Ombudsman A Vendor Ombudsman has been established within the Department of Financial Services. The duties of this office are found in section 215.422, F.S., which include disseminating information relative to prompt payment and assisting contractors in receiving their payments in a timely manner from a Customer. The Vendor Ombudsman may be contacted at (000) 000-0000.
Homework In addition to regular attendance at scheduled classes, each student will be required to devote additional time each week outside the classroom to study and work on assignments.
Emergency Situations If the condition is an emergency, this will be communicated to the Contractor with the request that corrections are to be accomplished immediately. The Contractor shall respond to the notice in emergency situations within twenty-four hours. If the Contractor fails to respond within this time limit, the Owner may correct the defect and charge the Contractor for the Work. If it is determined the complaint is not the responsibility of the Contractor, the Contractor shall be promptly paid for the cost of the corrective work. The Contractor shall give notice in writing to the Owner when corrections have been completed.
Emergency Situation In the event of an emergency situation beyond our reasonable control, such as an "act of God," war, fire, or natural disaster, services involving your account could be available only in a modified or reduced form or could be entirely unavailable. Unless expressly prohibited by applicable law, you agree that we will have no liability to you for such modification, reduction, or unavailability of services caused by an emergency situation.
Litigation Assistance Except when it would constitute a direct conflict of interest for BA, BA will make itself available to assist CE in any administrative or judicial proceeding by testifying as witness as to an alleged violation of HIPAA, the HITECH Act, the Privacy or Security Rule, or other law relating to security or privacy.
Virus Management DST shall maintain a malware protection program designed to deter malware infections, detect the presence of malware within DST environment.
PROTECTION OF TEACHERS A. The Board recognizes its responsibility to give reasonable support and assistance to Teachers for the maintenance of control and discipline in the classroom. Each Teacher, however, bears the primary responsibility for maintaining proper control and discipline in the classroom.
B. As permitted by Section 1309 of the Revised School Code, a Teacher may temporarily exclude a student from one (1) class when the nature of the offense, the persistence of the misbehavior, or the disruptive effect of the violation makes the continued presence of the student in the classroom intolerable. In such cases, the Teacher will furnish the Principal with written particulars of the incident as promptly as teaching obligations allow. Upon request of the Principal, the Teacher shall notify the student’s parent of the nature of the offense. If the Principal determines the need for a meeting with the student’s parent, the Teacher shall attend that meeting.
C. The Teachers recognize that all disciplinary actions and methods invoked by them shall be reasonable and just.
D. Any assault or threatened assault upon a Teacher, resulting from his/her position as a Teacher, shall be promptly reported to the Building Principal by the Teacher or representative. The Board shall provide legal counsel, if requested in writing by the Teacher, to advise the Teacher of the Teacher’s rights and obligations as to such assault. The Board will provide reasonable assistance to the Teacher in working with law enforcement and judicial authorities, unless such counsel and assistance are provided through the Association.
E. If a Teacher is complained against or sued as a result of any reasonable action as defined by a court of law and taken by the Teacher while in the scope of his/her employment with the District, the Board shall provide legal counsel and render all reasonable assistance, as appropriate, to the Teacher in his/her defense when requested in writing by the Teacher. This section shall only require the provision of legal counsel and shall not be interpreted to interfere with the Board’s right to exercise supervision and control, including discharge of the Teacher. If a final decision issued by a court or administrative agency indicates the Teacher’s liability for this action, all costs of assistance rendered by the District to the Teacher pursuant to this paragraph and not covered by the District’s insurance carrier, shall be reimbursed by the Teacher.
F. Except for disciplinary suspension or discharge, or for incarceration, any work time lost by a Teacher in connection with an incident identified in Article 9.D, not compensable under Workers’ Compensation, shall not be charged against the Teacher, unless the Teacher is adjudged liable by an agency or court of competent jurisdiction. When Workers’ Compensation is paid, the Board shall pay the difference between that sum and the Teacher’s regular salary, but not to exceed the current year’s contract. No deduction of leave shall be made under these circumstances.
G. In case of an assault by a student(s) on a Teacher acting in the line of duty, or other action taken by or against a Teacher in the line of duty, causing damage to the Teacher’s personal property, including clothing, the Board shall make an equitable financial settlement for such loss with the Teacher involved.
H. Any complaint directed toward a Teacher shall be promptly called to the Teacher’s attention unless otherwise prohibited by law. This requirement shall not prevent the Supervisor from screening out xxxxx gripes.
