Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
CONDUCT OF THE AUCTION Conduct of the auction and increments of bidding are at the discretion of the Auctioneer. The Auctioneer's decision is final in the event of a dispute over any matter. The Auctioneer reserves the right to accept bids in any increments he deems to be in the best interest of his client, and reserves the right to waive any previously announced requirements. Bid rigging and bid suppression schemes are violations of the Xxxxxxx Antitrust Act and are deemed illegal and punishable as a federal felony.
Obligations of the Academy Trust The Academy Trust must keep the Land clean and tidy and make good any damage or deterioration to the Land. The Academy Trust must not do anything to lessen the value or marketability of the Land without the Secretary of State’s consent.
Conduct of the Arbitration 1. Where issues relating to jurisdiction or admissibility are raised as preliminary objections, the tribunal shall decide the matter before proceeding to the merits.
2. A disputing Member State may, no later than 30 days after the constitution of the tribunal, file an objection that a claim is manifestly without merit. A disputing Member State may also file an objection that a claim is otherwise outside the jurisdiction or competence of the tribunal. The disputing Member State shall specify as precisely as possible the basis for the objection.
3. The tribunal shall address any such objection as a preliminary question apart from the merits of the claim. The disputing parties shall be given a reasonable opportunity to present their views and observations to the tribunal. If the tribunal decides that the claim is manifestly without merit, or is otherwise not within the jurisdiction or competence of the tribunal, it shall render an award to that effect.
4. The tribunal may, if warranted, award the prevailing party reasonable costs and fees incurred in submitting or opposing the objection. In determining whether such an award is warranted, the tribunal shall consider whether either the claim or the objection was frivolous or manifestly without merit, and shall provide the disputing parties a reasonable opportunity to comment.
5. Unless the disputing parties otherwise agree, the tribunal shall determine the place of arbitration in accordance with the applicable arbitration rules, provided that the place shall be in the territory of a State that is a party to the New York Convention.
6. Where an investment dispute relate to a measure which may be a taxation measure, the disputing Member State and the non-disputing Member State, including representatives of their tax administrations, shall hold consultations to determine whether the measure in question is a taxation measure.
7. Where a disputing investor claims that the disputing Member State has breached Article 14 (Expropriation and Compensation) by the adoption or enforcement of a taxation measure, the disputing Member State and the non-disputing Member State shall, upon request from the disputing Member State, hold consultations with a view to determining whether the taxation measure in question has an effect equivalent to expropriation or nationalisation.
8. Any tribunal that may be established under this Section shall accord serious consideration to the decision of both Member States under paragraphs 6 and 7.
9. If both Member States fail either to initiate such consultations referred to paragraphs 6 and 7, or to make such joint decisions, within the period of 180 days from the date of the receipt of request for consultation referred to in Article 31 (Consultations), the disputing investor shall not be prevented from submitting its claim to arbitration in accordance with this Section.
AMOUNTS AND TERMS OF THE ADVANCES AND THE LETTERS OF CREDIT SECTION 2.01. The Advances and the Letters of Credit.
Registration Procedures and Expenses The Company hereby agrees that it shall:
(a) prepare and file with the Securities and Exchange Commission (the “SEC”), as soon as reasonably practicable after the date of the Company’s initial issuance of Securities to a Trust pursuant to one of the Contribution Agreements, but in no event more than 120 days after such date, a shelf registration statement on Form S-3 covering the Securities (such registration statement and any successor registration statement filed under the Securities Act of 1933, as amended (the “Securities Act”), shall be hereinafter referred to as the “Registration Statement”), to enable the appropriate Committee, with respect to each Trust, to direct the Trustee to sell the Securities from time to time in the manner contemplated by the plan of distribution set forth in any prospectus that is part of the Registration Statement, as amended by any prospectus supplement or post-effective amendment thereto, and use its reasonable commercial efforts to cause such Registration Statement to be declared effective as promptly as reasonably possible after filing and to remain continuously effective until the earliest of (i) the date on which all Securities have been sold, and (ii) the fifth anniversary of the Contribution Agreements (the “Registration Period”); provided, however, that it shall not be required to file such Registration Statement or cause such Registration Statement to be declared effective during the pendency of any suspension period pursuant to Sections 1.2(c) or (d) below;
(b) prepare and file with the SEC such amendments (including post-effective amendments) and supplements to the Registration Statement and the prospectus filed with the SEC pursuant to Rule 424(b) under the Securities Act, or if no such filing is required, as included in the Registration Statement (the “Prospectus”), as may be necessary to keep the Registration Statement effective at all times until the end of the Registration Period; provided, however, that it shall not be required to file any such amendment or prospectus supplement during the pendency of any suspension period pursuant to Sections 1.2(c) or (d) below;
