Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.
Procedures for Providing NP Through Full NXX Code Migration Where a Party has activated an entire NXX for a single Customer, or activated at least eighty percent (80%) of an NXX for a single Customer, with the remaining numbers in that NXX either reserved for future use by that Customer or otherwise unused, if such Customer chooses to receive Telephone Exchange Service from the other Party, the first Party shall cooperate with the second Party to have the entire NXX reassigned in the LERG (and associated industry databases, routing tables, etc.) to an End Office operated by the second Party. Such transfer will be accomplished with appropriate coordination between the Parties and subject to appropriate industry lead times for movements of NXXs from one switch to another. Neither Party shall charge the other in connection with this coordinated transfer.
CERTIFICATION PROHIBITING DISCRIMINATION AGAINST FIREARM AND AMMUNITION INDUSTRIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has at least ten (10) full-time employees; (c) this contract has a value of at least $100,000 that is paid wholly or partly from public funds; (d) the contract is not excepted under Tex. Gov’t Code § 2274.003 of SB 19 (87th leg.); and (e) governmental entity has determined that company is not a sole-source provider or governmental entity has not received any bids from a company that is able to provide this written verification, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 19 (87th session), the company hereby certifies and verifies that the company, or association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, including a wholly owned subsidiary, majority-owned subsidiary parent company, or affiliate of these entities or associations, that exists to make a profit, does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association and will not discriminate during the term of this contract against a firearm entity or firearm trade association. For purposes of this contract, “discriminate against a firearm entity or firearm trade association” shall mean, with respect to the entity or association, to: “
(1) refuse to engage in the trade of any goods or services with the entity or association based solely on its status as a firearm entity or firearm trade association; (2) refrain from continuing an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association; or (3) terminate an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association. See Tex. Gov’t Code § 2274.001(3) of SB 19. “Discrimination against a firearm entity or firearm trade association” does not include: “
(1) the established policies of a merchant, retail seller, or platform that restrict or prohibit the listing or selling of ammunition, firearms, or firearm accessories; and (2) a company’s refusal to engage in the trade of any goods or services, decision to refrain from continuing an existing business relationship, or decision to terminate an existing business relationship to comply with federal, state, or local law, policy, or regulations or a directive by a regulatory agency, or for any traditional business reason that is specific to the customer or potential customer and not based solely on an entity’s or association’s status as a firearm entity or firearm trade association.” See Tex. Gov’t Code § 2274.001(3) of SB 19.
Referral Procedures Section 1. For Local Unions now having a job referral system as contained in their Collective Bargaining Agreement, the Contractor agrees to utilize such system and it shall be used exclusively by such Contractor, except as it may be modified by this Article. Referrals shall not be affected by obligations of Union membership or the lack thereof. Where airport security clearance requirements apply to work to be performed, the Contractor shall inform the Union’s hiring hall dispatcher of those requirements when requesting workers.
Section 2. In the event that Local Unions are unable to fill any request for employees within the time specified by the local CBAs the Contractor may employ applicants from any other available source. The Contractor shall inform the Union of the name and social security number of any applicants hired from other sources and shall refer the applicant to the Local Union for dispatch to the projects prior to the commencement of work.
Section 3. There shall be no discrimination against any employee or applicant for employment because of his/her membership or non-membership in the union or based upon race, creed, color, sex, age or national origin, or any other legally protected class of such employee or applicant.
Section 4. No employee covered by this Agreement shall be required to join any Union as a condition of being employed on the project; provided, however, that an employee who is a member of the referring union at the time of the referral shall maintain that membership while employed under the Agreement. All employees shall, however, be required to comply with the union security provision of the applicable Collective Bargaining Agreement, for the period during which they are performing on-site work, except as modified by this Agreement. The Contractor agrees to deduct union dues or representation fees, whichever is applicable, from the pay of any employee who executes a voluntary authorization for such deductions and to remit the dues to the Union or Council.
