Process for Adjusting Rebuilding Plan Sample Clauses

Process for Adjusting Rebuilding Plan. Where future amendments to the Rebuilding Plan are required by the foregoing factors or more generally by infeasibility or other circumstances, the Authority and Developer will work together to develop changes that accomplish the original goals set forth in the Rebuilding Plan (including its goal of achieving 479 replacement public housing untis) to the maximum extent reasonably feasible given available resources. A Mixed-Finance Proposal approved by HUD shall (provided it was prepared by or approved by the Developer prior to submission by, and approved or submitted by the Authority) automatically be deemed an amendment to the Rebuilding Plan with respect to the Phase to which it applies. The Authority's approval of any update to the Rebuilding Plan will confirm the Authority's commitment in principal of any Authority Funds or other resources ascribed to it, will confirm the Authority's approval of the proposed actions by the Developer described in it and will permit the Developer, lenders, investors and other third parties to proceed to finalize plans in reliance upon such approval. Any update to the Rebuilding Plan shall be incorporated in this Agreement as if attached in full.
Sample 1
AutoNDA by SimpleDocs

Related to Process for Adjusting Rebuilding Plan

  • Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.

  • Monitoring and Adjusting Forecasts Verizon will, for ninety (90) days, monitor traffic on each trunk group that it establishes at ECI’s suggestion or request pursuant to the procedures identified in Section 14.2 of this Attachment. At the end of such ninety-(90) day period, Verizon may disconnect trunks that, based on reasonable engineering criteria and capacity constraints, are not warranted by the actual traffic volume experienced. If, after such initial ninety (90) day period for a trunk group, Verizon determines that any trunks in the trunk group in excess of two (2) DS1s are not warranted by actual traffic volumes (considering engineering criteria for busy Centium Call Second (Hundred Call Second) and blocking percentages), then Verizon may hold ECI financially responsible for the excess facilities and disconnect such excess facilities.

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • Educator Plans: Improvement Plan A) An Improvement Plan is for those Educators with PTS whose overall rating is unsatisfactory.

  • PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:

  • Annual Work Plans (a) The Recipient shall prepare in accordance with guidelines acceptable to the Association and furnish to the Association not later than March 31 in each calendar year, a proposed annual work plan and budget for the Project for the following fiscal year of the Recipient, of such scope and in such detail as the Association shall reasonably request.

  • Contract Term Adjustment “Contract Term Adjustment” means adjustment only as provided for in the three circumstances described in this Subsection. Under these circumstances, the contract term shall be adjusted in writing to include additional calendar days in one or more Normal Operating Seasons equal to the actual time lost, except as limited by paragraph (b) in this Subsection. To qualify for such adjustment, Purchaser shall give written notice of the lost time not later than 30 days after end of Normal Operating Season in which time was lost and at least 10 days before Termination Date. Contracting Officer shall make prompt written acknowledgment of such notice, indicating concurrence with the number of days in the notice or the number of days Forest Service considers as qualifying for the adjustment. Lost portions of days shall be disregarded in computing time lost. The three circumstances qualifying for a Contract Term Adjustment are:

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

  • Other Change Orders For Change Orders involving the following situations that would materially affect the completion of the Work by lengthening the critical path of the Construction Progress Schedule, the Design Professional shall determine the appropriate number of days and thereby extend the Material Completion and Occupancy Date. The Contractor expressly agrees that the Contractor’s sole monetary remedy for such extensions of Contract Time shall be calculated at the daily rate established for Time Dependent Overhead Costs in the Contract.

  • Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.

Time is Money Join Law Insider Premium to draft better contracts faster.