Termination Procedures The Contractor acknowledges that this Agreement may be terminated for Convenience or Default.
Termination Procedure a. Upon termination of this Contract the DCYF, in addition to any other rights provided in this Contract, may require the Contractor to deliver to DCYF any property specifically produced or acquired for the performance of such part of this Contract as has been terminated. The provisions of Section (TREATMENT OF ASSETS) shall apply in such property transfer.
b. DCYF shall pay to the Contractor the agreed upon price, if separately stated, for completed work and service(s) accepted by DCYF, and the amount agreed upon by the Contractor and DCYF for (i) completed work and service(s) for which no separate price is stated, (ii) partially completed work and service(s), (iii) other property or services which are accepted by DCYF, and (iv) the protection and preservation of property, unless the termination is for default, in which case DCYF and Contractor may agree to the extent of the liability of DCYF. Failure to agree to the extent of the liability shall be a dispute within the meaning of Section (DISPUTES) of this Contract. DCYF may withhold from any amounts due the Contractor such sum as DCYF determines to be necessary to protect DCYF against potential loss or liability.
c. The rights and remedies of DCYF provided in this Section (TERMINATION PROCEDURE) shall not be exclusive and are in addition to any other rights and remedies provided by law or under this Contract.
d. After receipt of a notice of termination, and except as otherwise directed by DCYF, the Contractor shall:
(1) Stop work under the contract on the date, and to the extent specified, in the notice;
(2) Place no further orders or subcontracts for materials, services, or facilities except as may be necessary for completion of such portion of the work under the Contract as is not terminated;
(3) Assign to DCYF, in the manner, at the times, and to the extent directed by DCYF, all of the rights, title, and interest of the Contractor under the orders and subcontracts so terminated, in which case DCYF has the right, at its discretion, to settle or pay any or all claims arising out of the termination of such orders and subcontracts;
(4) Settle all outstanding liabilities and all claims arising out of such termination of orders and subcontracts, with the approval or ratification of DCYF to the extent DCYF may require, which approval or ratification shall be final for all the purposes of this clause;
(5) Transfer title to DCYF and deliver in the manner, at the times, and to the extent directed by this Contract or by DCYF any property which, if the contract had been completed, would have been required to be furnished to DCYF;
(6) Complete performance of such part of the work as shall not have been terminated by DCYF; and
(7) Take such action as may be necessary, or as DCYF may direct, for the protection and preservation of the property related to this contract which is in the possession of the Contractor and in which DCYF has or may acquire an interest.
Additional Termination Provisions Notwithstanding and in addition to the foregoing, in the event that (i) a Mortgage Loan becomes delinquent for a period of 90 days or more (a "Delinquent Mortgage Loan") or (ii) a Mortgage Loan becomes an REO Property, the Purchaser may at its election terminate this Agreement with respect to such Delinquent Mortgage Loan or REO Property, upon 15 days' written notice to the Seller.
Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.
CFR PART 200 Termination Termination for cause and for convenience by the grantee or subgrantee including the manner by which it will be effected and the basis for settlement. (All contracts in excess of $10,000) Pursuant to the above, when federal funds are expended by ESC Region 8 and TIPS Members, ESC Region 8 and TIPS Members reserves the right to terminate any agreement in excess of $10,000 resulting from this procurement process for cause after giving the vendor an appropriate opportunity and up to 30 days, to cure the causal breach of terms and conditions. ESC Region 8 and TIPS Members reserves the right to terminate any agreement in excess of $10,000 resulting from this procurement process for convenience with 30 days notice in writing to the awarded vendor. The vendor would be compensated for work performed and goods procured as of the termination date if for convenience of the ESC Region 8 and TIPS Members. Any award under this procurement process is not exclusive and the ESC Region 8 and TIPS reserves the right to purchase goods and services from other vendors when it is in the best interest of the ESC Region 8 and TIPS. Does vendor agree? Yes
Term Termination and Survival 9.1 This Agreement shall commence as of the Effective Date and shall continue thereafter until the completion of the Services under all Statements of Work unless sooner terminated pursuant to Section 9.2 or Section 9.3.
9.2 Either Party may terminate this Agreement, effective upon written notice to the other Party (the “Defaulting Party”) if the Defaulting Party:
(a) Materially breaches this Agreement, and such breach is incapable of cure, or with respect to a material breach capable of cure, the Defaulting Party does not cure such breach within 30 days after receipt of written notice of such breach.
(b) Becomes insolvent or admits its inability to pay its debts generally as they become due.
(c) Becomes subject, voluntarily or involuntarily, to any proceeding under any domestic or foreign bankruptcy or insolvency law, which is not fully stayed within seven business days or is not dismissed or vacated within 45 business days after filing.
(d) Is dissolved or liquidated or takes any corporate action for such purpose.
(e) Makes a general assignment for the benefit of creditors.
(f) Has a receiver, trustee, custodian, or similar agent appointed by order of any court of competent jurisdiction to take charge of or sell any material portion of its property or business.
9.3 Notwithstanding anything to the contrary in Section 9.2(a), TAI may terminate this Agreement upon written notice to XXX upon the occurrence of any of the following events (each of the following, a “Specified Event of Default”):
(a) XXX fails to pay any undisputed amount when due hereunder and such failure continues for 30 days after XXX’s receipt of written notice of nonpayment;
(b) XXX fails to timely achieve, complete, or pass any of the XXX Caravan STC Milestone Requirements by the applicable XXX Completion Date (subject to the applicable cure period) as set forth in Exhibit A as determined in the good faith discretion of TAI; provided that, the applicable XXX Completion Dates shall be equitably adjusted to the extent XXX is not able to achieve, complete or pass any XXX Caravan STC Milestone Requirement or such XXX Caravan STC Milestone Requirement is not otherwise met, in each case as a result of (a) the material breach of TAI of its obligations hereunder or (b) the occurrence of a Force Majeure Event, with an extension to the corresponding XXX Completion Date commensurate with the delay caused by such TAI breach or Force Majeure Event, provided, however, that no extension related to a Force Majeure Event shall be longer than 45 days;
(c) the occurrence of a “Change of Control”, which means (i) the acquisition by any Person of ownership or power to vote more than 49% of the voting stock of XXX by means of any transaction or series of related transactions (including any reorganization, merger or consolidation, but excluding any business combination with a SPAC by XXX or its Affiliate completed prior to the one (1) year anniversary of the date hereof), (ii) the acquisition of ownership or power to vote more than 10% of the voting stock of XXX by a TAI competitor, (iii) a sale of all or substantially all of the assets of XXX, (iv) a material change of XXX’s senior leadership occurring prior to the five (5) year anniversary of the date hereof, in each case of the foregoing clauses (i) – (iv), directly or indirectly, including as to any successor of XXX;
DURATION, MODIFICATION AND TERMINATION A. Effective Date: The effective date of this agreement is November 11, 2023, provided that SSA reported the proposal to re-establish this matching program to the Congressional committees of jurisdiction and OMB in accordance with 5 U.S.C. § 552a(o)(2)(A) and OMB Circular A-108 (December 23, 2016), and SSA published notice of the matching program in the Federal Register in accordance with 5 U.S.C. § 552a(e)(12).
B. Duration: This agreement will be in effect for a period of 18 months.
C. Renewal: The DIBs of VA and SSA may, within 3 months prior to the expiration of this agreement, renew this agreement for a period not to exceed 12 months if VA and SSA can certify to their DIBs that:
1. The matching program will be conducted without change; and
2. VA and SSA have conducted the matching program in compliance with the original agreement. If either party does not want to continue this program, it must notify the other agency of its intention not to continue at least 90 days before the end of the period of the agreement.
Survival; Termination The representations, warranties, and covenants of the respective parties shall survive the Closing Date and the consummation of the transactions herein contemplated for a period of two years.
Amendments, Suspension and Termination To the extent permitted by the Plan, this Agreement may be wholly or partially amended or otherwise modified, suspended or terminated at any time or from time to time by the Board or the Committee. Except as provided in the preceding sentence, this Agreement cannot be modified, altered or amended, except by an agreement, in writing, signed by both the Partnership and the Participant.
Term, Termination and Suspension 18.1 This Agreement shall be effective from the Effective Date for the Term. The Service shall commence on the Commencement Date and continue until the Completion Date, whereupon this Agreement shall expire unless terminated earlier in accordance with its terms.
18.2 You shall not commence any additional service in the event of notification of termination of this Agreement, however, in the event that service is provided to us beyond the Completion Date, the terms and conditions of this Agreement shall continue on a day-to-day basis terminable without cause upon twenty-four (24) hours prior written notice by either party to the other.
18.3 Either party may terminate a Service or this Agreement, in part or in whole, during the Term upon prior written notice without cause in accordance with the termination notice period as set out in Schedule 1.
18.4 We may terminate this Agreement at any time based upon your default of your obligations under this Agreement. We, in our sole discretion, may provide you with a notice to cure (“Cure Notice”) the breach that would otherwise amount to a basis to terminate this Agreement as a result of your failure to fulfill your obligations hereunder. You shall respond to any such Cure Notice within a reasonable time or within such time as provided therein, and you shall either cure the specified breach or provide assurances to cure the same which we, in our sole discretion, deem adequate.
18.5 Either party may terminate this Agreement immediately, if the other party:
(a) commits an irremediable breach; or
(b) is subject to a change of control or chooses to discontinue its business; or
(c) if the other party has a lack of funding or becomes or is deemed insolvent; or
(d) if the other party’s performance is affected by a force majeure event which lasts seven (7) days or more.
18.6 In the event of termination of this Agreement, all Fees then due and payable shall be paid to you.
18.7 Upon expiry or termination of this Agreement, you shall return all Government property or information or you shall irretrievably delete, as commercially practicable as possible, all Confidential Information, stored in any way using any device or application and all matter derived from such sources which is in your possession, custody or power and provide a signed statement that you have fully complied with your obligations under this section, save for any back-up required by law or as required in accordance with your record retention policy.
18.8 Upon expiry or termination of this Agreement, you shall provide us with all such assistance as may be reasonably necessary in order to end the relationship in a manner which causes the least inconvenience to us including assisting with the transfer of Data.
18.9 We may temporarily suspend a Service hereunder and shall confirm such instruction in writing to you.
18.10 Upon any such suspension, we shall pay all Fees and Expenses up until the time of such suspension of a Service. If, following suspension of a Service, there is no resumption within six (6) months, this Agreement may be terminated by you, and us shall make a payment of all outstanding Fees and Expenses in accordance with this Agreement if such amounts are due.
18.11 We may issue a written order to resume the provision of the Service within six (6) months of suspension in accordance with the terms and conditions of this Agreement.
18.12 The rights arising under this termination section represent your sole remedy and excludes common law rights to terminate and claim damages for any Loss you may suffer under this Agreement.
