Requirement to Work Reasonable Overtime The Employer may require any Employee to work reasonable overtime at overtime rates and such Employee shall work overtime in accordance with such requirement.
Supervisors Working (a) The Employer agrees that the function of supervisors is the supervision of Employees and not the performance of the work of the employees they supervise. Accordingly, the Employer agrees that supervisors or other employees of the Employer who are not members of the bargaining unit shall not perform any bargaining unit work, except to train employees or demonstrate safety, or as otherwise provided in the applicable Supplement, Rider or Addendum. However, in the case of Acts of God, supervisors shall comply with the procedures in subsections (b) and (c) and may only perform bargaining unit work until bargaining unit employees are available. The Employer shall make every reasonable effort to maintain a sufficient workforce to staff its operations with bargaining unit employees. The Employer also agrees that supervisors or other employees of the Employer who are not members of the bargaining unit shall not perform bargaining unit work in preparing the work areas before the start of the Employer’s hub, preload or reload operation, nor shall the Employer send any bargaining unit employee home and then have such employee’s work performed by a supervisor or other employees of the Employer who are not a member of the bargaining unit. (b) When additional employees are necessary to complete the Employer’s operations on any shift or within any classification, the supervisor shall exhaust all established local practices to first use bargaining unit employees including where applicable, double shifting, early call-in, and overtime. (c) If there is no established local practice, the following shall apply with regard to inside work. Within each building, each operation will maintain appropriate list(s), by seniority, of those part-time employees requesting coverage work. It will be the employees’ responsibility to sign up on the appropriate list. The Company shall post such lists and employees who are interested in adding their names to the lists shall do so on the first working day of each month. It will be the employee’s responsibility to make sure his/her their contact information is correct. Employees who are unavailable to work on three (3) separate occasions within a calendar month shall have their names removed from the coverage list. Those employees shall be eligible to re-sign the list the following month. When coverage work is available, the Company will use the appropriate list to fill the required positions, and such employees will work as assigned. The employee must be qualified for the available work and double shift employees shall have seniority among themselves. No employee is allowed to work more than two (2) shifts in any twenty-four (24) hour period. Local call verification practices and procedures shall remain in place. Nothing contained in this Section shall change existing practices or procedures covering full-time work. (d) If it is determined at any step of the grievance and/or arbitration procedure that this Section, or a “supervisor working” provision in a Supplement, Rider or Addendum, has been violated, the aggrieved employee will be paid as follows: (i) if the actual hours worked by the supervisor amounts to two (2) hours or less, the aggrieved employee will be paid for the actual hours worked by the supervisor at the rate of double time the employee’s rate of pay at the time of the incident; or (ii) if the supervisor works more than two (2) hours, the aggrieved employee shall be paid four (4) hours at straight time or actual hours worked at double time the employee’s rate of pay at the time of the incident, whichever is greater. If no aggrieved employee can be identified, the payment will be made to the grievant. Such remedy shall be in addition to any other remedies sought by the Union in the appropriate grievance procedure. If a Supplement, Rider, or Addendum does not have a provision requiring notice to the xxxxxxx when a supervisor works the following shall be incorporated: “In the event a supervisor does perform bargaining unit work, the Employer shall notify the appropriate shop xxxxxxx as soon as possible.” In the event that any individual supervisor is found to be in violation of the first paragraph of this Subsection three (3) times in any nine (9) month rolling period, the grievance shall be paid at triple quadruple time the employee’s rate of pay for the hours specified in the first paragraph of this subsection.
Construction Standards The Developer shall construct the Subdivision in accordance with the Subdivision Plan, as approved by the Planning Commission, and if applicable, the requirements of the Design Review Committee, and in accordance with the requirements of (a) the Millington Subdivision Regulations; (b) standards and specifications contained in “Local Public Works Standard, and Specifications”, as amended to include specific requirements for construction in Millington, TN; (c) the Building Code (as adopted by Shelby County); (d) the Fire Code (as adopted by Shelby County); (e) the Millington Zoning Ordinance; and (f) the applicable Ordinances of the City. Items (a) through (f) are hereby made a part of this Agreement by reference and are hereinafter referred to collectively as the “Codes”. References herein to the Codes are to those in effect on the Effective Date unless amendments are hereafter made which apply to all improvements or subdivisions regardless of their date of commencement and/or completion of construction. The Conditions of Approval established by the Planning Commission, and, as applicable, the Design Review Committee (any or all of which as may have been modified by the Board of Mayor and Aldermen) are set forth in Exhibit “A” to this Agreement and are incorporated herein by reference and made a part hereof.