Section 5. The parties agree that where a Contractor is not party to a current Collective Bargaining Agreement with the Union having jurisdiction over the affected work, the Contractor may request by name, and the Local will honor, referral of up to a maximum of five (5) persons per each contractor (“core” employees), provided that the Contractor first demonstrate that those persons possess the following qualifications:
(1) Any license required by state or federal law for the project work to be performed;
(2) Have worked a total of at least one thousand (1,000) hours in the construction craft during the prior three (3) years;
(3) Were on the Contractor’s active payroll for at least sixty (60) out of the one hundred eighty (180) calendar days prior to the contract award;
(4) Have the ability to perform the work safely. The Contractor may elect to hire its first “core” employee to be a xxxxxxx. After the contractor hires his first core employee, the Union will refer to such contractor one journeyman employee from the hiring hall out-of–work list for the affected trade or craft, then refer one of such Contractor’s “core” employees as a journeyman, and shall, alternate, one core employee and one employee from the out-of-work list, until such Contractor’s crew requirements are met or until such Contractor has hired five (5) “core” employees, whichever occurs first. Thereafter, all additional employees in the affected trade or craft shall be hired exclusively from the hiring hall out-of-work list(s). For the duration of the Contractor’s work the ratio of “core” employees to hiring hall referrals shall be maintained and when the Contractor’s workforce is reduced, employees shall be reduced in the same ratio as was applied in the initial hiring. All employees, core and union, shall be dispatched from the appropriate union. Trust benefits shall be paid on all employees, core and union.
Section 6. Upon referral or dispatch from a Union, “turnaround” or refusal of any worker by the Contractors, requires written explanation from the Contractor that shall be communicated from the Prime Contractor to the Port and affected Union within 48 hours.
Section 7. Individual seniority will not be recognized or applied to employees working on the project. This provision will not interfere with or supersede the use by individual Contractors of “call lists” maintained by such Contractor pursuant to addenda to the local Collective Bargaining Agreement between such Contractor and a Union signatory to this Agreement.
Section 8. The selection of craft foremen and/or general foremen and the number of such foremen and/or general foremen required shall be entirely the responsibility of the Contractor. Craft foremen shall be designated working foremen at the request of the Contractor. Craft workers covered by this Agreement will, in the normal day- to-day operations, take their direction and supervision from their xxxxxxx.
Procedures and Applicable Law A demand for arbitration must be communicated in writing to all parties. Each party shall select an arbitrator (party arbitrator) within thirty days and a third arbitrator (neutral arbitrator) shall be selected by either party. Each party to the arbitration shall pay such party’s pro rata share of the expenses and fees of neutral arbitrator, together with other expenses of the arbitration incurred or approved by the neutral arbitrator, not including counsel fees or witness fees, or other expenses incurred by a party for such party’s own benefit. The parties agree that the arbitrators have the immunity of a judicial officer from civil liability when acting in the capacity of arbitrator under this contract. This immunity shall supplement, not supplant, any other applicable statutory or common law. Either party shall have the absolute right to arbitrate separately the issues of liability and damages upon written request to the neutral arbitrator. The parties’ consent to the intervention and joinder in this arbitration of any person or entity which could otherwise be a proper additional party in a court action, and upon such intervention and joinder any existing court action against such additional person or entity shall be stayed pending arbitration. The parties agree that provisions of California law applicable to health care providers shall apply to disputes within this arbitration agreement, including, but not limited to, Code of Civil Procedure Sections 340.5 and 667.7 and Civil Code Sections 3333.1 and 3333.2. Any party may bring before the arbitrators a motion for summary judgement or summary adjudication in accordance with the Code of Civil Procedure. Discovery shall be conducted pursuant to Code of Civil Procedure section 1283.05; however dispositions may be taken without prior approval of the neutral arbitrator.
Procedures for Advances (a) In the case of the making of any Advance, the repayment of any Advance, or any termination, increase or reduction of the Facility Amount and prepayments of Advances, the Borrower shall give the Administrative Agent a Borrower Notice. Each Borrower Notice shall specify the amount (subject to Section 2.1 hereof) of Advances to be borrowed or repaid and the Funding Date or repayment date (which, in all cases, shall be a Business Day) and whether such Advance is a Revolver Advance or a Swing Advance.
(b) Subject to the conditions described in Section 2.1, the Borrower may request an Advance from the Lenders by delivering to the Administrative Agent at certain times the information and documents set forth in this Section 2.2.
(c) No later than 12:00 noon (New York, New York time) five (5) Business Days prior to the proposed Funding Date for a Revolver Advance (or such shorter period of time or later date as may be agreed to by the Required Lenders), the Borrower shall notify (i) the Collateral Custodian by delivery to the Collateral Custodian of written notice of such proposed Funding Date, and (ii) the Administrative Agent by delivery to the Administrative Agent of a credit report and transaction summary for each Loan that is the subject of the proposed Advance setting forth the credit underwriting by the Originator of such Loan, including without limitation a description of the Obligor and the proposed loan transaction in the form of Exhibit M hereto; provided that, in the case of Advances funding Revolver Loans, the requirements of this Section 2.2(c) shall apply only with respect to the first Advance to be made with respect to each such Revolver Loan. By 5:00 p.m. (New York, New York time) on the next Business Day, the Administrative Agent shall use its best efforts to confirm to the Borrower the receipt of such items and whether it has reviewed such items and found them to be complete and in proper form. If the Administrative Agent makes a determination that the items are incomplete or not in proper form, it will communicate such determination to the Borrower. Failure by the Administrative Agent to respond to the Borrower by 5:00 p.m. (New York, New York time) on the day the related Funding Request is delivered by the Borrower shall constitute an implied determination that the items are incomplete or not in proper form. The Borrower will take such steps requested by the Administrative Agent to correct the problem(s). In the event of a delay in the actual Funding Date due to the need to correct any such problems, the Funding Date shall be no earlier than two (2) Business Days after the day on which the Administrative Agent confirms to the Borrower that the problems have been corrected.
(d) No later than 1:00 p.m. (New York, New York time) one (1) Business Day prior to the proposed Funding Date for a Revolver Advance (or such shorter period of time or later date as may be agreed to by the Required Lenders), the Administrative Agent, each Managing Agent and the Collateral Custodian, as applicable, shall receive or shall have previously received the following:
(i) a Funding Request in the form of Exhibit A;
(ii) a wire disbursement and authorization form shall be delivered to the Administrative Agent; and
(iii) a certification substantially in the form of Exhibit H concerning the Collateral Custodian’s receipt of certain documentation relating to the Eligible Loan(s) related to such Advance shall be delivered to the Administrative Agent, which may be delivered either as a separate document or incorporated in the Monthly Report. Each Funding Request for a Revolver Advance shall specify the aggregate amount of the requested Advance, which shall be in an amount equal to at least $500,000.
(e) No later than 12:00 noon (New York, New York time) on the Business Day proposed for a Swing Advance, the Administrative Agent shall receive or shall have previously received the following:
(i) a Funding Request in the form of Exhibit A; and
(ii) a wire disbursement and authorization form.
(f) Each Funding Request shall be accompanied by (i) a Borrower Notice, depicting the outstanding amount of Advances under this Agreement and representing that all conditions precedent for a funding have been met, including a representation by the Borrower that the requested Advance shall not, on the Funding Date thereof, exceed the Availability on such day, (ii) a calculation of the Borrowing Base as of the applicable Funding Date (which calculation may, for avoidance of doubt, take into account (A) Loans which will become Transferred Loans on or prior to such Funding Date and (B) an updated Loan List including each Loan that is subject to the requested Advance, (C) the proposed Funding Date, and (D) wire transfer instructions for the Advance; provided, however, the Funding Request for a Swing Advance shall be required to contain only the information described in Section 2.2(e)(i) and (ii) above. A Funding Request shall be irrevocable when delivered; provided however, that if the Borrowing Base calculation delivered pursuant to clause (ii) above includes a Loan which does not become a Transferred Loan on or before the applicable Funding Date as anticipated, and the Borrower cannot otherwise make the representations required pursuant to clause (i) above, the Borrower shall revise the Funding Request accordingly, and shall pay any loss, cost or expense incurred by any Lender in connection with the broken funding evidenced by such revised Funding Request.
(g) On the Funding Date following the satisfaction of the applicable conditions set forth in this Section 2.2 and Article III, the Lenders shall make available to the Administrative Agent at its address listed beneath its signature on its signature page to this Agreement (or on the signature page to the Joinder Agreement pursuant to which it became a party hereto), for deposit to the account of the Borrower or its designee in same day funds, at the account specified in the Funding Request, an amount equal to such Lender’s ratable share of the Advance then being made (except that in the case of a Swing Advance, the Swingline Lender will make available to the Borrower the amount of any such Swing Advance). Each wire transfer of an Advance to the Borrower shall be initiated by the applicable Lender no later than 3:00 p.m. (New York, New York time) on the applicable Funding Date.
Procedures for LNP Request The Parties shall provide for the requesting of End Office LNP capability on a reciprocal basis through a written request. The Parties acknowledge that Verizon has deployed LNP throughout its network in compliance with FCC 96-286 and other applicable FCC Regulations.
15.4.1 If Party B desires to have LNP capability deployed in an End Office of Party A, which is not currently capable, Party B shall issue a LNP request to Party A. Party A will respond to the Party B, within ten (10) days of receipt of the request, with a date for which LNP will be available in the requested End Office. Party A shall proceed to provide for LNP in compliance with the procedures and timelines set forth in FCC 00-000, Xxxxxxxxx 80, and FCC 97-74, Paragraphs 65 through 67.
15.4.2 The Parties acknowledge that each can determine the LNP-capable End Offices of the other through the Local Exchange Routing Guide (LERG). In addition, the Parties shall make information available upon request showing their respective LNP-capable End Offices, as set forth in this Section 15.4.
Procedures for Actions and Consents of Partners The actions requiring Consent of any Partner or Partners pursuant to this Agreement, including Section 7.3 hereof, or otherwise pursuant to applicable law, are subject to the procedures set forth in this Article 14.
Purpose; Incorporation by Reference of Auction Procedures and Settlement Procedures (a) The Statement for each series of MuniPreferred will provide that the Applicable Rate for such series for each Subsequent Rate Period thereof shall, except under certain conditions, be the rate per annum that a bank or trust company appointed by the Fund advises results from implementation of the Auction Procedures for such series. The Board of Directors or Board of Trustees, as the case may be, of the Fund has adopted a resolution appointing the Auction Agent as auction agent for purposes of the Auction Procedures for each series of MuniPreferred. The Auction Agent accepts such appointment and agrees to follow the procedures set forth in this Section 2 and the Auction Procedures for the purpose of determining the Applicable Rate for each series of MuniPreferred for each Subsequent Rate Period thereof for which the Applicable Rate is to be determined by an Auction. Each periodic implementation of such procedures is hereinafter referred to as an "Auction."
(b) All of the provisions contained in the Auction Procedures and the Settlement Procedures are incorporated herein by reference in their entirety and shall be deemed to be a part hereof to the same extent as if such provisions were fully set forth herein.
Procedures for Surrender (i) As promptly as practicable after the Effective Time (but in no event later than three (3) Business Days thereafter), Parent shall cause the Paying Agent to mail or otherwise provide each holder of record of Eligible Common Shares that are (A) Certificates or (B) Book-Entry Shares not held, directly or indirectly, through DTC notice advising such holders of the effectiveness of the Merger, which notice shall include (1) appropriate transmittal materials (including a customary letter of transmittal) specifying that delivery shall be effected, and risk of loss and title to the Certificates or such Book-Entry Shares shall pass only upon delivery of the Certificates (or affidavits of loss in lieu of the Certificates, as provided in Section 4.2(f)) or the surrender of such Book-Entry Shares to the Paying Agent (which shall be deemed to have been effected upon the delivery of a customary “agent’s message” with respect to such Book-Entry Shares or such other reasonable evidence, if any, of such surrender as the Paying Agent may reasonably request pursuant to the terms and conditions of the Paying Agent Agreement), as applicable (such materials to be in such form and have such other provisions as Parent and the Company may reasonably agree), and (2) instructions for effecting the surrender of the Certificates (or affidavits of loss in lieu of the Certificates, as provided in Section 4.2(f)) or such Book-Entry Shares to the Paying Agent in exchange for the Per Share Common Stock Merger Consideration that such holder is entitled to receive as a result of the Merger pursuant to this Article IV.
