QUANTITY CHANGES PRIOR TO AWARD The Commissioner reserves the right, at any time prior to the award of a specific quantity Contract, to alter in good faith the quantities listed in the Bid Specifications. In the event such right is exercised, the lowest responsible Bidder meeting Bid Specifications will be advised of the revised quantities and afforded an opportunity to extend or reduce its Bid price in relation to the changed quantities. Refusal by the low Bidder to so extend or reduce its Bid price may result in the rejection of its Bid and the award of such Contract to the lowest responsible Bidder who accepts the revised qualifications.
Price Changes Applicable only to Term Contracts If this is a term contract for commodities or services, the following provisions apply.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
CALCULATION OF LOSS FOR SHORT SALE LOANS No Preceeding Loan Mod under Loss Share 1 Shared-Loss Month: May-09 2 Loan # 58776 3 RO # 542 4 Interest paid-to-date 7/31/08 5 Short Payoff Date 4/17/09 6 Note Interest rate 7.750% 7 Owner occupied? Yes If so: 8 Borrower current gross annual income 38,500 9 Estimated NPV of loan mod 200,000 10 Most recent BPO 380,000 11 Most recent BPO date 1/31/06 Short-Sale Loss calculation 12 Loan Principal balance 375,000 13 Accrued interest, limited to 90 days 7,266 14 Attorney's fees 0 15 Tax and insurance advances 0 16 3rd party fees due 2,800 17 Incentive to borrower 2,000 18 Gross balance recoverable by Purchaser 387,066 19 Amount accepted in Short-Sale 255,000 20 Hazard Insurance 0 21 Mortgage Insurance 0 22 Total Cash Recovery 255,000 23 Loss Amount 132,066 Exhibit 2c(2)
Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
Unit Weekend Schedule A unit weekend schedule may be developed in order to meet the Hospital’s need for weekend staff, and individual nurses’ preference for a weekend work schedule. A unit weekend schedule is defined as a schedule in which a full-time nurse works a weekly average of thirty (30) hours and is paid for 37.5 hours at her or his regular straight time hourly rate. The schedule must include two 11.25 hour tours, which fall within a weekend period as determined by the Hospital and the Association. A nurse working a weekend schedule will work every weekend except as provided for in the provisions below. If the Hospital and the Association agree to a unit weekend schedule, the introduction of that schedule and the manner in which the position(s) are filled, shall be determined by the local parties and recorded in the Appendix of Local Provisions. This unit schedule may be discontinued by either party with notice as determined within the Appendix of Local Provisions. The opportunity for an individual nurse to discontinue this schedule shall be resolved by the local parties:
Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract. If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.
Recovery of Schedule Delays During Last Sixty Days of Contract Time At any time during the last sixty days of the Contract Time that the Design Professional finds that the Contractor is behind schedule per the Contract Time, as amended, the Design Professional shall notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall prepare and deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.
Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price Decreases Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.
Contractor Changes and Assignment (a) The Contractor shall notify the Agency in writing:
