Taxes Other Than Income Taxes Upon the timely request by the Interconnection Customer, and at the Interconnection Customer’s sole expense, the CAISO or Participating TO may appeal, protest, seek abatement of, or otherwise contest any tax (other than federal or state income tax) asserted or assessed against the CAISO or Participating TO for which the Interconnection Customer may be required to reimburse the CAISO or Participating TO under the terms of this LGIA. The Interconnection Customer shall pay to the Participating TO on a periodic basis, as invoiced by the Participating TO, the Participating TO’s documented reasonable costs of prosecuting such appeal, protest, abatement, or other contest. The Interconnection Customer, the CAISO, and the Participating TO shall cooperate in good faith with respect to any such contest. Unless the payment of such taxes is a prerequisite to an appeal or abatement or cannot be deferred, no amount shall be payable by the Interconnection Customer to the CAISO or Participating TO for such taxes until they are assessed by a final, non-appealable order by any court or agency of competent jurisdiction. In the event that a tax payment is withheld and ultimately due and payable after appeal, the Interconnection Customer will be responsible for all taxes, interest and penalties, other than penalties attributable to any delay caused by the Participating TO.
Disbursements to Contractors to Pay Costs of the Project The Recipient shall require that as work on the Project and as specified in its contract is performed a Contractor shall promptly submit a detailed project specific invoice to the Project Manager. Within three (3) Business Days following receipt of such invoice from a Contractor, the Project Manager shall review the invoice and, if found to be accurate, shall so certify in writing, forwarding such certification together with a copy of the invoice to the Chief Fiscal Officer. Within five (5) Business Days following receipt of such invoice and certification from the Project Manager, the Chief Fiscal Officer shall conduct such reviews as he considers appropriate and, if he approves such invoice, shall submit to the Director a Disbursement Request together with the information and certifications required by this Section 6(b). The dollar amount set forth in the Disbursement Request shall be calculated based on the Participation Percentage as set forth originally in Appendix D of this Agreement or as may be adjusted from time to time to account for changed conditions in the project financing scheme. Within five (5) Business Days following receipt of the Disbursement Request and all required information and certifications, the Director shall, if such items are deemed by the Director to be accurate and completed, initiate a voucher in accordance with applicable State requirements for the payment of the amount set forth in the Disbursement Request. Upon receipt of a warrant from the Auditor of State drawn in connection with a voucher initiated in accordance with the terms of the preceding sentence, the Director shall forward it by regular first class United States mail or electronic funds transfer, to the contractor or other authorized recipient designated in the Disbursement Request. Prior to any disbursement from the Fund, the following documents shall be submitted to the Director by the Recipient:
Payment of Debt Borrower will pay the Debt at the time and in the manner provided in the Note and in this Security Instrument.
Recovery of Overpayments On occasion a payment will be made to You when You are not covered, for a service that is not Covered, or which is more than is proper. When this happens We will explain the problem to You and You must return the amount of the overpayment to Us within 60 days after receiving notification from Us. However, We shall not initiate overpayment recovery efforts more than 24 months after the original payment was made unless We have a reasonable belief of fraud or other intentional misconduct.
Funding Arrangements Minimum amounts/increments for Japan Local Currency Borrowings, repayments and prepayments: Same as Credit Agreement.
Payment of Taxes and Other Expenses Should City, in its discretion, or a relevant taxing authority such as the Internal Revenue Service or the State Employment Development Division, or both, determine that Contractor is an employee for purposes of collection of any employment taxes, the amounts payable under this Agreement shall be reduced by amounts equal to both the employee and employer portions of the tax due (and offsetting any credits for amounts already paid by Contractor which can be applied against this liability). City shall then forward those amounts to the relevant taxing authority. Should a relevant taxing authority determine a liability for past services performed by Contractor for City, upon notification of such fact by City, Contractor shall promptly remit such amount due or arrange with City to have the amount due withheld from future payments to Contractor under this Agreement (again, offsetting any amounts already paid by Contractor which can be applied as a credit against such liability). A determination of employment status pursuant to the preceding two paragraphs shall be solely for the purposes of the particular tax in question, and for all other purposes of this Agreement, Contractor shall not be considered an employee of City. Notwithstanding the foregoing, should any court, arbitrator, or administrative authority determine that Contractor is an employee for any other purpose, then Contractor agrees to a reduction in City’s financial liability so that City’s total expenses under this Agreement are not greater than they would have been had the court, arbitrator, or administrative authority determined that Contractor was not an employee.
