Recovery of Schedule Delays During Last Sixty Days of Contract Time Sample Clauses

Recovery of Schedule Delays During Last Sixty Days of Contract Time. At any time during the last sixty days of the Contract Time that the Design Professional finds that the Contractor is behind schedule per the Contract Time, as amended, the Design Professional shall notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall prepare and deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.
AutoNDA by SimpleDocs
Recovery of Schedule Delays During Last Sixty Days of Contract Time. At any time during the last sixty days of the Contract Time that the Design Professional finds that the CM/GC is behind schedule per the Contract Time, as amended, the Design Professional shall notify the CM/GC in writing. Within seven days of the date of the Design Professional's notice, the CM/GC shall prepare and deliver to the Design Professional and Owner a written plan explaining how the CM/GC intends to bring the Project back on schedule. The CM/GC's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility. Payment of Costs of Recovery of Schedule Delays. Costs attributable to recovery of schedule delays, after execution of the GMP Change Order, may be paid from the Construction Contingency.

Related to Recovery of Schedule Delays During Last Sixty Days of Contract Time

  • Recovery of Schedule Delays If the Design Professional determines that the Project is one week or more behind schedule, per the approved Overall Project Schedule, the Design Professional shall so notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.

  • Holiday Falling on a Scheduled Workday An Employee who works on a designated holiday which is a scheduled workday shall be compensated at the rate of double time for hours worked, plus a day off in lieu of the holiday; except for Christmas and New Year's when the compensation shall be at the rate of double time and one-half (2½) for hours worked, plus a day off subject to this Agreement.

  • Effective Date of Settlements ‌ Settlements reached at any step of the grievance procedure in this article, other than Clause 8.11, shall be applied retroactively to the date of the occurrence of the action or situation which gave rise to the grievance, but not prior to the effective date of the agreement in effect at the time of the occurrence or the date set by a board of arbitration.

  • Additional Procedures Applicable to High Value Accounts 1. If a Preexisting Individual Account is a High Value Account as of December 31, 2013, the Reporting [FATCA Partner] Financial Institution must complete the enhanced review procedures described in paragraph D of this section with respect to such account by December 31, 2014. If based on this review, such account is identified as a U.S. Reportable Account, the Reporting [FATCA Partner] Financial Institution must report the required information about such account with respect to 2013 and 2014 in the first report on the Account. For all subsequent years, information about the account should be reported on an annual basis.

  • Holiday Falling on a Scheduled Workday‌ An employee who works on a designated holiday which is a scheduled workday shall be compensated at the rate of double time for hours worked plus a day off in lieu of the holiday; except for Christmas and New Year's when the compensation shall be at the rate of double time and one-half for hours worked plus a day off in lieu of the holiday.

  • Five Day Work Week Schedule When working under the five (5) day work week schedule, Employees shall receive one and one-half (1.5x) times their regular rate of pay for the first two (2) hours of overtime Monday through Friday. All other overtime Monday through Friday shall be paid at double time (2x).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!