(ii) With respect to Book-Entry Shares held, directly or indirectly, through DTC, Parent and the Company shall cooperate to establish procedures with the Paying Agent, DTC, DTC’s nominees and such other necessary or desirable third-party intermediaries to ensure that the Paying Agent shall transmit to DTC or its nominees as promptly as practicable after the Effective Time, upon surrender of Eligible Common Shares held of record by DTC or its nominees in accordance with DTC’s customary surrender procedures and such other procedures as agreed by Parent, the Company, the Paying Agent, DTC, DTC’s nominees and such other necessary or desirable third-party intermediaries, the Per Share Common Stock Merger Consideration to which the beneficial owners thereof are entitled to receive as a result of the Merger pursuant to this Article IV.
(iii) Upon surrender to the Paying Agent of Eligible Common Shares that (A) are Certificates, by physical surrender of such Certificates (or affidavits of loss in lieu of the Certificates, as provided in Section 4.2(f)) together with the letter of transmittal, duly completed and executed, and such other documents as may be reasonably required by the Paying Agent, (B) are Book-Entry Shares not held through DTC, by book-receipt of an “agent’s message” by the Paying Agent in connection with the surrender of Book-Entry Shares (or such other reasonable evidence, if any, of surrender with respect to such Book-Entry Shares, as the Paying Agent may reasonably request pursuant to the terms and conditions of the Paying Agent Agreement), in each case of the foregoing clauses (A) and (B) of this 4.2(c)(iii), pursuant to such materials and instructions contemplated by Section 4.2(c)(i), and (C) are Book-Entry Shares held, directly or indirectly, through DTC, in accordance with DTC’s customary surrender procedures and such other procedures as agreed by the Company, Parent, the Paying Agent, DTC, DTC’s nominees and such other necessary or desirable third-party intermediaries pursuant to Section 4.2(a)(i), the holder of such Certificate or Book-Entry Share shall be entitled to receive in exchange therefor, and Parent shall cause the Paying Agent to pay and deliver, out of the Exchange Fund, as promptly as practicable to such holders of Eligible Common Shares, an amount in cash in immediately available funds (after giving effect to any required Tax withholdings as provided in Section 4.2(g)) equal to the product obtained by multiplying (1) the number of Eligible Common Shares represented by such Certificates (or affidavits of loss in lieu of the Certificates, as provided in Section 4.2(f)) or such Book-Entry Shares by (2) the Per Share Common Stock Merger Consideration, and each Certificate so surrendered shall forthwith be cancelled.
(iv) In the event of a transfer of ownership of any Certificate that is not registered in the stock transfer books or ledger of the Company or if the consideration payable is to be paid in a name other than that in which the Certificate or Certificates surrendered or transferred in exchange therefor are registered in the stock transfer books or ledger of the Company, a check for any cash to be exchanged upon due surrender of any such Certificate or Certificates may be issued to such a transferee if the Certificate or Certificates is or are (as applicable) properly endorsed and otherwise in proper form for surrender and presented to the Paying Agent, accompanied by all documents required to evidence and effect such transfer and to evidence that any applicable Transfer Taxes have been paid or are not applicable, in each case, in form and substance, reasonably satisfactory to Parent and the Paying Agent. Payment of the Per Share Common Stock Merger Consideration with respect to Book-Entry Shares shall only be made to the Person in whose name such Book-Entry Shares are registered in the stock transfer books or ledger of the Company.
(v) For the avoidance of doubt, no interest shall be paid or accrued for the benefit of any holder of Eligible Common Shares on any amount payable upon the surrender of any Eligible Common Shares.
