Foreign-Owned Companies in Connection with Critical Infrastructure If Texas Government Code, Section 2274.0102(a)(1) (relating to prohibition on contracts with certain foreign-owned companies in connection with critical infrastructure) is applicable to this Contract, pursuant to Government Code Section 2274.0102, Contractor certifies that neither it nor its parent company, nor any affiliate of Contractor or its parent company, is: (1) majority owned or controlled by citizens or governmental entities of China, Iran, North Korea, Russia, or any other country designated by the Governor under Government Code Section 2274.0103, or (2) headquartered in any of those countries.
CERTIFICATION REGARDING CERTAIN FOREIGN-OWNED COMPANIES IN CONNECTION WITH CRITICAL INFRASTRUCTURE (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree to the following required by Texas law as of September 1, 2021: Proposing Company is prohibited from entering into a contract or other agreement relating to critical infrastructure that would grant to the company direct or remote access to or control of critical infrastructure in this state, excluding access specifically allowed by the Proposing Company for product warranty and support purposes. Company, certifies that neither it nor its parent company nor any affiliate of company or its parent company, is (1) owned by or the majority of stock or other ownership interest of the company is held or controlled by individuals who are citizens of China, Iran, North Korea, Russia, or a designated country; (2) a company or other entity, including governmental entity, that is owned or controlled by citizens of or is directly controlled by the government of China, Iran, North Korea, Russia, or a designated country; or (3) headquartered in China, Iran, North Korea, Russia, or a designated country. For purposes of this contract, “critical infrastructure” means “a communication infrastructure system, cybersecurity system, electric grid, hazardous waste treatment system, or water treatment facility.” See Tex. Gov’t Code § 2274.0101(2) of SB 1226 (87th leg.). The company verifies and certifies that company will not grant direct or remote access to or control of critical infrastructure, except for product warranty and support purposes, to prohibited individuals, companies, or entities, including governmental entities, owned, controlled, or headquartered in China, Iran, North Korea, Russia, or a designated country, as determined by the Governor.
Change of Control; Assignment and Subcontracting Except as set forth in this Section 7.5, neither party may assign any of its rights and obligations under this Agreement without the prior written approval of the other party, which approval will not be unreasonably withheld. For purposes of this Section 7.5, a direct or indirect change of control of Registry Operator or any subcontracting arrangement that relates to any Critical Function (as identified in Section 6 of Specification 10) for the TLD (a “Material Subcontracting Arrangement”) shall be deemed an assignment. (a) Registry Operator must provide no less than thirty (30) calendar days advance notice to ICANN of any assignment or Material Subcontracting Arrangement, and any agreement to assign or subcontract any portion of the operations of the TLD (whether or not a Material Subcontracting Arrangement) must mandate compliance with all covenants, obligations and agreements by Registry Operator hereunder, and Registry Operator shall continue to be bound by such covenants, obligations and agreements. Registry Operator must also provide no less than thirty (30) calendar days advance notice to ICANN prior to the consummation of any transaction anticipated to result in a direct or indirect change of control of Registry Operator. (b) Within thirty (30) calendar days of either such notification pursuant to Section 7.5(a), ICANN may request additional information from Registry Operator establishing (i) compliance with this Agreement and (ii) that the party acquiring such control or entering into such assignment or Material Subcontracting Arrangement (in any case, the “Contracting Party”) and the ultimate parent entity of the Contracting Party meets the ICANN-‐adopted specification or policy on registry operator criteria then in effect (including with respect to financial resources and operational and technical capabilities), in which case Registry Operator must supply the requested information within fifteen (15) calendar days. (c) Registry Operator agrees that ICANN’s consent to any assignment, change of control or Material Subcontracting Arrangement will also be subject to background checks on any proposed Contracting Party (and such Contracting Party’s Affiliates). (d) If ICANN fails to expressly provide or withhold its consent to any assignment, direct or indirect change of control of Registry Operator or any Material Subcontracting Arrangement within thirty (30) calendar days of ICANN’s receipt of notice of such transaction (or, if ICANN has requested additional information from Registry Operator as set forth above, thirty (30) calendar days of the receipt of all requested written information regarding such transaction) from Registry Operator, ICANN shall be deemed to have consented to such transaction. (e) In connection with any such assignment, change of control or Material Subcontracting Arrangement, Registry Operator shall comply with the Registry Transition Process. (f) Notwithstanding the foregoing, (i) any consummated change of control shall not be voidable by ICANN; provided, however, that, if ICANN reasonably determines to withhold its consent to such transaction, ICANN may terminate this Agreement pursuant to Section 4.3(g), (ii) ICANN may assign this Agreement without the consent of Registry Operator upon approval of the ICANN Board of Directors in conjunction with a reorganization, reconstitution or re-‐incorporation of ICANN upon such assignee’s express assumption of the terms and conditions of this Agreement, (iii) Registry Operator may assign this Agreement without the consent of ICANN directly to a wholly-‐owned subsidiary of Registry Operator, or, if Registry Operator is a wholly-‐owned subsidiary, to its direct parent or to another wholly-‐owned subsidiary of its direct parent, upon such subsidiary’s or parent’s, as applicable, express assumption of the terms and conditions of this Agreement, and (iv) ICANN shall be deemed to have consented to any assignment, Material Subcontracting Arrangement or change of control transaction in which the Contracting Party is an existing operator of a generic top-‐level domain pursuant to a registry agreement between such Contracting Party and ICANN (provided that such Contracting Party is then in compliance with the terms and conditions of such registry agreement in all material respects), unless ICANN provides to Registry Operator a written objection to such transaction within ten (10) calendar days of ICANN’s receipt of notice of such transaction pursuant to this Section 7.5. Notwithstanding Section 7.5(a), in the event an assignment is made pursuant to clauses (ii) or (iii) of this Section 7.5(f), the assigning party will provide the other party with prompt notice following any such assignment.
Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
State Approval of Replacement Personnel The Engineer may not replace the project manager or key personnel without prior consent of the State. The State must be satisfied that the new project manager or other key personnel is qualified to provide the authorized services. If the State determines that the new project manager or key personnel is not acceptable, the Engineer may not use that person in that capacity and shall replace him or her with one satisfactory to the State within forty-five (45) days.
GRANT AND SCOPE OF LICENCE 1.1 In consideration of payment by you of the agreed licence fee and you agreeing to abide by the terms of this Licence, we grant to you a non-exclusive, non-transferable and non-sublicensable licence to use the Software and the Documents in the UK on the terms of this Licence.
No Construction as Employment Agreement Nothing contained in this Agreement shall be construed as giving Indemnitee any right to be retained in the employ of the Company or any of its subsidiaries.
GENERAL WORKING CONDITIONS Section 18-1. Employment begins and ends at each project site. Section 18-2. The selection of craft foremen and/or general foremen and the number of foremen required shall be entirely the responsibility of the Employer, it being understood that in the selection of such foremen and/or general foremen the Employer will give primary consideration to the qualified individuals available in the local area. After giving such consideration, the Employer may select such individuals from other areas. All foremen shall take orders from the designated Employer representatives. Craft foremen shall be designated working foremen at the request of the Employer. Section 18-3. There shall be no limit on production by employees nor restrictions on the full use of tools or equipment. Employees using tools shall perform any of the work of the trade and shall work under the direction of the craft foremen. There shall be no restrictions on efficient use of manpower other than as may be required by safety regulations. Section 18-4. Employees shall be at their place of work at the starting time and shall remain at their place of work performing their assigned functions under the supervision of the Employer until quitting time. The parties reaffirm their policy of a fair day’s work for a fair day’s wage. Section 18-5. All equipment assigned to a project shall be under the control of the Employer. The Employer shall have the right to determine how many pieces of equipment an individual employee shall operate. In an emergency, foremen shall operate any equipment assigned by the Employer, and there shall be no restriction on foremen in the use of the tools of his or her craft in such emergency. The foremen shall be from the craft normally operating the equipment. In accordance with currently recognized craft jurisdiction, the Employer shall determine the assignment of employees to start, stop, and maintain small portable construction equipment. Such work may be assigned to craft employees within a reasonable distance of their primary duties or an employee may be assigned full time to start, stop and maintain the Employer’s small, portable equipment on the job site. There shall be no over xxxxxxx of this type of equipment. The number of employees assigned to rigging and scaffolding operations shall be at the sole discretion of the Employer. The ratio of journeyperson to welders shall be determined solely by the Employer. Section 18-6. The Employer may utilize the most efficient methods or techniques of construction, tools or other labor saving devices to accomplish the work. Practices not a part of the terms and conditions of this Agreement, stand by crews and feather bedding practices will not be recognized. Section 18-7. It is recognized that specialized or unusual equipment may be installed and/ or serviced by individuals who have special training, skill, or qualifications and are not covered by this Agreement. Testing, inspection, or service performed on plant equipment under warranty may be performed by the vendor’s personnel. Section 18-8. Neither the Union nor its local unions shall coerce or in any way interfere with the Owner’s personnel, operation or facilities at the plant site. The Owner’s right to contract directly with other companies for work at the plant site shall not be limited, and the Union shall cooperate and not interfere with the Employer’s operations. Section 18-9. It is agreed that overtime is undesirable and not in the best interest of the industry or the employees; therefore, except in unusual circumstances, overtime will not be worked. Where unusual circumstances do exist, however, the Employer will have the right to assign specific employees and/or crews to perform such overtime work as is necessary to accomplish the job. Section 18-10. There will be no rest periods, organized coffee breaks or other non-working time established during working hours. Section 18-11. Individual seniority shall not be recognized or applied to employees working on projects under this Agreement. Section 18-12. The Employer shall establish such reasonable project rules as the Employer deems appropriate. These rules will be reviewed at the pre-job conference and posted at the project site by the Employer, and may be amended thereafter as necessary.
Data Protection Impact Assessment and Prior Consultation Processor shall provide reasonable assistance to the Company with any data protection impact assessments, and prior consultations with Supervising Authorities or other competent data privacy authorities, which Company reasonably considers to be required by article 35 or 36 of the GDPR or equivalent provisions of any other Data Protection Law, in each case solely in relation to Processing of Company Personal Data by, and taking into account the nature of the Processing and information available to, the Contracted Processors.
