File Management and Record Retention relating to CRF Eligible Persons or Households Grantee must maintain a separate file for every applicant, Eligible Person, or Household, regardless of whether the request was approved or denied.
a. Contents of File: Each file must contain sufficient and legible documentation. Documents must be secured within the file and must be organized systematically.
Fraud, Waste, and Abuse Contractor understands that HHS does not tolerate any type of fraud, waste, or abuse. Violations of law, agency policies, or standards of ethical conduct will be investigated, and appropriate actions will be taken. Pursuant to Texas Government Code, Section 321.022, if the administrative head of a department or entity that is subject to audit by the state auditor has reasonable cause to believe that money received from the state by the department or entity or by a client or contractor of the department or entity may have been lost, misappropriated, or misused, or that other fraudulent or unlawful conduct has occurred in relation to the operation of the department or entity, the administrative head shall report the reason and basis for the belief to the Texas State Auditor’s Office (SAO). All employees or contractors who have reasonable cause to believe that fraud, waste, or abuse has occurred (including misconduct by any HHS employee, Grantee officer, agent, employee, or subcontractor that would constitute fraud, waste, or abuse) are required to immediately report the questioned activity to the Health and Human Services Commission's Office of Inspector General. Contractor agrees to comply with all applicable laws, rules, regulations, and System Agency policies regarding fraud, waste, and abuse including, but not limited to, HHS Circular C-027. A report to the SAO must be made through one of the following avenues: ● SAO Toll Free Hotline: 1-800-TX-AUDIT ● SAO website: xxxx://xxx.xxxxx.xxxxx.xx.xx/ All reports made to the OIG must be made through one of the following avenues: ● OIG Toll Free Hotline 0-000-000-0000 ● OIG Website: XxxxxxXxxxxXxxxx.xxx ● Internal Affairs Email: XxxxxxxxXxxxxxxXxxxxxxx@xxxx.xxxxx.xx.xx ● OIG Hotline Email: XXXXxxxxXxxxxxx@xxxx.xxxxx.xx.xx. ● OIG Mailing Address: Office of Inspector General Attn: Fraud Hotline MC 1300 P.O. Box 85200 Austin, Texas 78708-5200
Compliance with Contractor Employee Jury Service Ordinance Contractor shall comply with the County Ordinance with respect to provision of jury duty pay to employees and have and adhere to a written policy that provides that its employees shall receive from the Contractor, on an annual basis, no less than five days of regular pay for actual jury service in San Mateo County. The policy may provide that employees deposit any fees received for such jury service with the Contractor or that the Contractor deduct from the employees’ regular pay the fees received for jury service.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
COMPLIANCE WITH NEW YORK STATE INFORMATION SECURITY BREACH AND NOTIFICATION ACT Contractor shall comply with the provisions of the New York State Information Security Breach and Notification Act (General Business Law Section 899-aa; State Technology Law Section 208).
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS The Contractor, it’s Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor’s obligations under this paragraph.
Access to Work District representatives shall at all times have access to the Work, wherever it is, in preparation or in progress. Contractor shall provide safe and proper facilities for such access.
Definitions of Key Terms Relating to Additional Rent As used in this Article 4, the following terms shall have the meanings hereinafter set forth: