FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such 9.9.2 Neither the final payment nor the remaining retained percentage shall become due until the Contractor submits to the Architect (1) an affidavit that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the State or its property might in any way be responsible, have been paid or otherwise satisfied; (2) consent of surety, if any, to final payment; (3) Other data establishing payment or satisfaction of all such obligations, including, but not limited to, receipts, releases, or other supporting documentation. and (4) final waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the State. If any Subcontractor refuses to furnish a release or waiver required by the State, the Contractor may furnish a bond satisfactory to the State to indemnify him against any such lien. If any such lien remains unsatisfied after all payments are made, the Contractor shall refund to the State all moneys that the latter may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees. 9.9.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by the issuance of Change Orders affecting final completion, and the Architect so confirms, the State shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than the retainage stipulated in the Contract Documents, and if bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. 9.9.4 The making of final payment shall constitute a waiver of all claims by the State except those arising from: (a) unsettled liens, (b) faulty or defective Work appearing after Substantial Completion, (c) failure of the Work to comply with the requirements of the Contract Documents, or (d) terms of any special warranties required by the Contract Documents. 9.9.5 The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and identified by the Contractor as unsettled at the time of the final Application for Payment.
Payment of GST Payment of the additional amount will be made at the same time as payment for the supply is required to be made under this Contract.
Final Payment All items or Automated Clearing House (ACH) transfers credited to your account are provisional until we receive final payment. If final payment is not received, we may charge your account for the amount of such items or ACH transfers and impose a return item charge on your account. Any collection fees we incur may be charged to your account. We reserve the right to refuse or return any item or funds transfer.
Additional Fee on Late Payments For any payments thirty (30) calendar days or more overdue under this Agreement, Registry Operator shall pay an additional fee on late payments at the rate of 1.5% per month or, if less, the maximum rate permitted by applicable law.
Rollovers of Settlement Payments From Bankrupt Airlines If you are a qualified airline employee who has received a qualified airline settlement payment from a commercial airline carrier under the approval of an order of a federal bankruptcy court in a case filed after September 11, 2001, and before January 1, 2007, you are allowed to roll over any portion of the proceeds into your Xxxx XXX within 180 days after receipt of such amount, or by a later date if extended by federal law. For further detailed information and effective dates you may obtain IRS Publication 590-A, Contributions to Individual Retirement Arrangements (IRAs), from the IRS or refer to the IRS website at xxx.xxx.xxx.
Payment Scheduling The earliest possible Scheduled Payment Date for each Xxxxxx will be designated within the portion of the Site through which the Service is offered when you are scheduling the payment. Therefore, the Service will not permit you to select a Scheduled Payment Date less than the earliest possible Scheduled Payment Date designated for each Xxxxxx. When scheduling payments you must select a Scheduled Payment Date that is no later than the actual Due Date reflected on your Xxxxxx statement unless the Due Date falls on a non-Business Day. If the actual Due Date falls on a non-Business Day, you must select a Scheduled Payment Date that is at least one (1) Business Day before the actual Due Date. Scheduled Payment Dates must be prior to any late date or grace period. Depending on the method of payment, your Eligible Transaction Account may be debited prior to the Scheduled Payment Date. For example, if the selected method of payment is a draft, the draft arrives earlier than the Scheduled Payment Date due to expedited delivery by the postal service, and the Xxxxxx immediately deposits the draft, your Eligible Transaction Account may be debited earlier than the Scheduled Payment Date.
Payment of Settlement Amount (1) Within thirty (30) days of the Execution Date, the Settling Defendants shall pay the Settlement Amount to Siskinds LLP for deposit into the Trust Account. The Settlement Amount shall be converted into Canadian currency upon deposit into the Trust Account. (2) The Settling Defendants shall deposit the Settlement Amount into the Trust Account by wire transfer. Siskinds LLP shall provide the necessary wire transfer information to Counsel for the Settling Defendants with reasonable advance notice so that the Settling Defendants have a reasonable period of time to comply with section 3.1(1) of this Settlement Agreement. (3) The Settlement Amount and other consideration to be provided in accordance with the terms of this Settlement Agreement shall be provided in full satisfaction of the Released Claims against the Releasees. (4) The Settlement Amount shall be all-inclusive of all amounts, including without limitation, interest, costs, Class Counsel Fees and Class Counsel Disbursements. (5) The Releasees shall have no obligation to pay any amount in addition to the Settlement Amount, for any reason, pursuant to or in furtherance of this Settlement Agreement or the Proceedings or any Other Actions. (6) Once a Claims Administrator has been appointed, Siskinds LLP shall transfer control of the Trust Account to the Claims Administrator. (7) Siskinds LLP and the Claims Administrator shall maintain the Trust Account as provided for in this Settlement Agreement. While in control of the Trust Account, Siskinds LLP and the Claims Administrator shall not pay out all or part of the monies in the Trust Account, except in accordance with this Settlement Agreement, or in accordance with an order of the Courts obtained after notice to the Parties.
Treatment of Unallowable Costs Previously Submitted for Payment Mallinckrodt further agrees that within 120 days of the Effective Date of this Agreement it shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this Paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Mallinckrodt or any of its subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Mallinckrodt agrees that the United States, at a minimum, shall be entitled to recoup from Mallinckrodt any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Mallinckrodt or any of its subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this Paragraph) on Mallinckrodt or any of its subsidiaries or affiliates’ cost reports, cost statements, or information reports.
Expense Accrual and Payment Services (1) For each valuation date, calculate the expense accrual amounts as directed by the Trust as to methodology, rate or dollar amount. (2) Process and record payments for Fund expenses upon receipt of written authorization from the Trust. (3) Account for Fund expenditures and maintain expense accrual balances at the level of accounting detail, as agreed upon by USBFS and the Trust. (4) Provide expense accrual and payment reporting.
Termination Procedures and Compensation During Dispute 7.1. After a Change in Control and during the term of this Agreement, any purported termination of the Executive's employment (other than by reason of death) shall be communicated by written Notice of Termination from one party hereto to the other party hereto in accordance with Section 10 hereof. For purposes of this Agreement, a "Notice of Termination" shall mean a notice which shall indicate the specific termination provision in this Agreement relied upon and shall set forth in reasonable detail the facts and circumstances claimed to provide a basis for termination of the Executive's employment under the provision so indicated. Further, a Notice of Termination for Cause issued by the Company is required to include a copy of a resolution duly adopted by the affirmative vote of not less than three-quarters (3/4) of the entire membership of the Board at a meeting of the Board which was called and held for the purpose of considering such termination (after reasonable notice to the Executive and an opportunity for the Executive, together with the Executive's Counsel, to be heard before the Board) finding that, in the good faith opinion of the Board, the Executive engaged in conduct set forth in clause (i) or (ii) of the definition of Cause herein, and specifying the particulars thereof in detail.