I. Teachers shall be expected to exercise reasonable care as to the safety of students and property.
WORKFORCE REDUCTION SECTION 1 Layoffs
(A) When employees are to be laid off as defined in the F.S., the state shall implement such layoff in the following manner:
(1) The competitive area for the bargaining unit shall be statewide unless the Department and PBA agree otherwise.
(2) Layoff shall be by class or occupational level within the Security Services Bargaining Unit.
(3) An employee who has not attained permanent status in his current position may be laid off without applying the provision for retention rights.
(4) No employee with permanent status in his current position shall be laid off while an employee who does not hold permanent status in his current position is serving in that class or level unless the permanent employee does not elect to exercise his retention rights or does not meet the selective competition criteria.
(5) All employees who have permanent status in their current positions shall be ranked on a layoff list for the affected class or level based on the total retention points derived as follows:
(a) Length of service retention points shall be based on one point for each month of continuous service in a Career Service position.
1. An employee who resigns from one Career Service position to accept employment in another Career Service position is not considered to have a break in service.
2. An employee who has been laid off and is reemployed within one year from the date of the layoff shall not be considered to have a break in service.
3. Moving from Career Service to Selected Exempt Service or Senior Management Service and back to Career Service does not constitute a break in service unless the employee’s break in service is more than 31 calendar days. Only time spent in the Career Service is counted in calculating retention points.
(b) Retention points deducted for performance not meeting performance standards or work expectations defined for the position shall be based on the five years immediately prior to the agency’s established cutoff date. Five points shall be deducted for each month an employee has a rating below performance expectations.
(6) The layoff list shall be prepared by totaling retention points. Employees eligible for veterans’ preference pursuant to section 295.07(1)(a) or (b), F.S., shall have 15 percent added to their total retention points, those eligible pursuant to section 295.07(1)(c), (d), or (e), F.S., shall have 10 percent added to their total retention points, and those eligible pursuant to section 295.071(1)(f), or (g), F.S., shall have five percent added to their total retention points.
(7) The employee with the highest total retention points is placed at the top of the list, and the employee with the lowest retention points is placed at the bottom of the list.
(8) The employee at the top of the list shall bump the employee at the bottom of the list. The next highest employee on the list and the remaining employees shall be handled in the same manner until the total number of filled positions in the class to be abolished is complete.
(9) Should two or more employees have the same combined total of retention points, the order of layoff shall be determined by giving preference for retention in the following sequence:
(a) The employee with the longest service in the affected class.
(b) The employee with the longest continuous service in the Career Service.
(c) The employee who is entitled to veterans’ preference pursuant to section 295.07(1), F.S.
(10) An employee who has permanent status in his current position and is to be laid off shall be given at least 14 calendar days’ notice of such layoff or two weeks’ pay, or a combination of days of notice and pay. Any payment will be made at the employee’s current hourly base rate of pay. The notice of layoff shall be in writing and sent to the employee by certified mail, return receipt requested. Within seven calendar days after receiving the notice of layoff, the employee shall have the right to request, in writing, a lateral action, reassignment, or demotion within the competitive area in lieu of layoff to a position in a class within the bargaining unit in which the employee held permanent status, or to a position in a class at the level of or below the class in the bargaining unit in which the employee held permanent status.
(11) An employee’s request for lateral action, reassignment, or demotion shall be granted unless it would cause the layoff of another employee who possesses a greater total of retention points.
(12) An employee adversely affected as a result of another employee having a greater number of retention points shall have the same right of lateral action, reassignment or demotion under the same procedure as provided in this section.
(13) If an employee requests a lateral action, reassignment, or demotion in lieu of layoff, the same formula and criteria for establishing retention points for that class shall be used as prescribed in this section.
(B) If there is to be a layoff of employees, the state shall take all reasonable steps to place any adversely affected employees in existing vacancies for which they are qualified.
(C) If work performed by employees in this unit is to be performed by non-state employees, the state agrees to encourage the employing entity to consider any adversely affected unit employees for employment in its organization if the state has been unable to place the employees in other positions within the State Personnel System.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Termination of Therapy Therapist reserves the right to terminate therapy at his/her discretion. Reasons for termination include, but are not limited to, untimely payment of fees, failure to comply with treatment recommendations, conflicts of interest, failure to participate in therapy, Patient needs are outside of Therapist’s scope of competence or practice, or Patient is not making adequate progress in therapy. Patient has the right to terminate therapy at his/her discretion. Upon either party’s decision to terminate therapy, Therapist will generally recommend that Patient participate in at least one, or possibly more, termination sessions. These sessions are intended to facilitate a positive termination experience and give both parties an opportunity to reflect on the work that has been done. Therapist will also attempt to ensure a smooth transition to another therapist by offering referrals to Patient.
