the defect. The Supplier may only refuse the form of supplementary performance we have chosen on the grounds of dispropor- tionate cost where such costs would exceed the value of the goods in defect-free condition. 8.4 The Supplier warrants that the supplied goods are free of any fault or defect, whether of design, workmanship or materials. 8.5 Where supplementary performance fails, we are entitled to withdraw from the contract according to applicable law. Supplementary performance shall be deemed to have failed after one unsuccessful attempt, provided that the type of product or defect does not indicate that we are required to accept a further attempt at supplementary perfor- xxxxx. 8.6 We are entitled to remedy defects ourselves or to have them remedied at the expense of the Supplier, or to under- take shortfall purchases, where exigency or particular urgency applies and it is no longer possible to notify the Sup- plier with a deadline because of such particular urgency. 8.7 The Supplier shall be liable for any breach of the warranties if, within 18 months after the delivery date, we give no- xxxx in writing to the Supplier of any defect in the goods which shall arise from faulty design, materials or xxxxxxx- ship. This warranty period starts upon delivery of the goods and shall be suspended while the Supplier attempts supplementary performance. With respect to replaced or repaired goods, a new warranty period shall commence upon delivery of the replaced or repaired goods. 8.8 We expressly reserve the right to claim damages under applicable law. Warranty disclaimers and/or limitations of li- ability on the part of the Supplier do not apply. The foregoing warranties shall be without prejudice to any other rights and remedies available to us. 8.9 The Supplier indemnifies and holds us harmless against third party claims in connection with defective, delayed or in other manners faulty delivery, including court and attorney fees.
Contractor Warranties 7.12.1 If and to the extent Developer obtains general or limited warranties from any Contractor in favor of Developer with respect to design, materials, workmanship, equipment, tools, supplies, software or services, Developer also shall cause such warranty to be expressly extended to TxDOT and any third parties for whom Work is being performed or equipment, tools, supplies or software is being supplied by such Contractor; provided that the foregoing requirement shall not apply to standard, pre-specified manufacturer warranties of mass- marketed materials, products (including software products), equipment or supplies where the warranty cannot be extended to TxDOT using commercially reasonable efforts. TxDOT agrees to forebear from exercising remedies under any such warranty so long as Developer or a Lender is diligently pursuing remedies thereunder. To the extent that any Contractor warranty would be voided by reason of Developer's negligence in incorporating material or equipment into the Work, Developer shall be responsible for correcting such defect. 7.12.2 Contractor warranties (if any) are in addition to all rights and remedies available under the CDA Documents or applicable Law or in equity, and shall not limit Developer’s liability or responsibility imposed by the CDA Documents or applicable Law or in equity with respect to the Work, including liability for design Defects, latent construction Defects, strict liability, breach, negligence, willful misconduct or fraud.
Warranty Liability 6.1 The Seller represents and warrants that: (i) the Goods shall comply with all specifications and requirements contained in the Order or agreed in writing between the Buyer and Seller; (ii) the Goods shall be state of the art and new; (iii) the Goods shall be fit for the particular purposes that such specific Goods will usually be expected to be used for; (iv) the Goods shall be free from defects in design, materials and workmanship; (v) the Goods shall satisfactorily comply with the performance requirements expected by the Buyer; and (vi) the Goods shall meet all applicable statutory requirements and standards, especially those relating to the environment, safety and health (individually “Warranty” and collectively the “Warranties”). Any representations or warranties relating to the Goods and included in the Seller's catalogues, brochures, proposals, sales literature and quality systems or otherwise made by the Seller to the Buyer (whether verbally or in writing) shall be binding on Seller. The Seller warrants the adequacy of the technical specifications of the Order to meet the specific needs of the Buyer, and the Seller acknowledges having examined those specifications thoroughly. 6.2 The Seller warrants that all Goods sold and delivered to the Buyer (whether in terms of clause 4.1 or otherwise) are free from any lien or encumbrance of any nature whatsoever and upon delivery (whether in terms of clause 4.1 or otherwise), of the Goods to the Buyer, free and unencumbered ownership of the Goods shall pass to the Buyer upon receipt of payment for the Goods and thereafter the Buyer will be the sole owner of, and have valid and exclusive title to, the Goods. The Seller warrants further that no third party shall have any right to acquire the Goods. 6.3 The Seller warrants that the Goods will comply with the Manufacturers’ Warranty from date of delivery thereof. 6.4 If any Goods at any time are found not to comply with the Manufacturers’ Warranty, the Buyer shall be entitled, at its sole discretion, by written notice to the Seller to: (a) rescind the Order according to the provisions of clause 10 (Termination); (b) accept such Goods with a reduction in price equal to a reasonable estimate of the reduced utility of the Goods to the Buyer; or