(c) with respect to each Trust, furnish the Committees and the Trustee with such reasonable number of copies of the Prospectus in conformity with the requirements of the Securities Act, and such other documents as the Committees may direct the Trustee to request, in order to facilitate the public sale or other disposition of all or any of the Securities held by such Trust by the Trustee, as directed by the appropriate Committee;
(d) use its reasonable commercial efforts to file documents required of the Company for normal blue sky clearance in such states as the Committees shall reasonably designate in writing; provided, however, that the Company shall not be required to qualify to do business or consent to service of process in any jurisdiction in which it is not now so qualified or has not so consented; and
(e) bear all expenses in connection with the actions contemplated by paragraphs (a) through (d) of this Section 1.1 and the registration of the Securities pursuant to the Registration Statement. With respect to each Trust, the Committees shall provide such reasonable assistance to the Company and furnish, or cause to be furnished, to the Company in writing such information regarding the Securities to be sold and the intended method or methods of disposition of the Securities, as shall be required to effect the registration of the Securities and as may be required from time to time under the Securities Act and the rules and regulations thereunder. As directed by the appropriate Committee, with respect to each Trust, the Trustee will provide the Company with specific information from the Trustee’s ordinary books and records about the Securities or the Trust.
Amounts and Terms of the Advances and Letters of Credit SECTION 2.01. The Advances and Letters of Credit.
Other Activities of the Adviser The services of the Adviser to the Corporation are not exclusive, and the Adviser may engage in any other business or render similar or different services to others including, without limitation, the direct or indirect sponsorship or management of other investment based accounts or commingled pools of capital, however structured, having investment objectives similar to those of the Corporation, so long as its services to the Corporation hereunder are not impaired thereby, and nothing in this Agreement shall limit or restrict the right of any manager, partner, member (including its members and the owners of its members), officer or employee of the Adviser to engage in any other business or to devote his or her time and attention in part to any other business, whether of a similar or dissimilar nature, or to receive any fees or compensation in connection therewith (including fees for serving as a director of, or providing consulting services to, one or more of the Corporation’s portfolio companies, subject to applicable law). The Adviser assumes no responsibility under this Agreement other than to render the services called for hereunder. It is understood that directors, officers, employees and stockholders of the Corporation are or may become interested in the Adviser and its affiliates, as directors, officers, employees, partners, stockholders, members, managers or otherwise, and that the Adviser and directors, officers, employees, partners, stockholders, members and managers of the Adviser and its affiliates are or may become similarly interested in the Corporation as stockholders or otherwise.
The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
Other Activities of the Advisor Except as set forth in this Section 14 , nothing herein contained shall prevent the Advisor or any of its Affiliates from engaging in or earning fees from other activities, including the rendering of advice to other Persons (including other REITs) and the management of other programs advised, sponsored or organized by the Sponsor or its Affiliates; nor shall this Agreement limit or restrict the right of any director, officer, member, partner, employee or stockholder of the Advisor or any of its Affiliates to engage in or earn fees from any other business or to render services of any kind to any other Person and earn fees for rendering such services; provided, however , that the Advisor must devote sufficient resources to the Company’s business to discharge its obligations to the Company under this Agreement. The Advisor may, with respect to any investment in which the Company is a participant, also render advice and service to each and every other participant therein, and earn fees for rendering such advice and service. Specifically, it is contemplated that the Company may enter into Joint Ventures or other similar co-investment arrangements with certain Persons, and pursuant to the agreements governing such Joint Ventures or arrangements, the Advisor may be engaged to provide advice and service to such Persons, in which case the Advisor will earn fees for rendering such advice and service. The Advisor shall report to the Board the existence of any condition or circumstance, existing or anticipated, of which it has knowledge, which creates or could create a conflict of interest between the Advisor’s obligations to the Company and its obligations to or its interest in any other Person. If the Advisor, Director or Affiliates thereof have sponsored other investment programs with similar investment objectives which have investment funds available at the same time as the Company, the Advisor shall inform the Board of the method to be applied by the Advisor in allocating investment opportunities among the Company and competing investment entities and shall provide regular updates to the Board of the investment opportunities provided by the Advisor to competing programs in order for the Board (including the Independent Directors) to fulfill its duty to ensure that the Advisor and its Affiliates use their reasonable best efforts to apply such method fairly to the Company.