COPIES OF THE COLLECTIVE AGREEMENT The Union and the Employer agree that every employee should be familiar with the provisions of this Agreement and her rights and obligations under it. For this reason, the Employer shall make available copies of the Collective Agreement in booklet form to all of its employees. The cost of printing shall be shared equally between the Union and the Employer. The Agreement shall be printed in a Union shop and bear a recognized Union label. The Union and the Employer shall agree on the size, print and color of the Agreement and all other particulars prior to it being printed. Printing shall be completed as soon as possible after the signing of the Collective Agreement.
Billing Arrangements Unless otherwise agreed to in writing, you will receive a consolidated bill from the LDU for each billing period containing both the electric supply services provided by Starion and the services provided by your LDU. Your LDU will set your payment due date and payment address. You will continue to make payment for all of these services to the LDU in accordance with the payment terms stated in the LDU’s tariffs. Xxxxxxx’s charges are due when the LDU’s charges are due. Customer agrees to timely review its invoices and agrees that subject to applicable tariff and law, unless notice is given to Starion within ninety (90) days of the invoice date, all invoiced amounts will be deemed by you to be correct and Customer shall waive any right to dispute amounts set forth on such invoice. We reserve the right to assume any and all billing responsibility, including the LDU’s charges, if necessary. If we assume billing responsibility, we will follow the applicable Uniform Business Practices Act (UBP) and Home Energy Fair Practices Act (HEFPA), and the following provisions will apply: a $30 fee may be assessed for all returned payments; if you pay a lesser amount than is due, even if you designate it as a full payment, our acceptance of the payment is without prejudice to any other rights or remedies we may have, and you agree we may disregard your designation and apply the payment as a partial payment to your account; and if payments are returned two (2) times in a 12-month period, we may demand payment be made using a money order, certified check or electronic funds transfer.
Financing Arrangements (a) The Owner will obtain the Project Loan which shall be sufficient, together with the Owner's equity contributions, to pay the full amount of the costs to construct the Project in accordance with the development budget. The Owner and the Developer also contemplate that the Property and the Project, together with all fixtures, furnishing, equipment, and articles of personal property now owned or hereafter acquired by the Owner which are or may be attached to or used in connection with the Property or the Project, together with any and all replacements thereto and substitutions therefor, and all proceeds thereof; and all present and future rents, issues, leases, and profits of the Property and the Project will serve as security for the payment obligations to any lenders relating to the Project Loan or otherwise, and that the Owner will be the principal obligor for the repayment of all financial obligations thereunder after the transfer of title to the Owner. The Owner therefore, agrees to execute and deliver all commitments, promissory notes, mortgages, collateral assignments, documents, certificates, affidavits, and other writings required to be executed by any lender in connection with such financing.
Correction of Errors and Omissions; Other Liabilities (a) In the event any bookkeeping omissions or errors are discovered in preparing any pro forma statement or in completing the transfers and assumptions contemplated hereby, the parties hereto agree to correct such errors and omissions, it being understood that, as far as practicable, all adjustments will be made consistent with the judgments, methods, policies or accounting principles utilized by the Failed Bank in preparing and maintaining Accounting Records, except that adjustments made pursuant to this Section 8.2(a) are not intended to bring the Accounting Records of the Failed Bank into accordance with generally accepted accounting principles.