Warranty Obligations (a) Project Co represents, warrants and covenants that: (i) the Works shall conform to the requirements of this Project Agreement, Good Industry Practice, Applicable Law and all professional engineering principles generally accepted as standards of the industry in the Province of Ontario; (ii) the Works shall be free of defects, including design defects, errors and omissions; and (iii) materials and equipment shall be of good quality and in compliance with this Project Agreement. (b) During the Warranty Period and subject to Section 11.15(c), Project Co shall promptly, at its sole cost and expense, correct and Make Good all Construction Defects arising in respect of the Works. For greater certainty, Project Co is required to correct and Make Good Construction Defects related to any Product during the applicable Warranty Period despite Project Co having obtained on Contracting Authority’s behalf industry- standard or other equipment warranties in accordance with Section 11.15(f). For all work to correct Construction Defects, the applicable Warranty Period shall be extended for a further two years from the date of the last work completed in respect of such corrective Works. For clarity, any extension of a Warranty Period for the purposes of a correction shall only apply to the relevant Construction Defect and not the Works as a whole. (c) In addition to the obligation to correct and Make Good Construction Defects during the Warranty Period, Project Co shall at its expense correct and Make Good any Construction Defects that could not reasonably have been ascertained by a competent person in accordance with Good Industry Practice during a visual inspection of the Works (“Construction Latent Defect”), provided Contracting Authority gives Project Co written Notice of the Construction Latent Defect within the time frame applicable to such Construction Latent Defect pursuant to the Limitations Act, 2002 (Ontario). (d) The warranties described in this Section 11.15 shall cover labour and material, including, the costs of removal and replacement of covering materials. The warranties shall not limit extended warranties on any Product or item of equipment called for elsewhere in the Output Specifications or otherwise provided by any manufacturer of such Product or equipment. (e) If Project Co fails to correct and Make Good any Construction Defects or Construction Latent Defects in accordance with Sections 11.15(b) and 11.15(c) and in the time period specified in Section 11.16(a) or Section 11.16(b), as applicable, without prejudice to any other right or remedy Contracting Authority may have, Contracting Authority may correct such Construction Defects or Construction Latent Defects at Project Co’s sole cost and expense. (f) Project Co shall obtain warranties from the manufacturers of each of the Products for the duration(s) and in accordance with the applicable requirements specified in the Output Specifications in the name of and to the benefit of both Project Co and Contracting Authority. Where, in respect of a Product warranty, the Output Specifications do not specify a specific duration and/or other requirements, Project Co shall obtain industry-standard warranties from the applicable manufacturers in the name of and to the benefit of Project Co and Contracting Authority which shall extend no less than two years from the Substantial Completion Date. Each Product warranty shall be issued by the applicable manufacturer and delivered to Project Co no later than 30 days prior to the Substantial Completion Date. Project Co shall ensure that each Product warranty, including any Product warranty extended under this Section 11.15(f), is fully assigned to Contracting Authority, at no cost or expense to Contracting Authority, at the end of the Warranty Period, as such Warranty Period may be extended in accordance with Section 11.15(b).
Vendor Warranties 6.1 The vendor warrants that these general conditions 1 to 35 are identical to the general conditions 1 to 35 in the form of contract of sale of land published by the Law Institute of Victoria Limited and the Real Estate Institute of Victoria Pty Ltd in the month and year set out at the foot of this page. 6.2 The warranties in general conditions 6.3 and 6.4 replace the purchaser’s right to make requisitions and inquiries. 6.3 The vendor warrants that the vendor: (a) has, or by the due date for settlement will have, the right to sell the land; and (b) is under no legal disability; and (c) is in possession of the land, either personally or through a tenant; and (d) has not previously sold or granted any option to purchase, agreed to lease or granted a pre-emptive right which is current over the land and which gives another party rights which have priority over the interest of the purchaser; and (e) will at settlement be the holder of an unencumbered estate in fee simple in the land; and (f) will at settlement be the unencumbered owner of any improvements, fixtures, fittings and goods sold with the land. 6.4 The vendor further warrants that the vendor has no knowledge of any of the following: (a) public rights of way over the land; (b) easements over the land; (c) lease or other possessory agreement affecting the land; (d) notice or order directly or indirectly affecting the land which will not be dealt with at settlement, other than the usual rate notices and any land tax notices; (e) legal proceedings which would render the sale of the land void or voidable or capable of being set aside. 6.5 The warranties in general conditions 6.3 and 6.4 are subject to any contrary provisions in this contract and disclosures in the section 32 statement. 6.6 If sections 137B and 137C of the Building Act 1993 apply to this contract, the vendor warrants that: (a) all domestic building work carried out in relation to the construction by or on behalf of the vendor of the home was carried out in a proper and workmanlike manner; and (b) all materials used in that domestic building work were good and suitable for the purpose for which they were used and that, unless otherwise stated in the contract, those materials were new; and (c) domestic building work was carried out in accordance with all laws and legal requirements, including, without limiting the generality of this warranty, the Building Act 1993 and regulations made under the Building Act 1993. 6.7 Words and phrases used in general condition 6.6 which are defined in the Building Act 1993 have the same meaning in general condition 6.6.