Common Areas - Rules and Regulations Lessor or such other person(s) as Lessor may appoint shall have the exclusive control and management of the Common Areas and shall have the right, from time to time, to establish, modify, amend and enforce reasonable rules and regulations (“Rules and Regulations”) for the management, safety, care, and cleanliness of the grounds, the parking and unloading of vehicles and the preservation of good order, as well as for the convenience of other occupants or tenants of the Building and the Project and their invitees. Lessee agrees to abide by and conform to all such Rules and Regulations, and to cause its employees, suppliers, shippers, customers, contractors and invitees to so abide and conform. Lessor shall not be responsible to Lessee for the non-compliance with said Rules and Regulations by other tenants of the Project.
CONTRACT WORK HOURS AND SAFETY STANDARDS As per the Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708), where applicable, all Customer Purchase Orders in excess of ,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each contractor must be required to compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
PROFESSIONAL IMPROVEMENT The parties’ support the principle of continuing training of teachers, participation by teachers in professional organizations in the areas of their specialization, leaves for work on advanced degrees or special studies, foreign travel and participation in community educational projects.
Overtime Scheduling 1. Each employee interested in working overtime may volunteer by requesting, in writing, to be added to the voluntary overtime list within his/her building and/or the district-wide voluntary overtime list. They will also indicate whether they wish to work during their vacation period. Such written request to be added to or deleted from the overtime lists may be made at any time; however, if the employee is requesting to be deleted from the list(s), he/she shall not be allowed to rejoin the list(s) for a ninety (90) calendar day period. Such lists shall be maintained on a yearly basis, from September 1st to August 31st of each year. The employer will serve notice to the employees, by a memo into each work area, that overtime lists are being formulated, by August 15th of each year. 2. The list will be compiled for September with the volunteers listed in seniority order. Overtime shall be rotated among volunteers. The rotation shall be continuous through the year until a new list is compiled the following September. If an employee volunteers who was not on the list he/she shall be placed on the list according to his/her seniority and he/she shall be eligible to work overtime in accordance with the normal rotation. 3. To the extent possible, employees will be notified at least four (4) hours prior to the end of the shift of any overtime for that day and by noon on Friday for any Saturday overtime. Any employee who has volunteered to work overtime and is notified in accordance with this paragraph shall be obligated to work the overtime hours in their building unless excused by the supervisor. 4. Overtime assignments will be on a rotating schedule among the qualified employees within each classification who have expressly volunteered for such overtime work. The employer’s obligation to rotate overtime shall be satisfied by calling employees who are working at the time the overtime determination is made (i.e., not on vacation or other leave of absence) in seniority order and offering them the opportunity to work. 5. If there are insufficient volunteers available for any specific assignment, the employer may require the least senior employee in the division to perform the work. 6. Substantiated errors made in the rotation of overtime (Article XIII Section G.4) will be corrected on the basis of offering the by-passed employee an amount of overtime equal to the time lost due to the error of assignment. Depending on the number of hours involved, it is possible that this may take more than (1) one overtime offer/assignment. Acceptance of the compensatory overtime will not change the employees spot in the overtime rotation, thus the employee will remain eligible for overtime in the same rotation as before the error. The compensatory overtime will not be offered at such a time or in such a manner that would purposefully cause inconvenience or inability to the effected employee to comply. In the event the employee declines the offered overtime work, the employee shall forfeit any future claim to the overtime hours in dispute.
Architect Engineer shall provide assistance to Owner through the commissioning consultant/agent for the purpose of advising and counseling Owner’s personnel in the usage, operation and maintenance of the building mechanical, electrical, and plumbing systems.
Contract Work Hours and Safety Standards Act The following clauses apply to any Federal-aid construction contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses shall be inserted in addition to the clauses required by 29 CFR 5.5(a) or 29 CFR 4.6. As used in this paragraph, the terms laborers and mechanics include watchmen and guards.
