Change Management BellSouth provides a collaborative process for change management of the electronic interfaces through the Change Control Process (CCP). Guidelines for this process are set forth in the CCP document as amended from time to time during this Agreement. The CCP document may be accessed via the Internet at xxxx://xxx.xxxxxxxxxxxxxxx.xxxxxxxxx.xxx.
Case Management Prompt resolution of any dispute is important to both parties; and the parties agree that the arbitration of any dispute shall be conducted expeditiously. The arbitrators are instructed and directed to assume case management initiative and control over the arbitration process (including scheduling of events, pre-hearing discovery and activities, and the conduct of the hearing), in order to complete the arbitration as expeditiously as is reasonably practical for obtaining a just resolution of the dispute.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Patch Management All workstations, laptops and other systems that process and/or 20 store PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or 21 transmits on behalf of COUNTY must have critical security patches applied, with system reboot if 22 necessary. There must be a documented patch management process which determines installation 23 timeframe based on risk assessment and vendor recommendations. At a maximum, all applicable 24 patches must be installed within thirty (30) calendar or business days of vendor release. Applications 25 and systems that cannot be patched due to operational reasons must have compensatory controls 26 implemented to minimize risk, where possible.
Traffic Management 9.2.1 During the Operating Period, Developer shall be responsible for the general management of traffic on the Project. Developer shall manage traffic so as to preserve and protect safety of traffic on the Project and Related Transportation Facilities and, to the maximum extent practicable, to avoid disruption, interruption or other adverse effects on traffic flow, throughput or level of service on the Project and Related Transportation Facilities. Developer shall conduct traffic management in accordance with all applicable Technical Provisions, Technical Documents, Laws and Governmental Approvals, and in accordance with the Traffic Management Plan.
9.2.2 Developer shall prepare and submit to TxDOT and the Independent Engineer for TxDOT approval a Traffic Management Plan for managing traffic on the Project and Related Transportation Facilities after the commencement of traffic operations on any portion of the Project, addressing (a) orderly and safe movement and diversion of traffic on Related Transportation Facilities during Project construction, (b) orderly and safe movement of traffic on the Project and (c) orderly and safe diversion of traffic on the Project and Related Transportation Facilities necessary in connection with field maintenance and repair work or Renewal Work or in response to Incidents, Emergencies and lane closures. Developer shall prepare the Traffic Management Plan according to the schedule set forth in the Technical Provisions. The Traffic Management Plan shall comply with the Technical Provisions and Technical Documents concerning traffic management and traffic operations. Developer shall carry out all traffic management during the Term in accordance with the approved Traffic Management Plan.
9.2.3 Developer shall implement the Traffic Management Plan to promote safe and efficient operation of the Project and Related Transportation Facilities at all times during the course of any construction or operation of the Project and during the Utility Adjustment Work.
9.2.4 TxDOT shall have at all times, without obligation or liability to Developer, the right
9.2.4.1 Issue Directive Letters to Developer regarding traffic management
9.2.4.2 Provide on the Project, via message signs or other means consistent with Good Industry Practice, non-Discriminatory traveler and driver information, and other public information (e.g. amber alerts), provided that the means to disseminate such information does not materially interfere with the functioning of the ETCS.
Disease Management If you have a chronic condition such as asthma, coronary heart disease, diabetes, congestive heart failure, and/or chronic obstructive pulmonary disease, we’re here to help. Our tools and information can help you manage your condition and improve your health. You may also be eligible to receive help through our care coordination program. This voluntary program is available at no additional cost you. To learn more about disease management, please call (000) 000-0000 or 0-000-000-0000. Our entire contract with you consists of this agreement and our contract with your employer. Your ID card will identify you as a member when you receive the healthcare services covered under this agreement. By presenting your ID card to receive covered healthcare services, you are agreeing to abide by the rules and obligations of this agreement. Your eligibility for benefits is determined under the provisions of this agreement. Your right to appeal and take action is described in Appeals in Section 5. This agreement describes the benefits, exclusions, conditions and limitations provided under your plan. It shall be construed under and shall be governed by the applicable laws and regulations of the State of Rhode Island and federal law as amended from time to time. It replaces any agreement previously issued to you. If this agreement changes, an amendment or new agreement will be provided.
Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.
Office Visits (other than Preventive Care Services) This plan covers office and clinic visits to diagnose or treat a sickness or injury. Office visit copayments differ depending on the type of provider you see. This plan covers physician visits in your home if you have an injury or illness that: • confines you to your home; or • requires special transportation; and • because of this injury or illness, you are physically unable to travel to the provider’s
International Olympic Committee; International Red Cross and Red Crescent Movement As instructed from time to time by ICANN, the names (including their IDN variants, where applicable) relating to the International Olympic Committee, International Red Cross and Red Crescent Movement listed at xxxx://xxx.xxxxx.xxx/en/resources/registries/reserved shall be withheld from registration or allocated to Registry Operator at the second level within the TLD. Additional International Olympic Committee, International Red Cross and Red Crescent Movement names (including their IDN variants) may be added to the list upon ten (10) calendar days notice from ICANN to Registry Operator. Such names may not be activated in the DNS, and may not be released for registration to any person or entity other than Registry Operator. Upon conclusion of Registry Operator’s designation as operator of the registry for the TLD, all such names withheld from registration or allocated to Registry Operator shall be transferred as specified by ICANN. Registry Operator may self-‐allocate and renew such names without use of an ICANN accredited registrar, which will not be considered Transactions for purposes of Section 6.1 of the Agreement.
Program Management 1.1.01 Implement and operate an Immunization Program as a Responsible Entity
1.1.02 Identify at least one individual to act as the program contact in the following areas:
1. Immunization Program Manager;