Product Liability Claims As soon as it becomes aware, each party will give the other prompt written notice of any defect or alleged defect in a Product, any injury alleged to have occurred as a result of the use or application of a Product, and any circumstances that may give rise to litigation or recall of a Product or regulatory action that may affect the sale or manufacture of a Product, specifying, to the extent the party has such information, the time, place and circumstances thereof and the names and addresses of the persons involved. Each party will also furnish promptly to the other copies of all papers received in respect of any claim, action or suit arising out of such alleged defect, injury or regulatory action.
Warranty Against Encumbrances Seller warrants that the goods are now free, and at the time of delivery shall be free, from any security interest or other lien or encumbrance.
Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.] 19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor: 12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. 12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University. 12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,
Warranty Limitations This Contractual Warranty does not warrant uninterrupted or error-free operation of the Product or cover normal wear and tear of the Product or costs related to the removal, installation, or troubleshooting of the customer's electrical systems. The warranty claims that relate to defects caused by any of the following factors are not covered by the Contractual Warranty: • Improper Use or Non-compliance with installation, commissioning, operation or maintenance instructions (i.e. not according to the operation & installation manual) • Unauthorized modifications, changes or attempted repairs, • Vandalism, destruction through external influence and/or persons/animals • Use in an unsuitable environment, including any environment or location that causes excessive wear and tear or dirt or dust or debris buildup within the system or that is difficult or unsafe for Xantrex LLC representatives to access • Insufficient ventilation • Installation in a corrosive environment • Failure to observe applicable safety standards & regulations • Damages during transportation or storage • Force majeure, examples include, but not limited to: fire, flood, earthquakes, storm damage, overvoltage & lightning strikes • Exposure to fire, water, snow, moisture, or liquid ingress (except for any such exposure to environmental conditions that your Product was specifically designed to withstand as indicated in the applicable specifications for your Product) • Used as a component part of a product expressly warranted by another manufacturer • If the original identification (trade-mark, serial number) markings have been defaced, altered, or removed • Consumable components of any type are not covered, including but not limited to fans, fuses and filters etc. • Cosmetic shortcoming which do not impair the use of the product for the intended purpose i.e. supply of energy Warranty claims also exclude: • Damages arising due to the fact that the use of the product for the intended purpose is no longer possible or only possible with restrictions as a result of amendments to the statutory provisions applicable to the operation of the product made after the delivery of the product • Compensation for damages related to loss of power production or business operation or any expenses incurred by customer towards repair & replacement of the product (including but not limited to labor, transportation, temporary power) • Cost arising from changes to existing PV systems or building installations or vehicle or marine vessel installation and like • Additional costs and expenses (i.e. shipping costs, travel, accommodation, meals, etc.) arising due to remote locations of the indicated geographies, including but not limited to islands and overseas territories
Warranty Exclusions The Limited Warranty in clauses 1.2 and 1.3 does not apply: a) if the Product was not purchased and installed in Australia; b) if You do not grant BYD or BYD Partner access to the performance data of the Product over the Internet upon request after reporting the warranty claim and/or manipulate such data; c) to wear and tear in the appearance of the Product (including but not limited to any scratches, stains, mechanical wear, rust or mould) which does not impair its function; d) to any damage to property or personal injury arising from any defect if the state of scientific and technical knowledge at the time when the Product is sold to Original Buyer was not such as to enable the defect to be discovered; e) if the invoice for the Product and the information listed in clause 4 below is not provided with the warranty claim; or f) if the serial number on the Product can no longer be identified or has been modified.
