We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

Rejected Work Sample Clauses

Rejected WorkDistrict shall have the right to reject Consultant’s defective work. Consultant shall promptly eliminate all defects free of charge. If Consultant fails to eliminate all defects within a reasonable time, District may eliminate the defects, or hire another consultant to eliminate the defects and charge the expense of eliminating the defects to Consultant. If District deems it inexpedient to correct a defect, District may reduce the fee payable to Consultant by an amount that in District’s sole judgment reflects the diminished value of the work represented by the defect. District’s rights under this paragraph shall be in addition to and not in lieu of all rights District may otherwise have in the event Consultant produces defective work.
Rejected Work. 37.1 Defective Work, whether the result of poor design, poor workmanship, use of defective equipment or materials, or damage through carelessness, default or other acts of the Design-Builder or any Subcontractor, and whether incorporated in the Work or not, which has been rejected by the Owner as failing to conform to any of the Statement of Requirements, the Design or the Standards, will be removed promptly by the Design-Builder and replaced and re-executed promptly and properly at the Design-Builder’s expense. 37.2 If the Design-Builder does not remove such defective Work within the time fixed by written notice by the Owner, the Owner may remove them and store any materials at the expense of the Design-Builder. 37.3 Other Contractor’s work destroyed or damaged by such removals or replacements will be made good by the Design-Builder promptly at the Design-Builder’s expense.
Rejected WorkDistrict shall have the right to reject Contractor's defective work. Contractor shall promptly eliminate all defects free of charge. If Contractor fails to eliminate all defects within a reasonable time, District may eliminate the defects, or hire another contractor to eliminate the defects and charge the expense of eliminating the defects to Contractor. If District deems it inexpedient to correct a defect, District may reduce the fee payable to Contractor by an amount that in District’s sole judgment reflects the diminished value of the work represented by the defect. District's rights under this paragraph shall be in addition to and not in lieu of all rights District may otherwise have in the event Contractor produces defective work.
Rejected Work. If, after inspection any Work is rejected by the Engineer as defective or improperly done, such defective or improper Work shall be taken down and rebuilt or the defects otherwise remedied as the Engineer may direct. If the Contractor refuses or neglects to remove such rejected Work, or otherwise correct the defects, as the Engineer directs, the Commissioner may obtain, use and employ materials, men and equipment to do the same, and the expense thereof will be solely borne by the Contractor and may be deducted from any money which may then be due or thereafter become due to the Contractor for Work performed under this Contract.
Rejected Work. If the Client rejects the work within the review period, or will not approve subsequent work performed by The Agency to remedy any points reported by the Client as unsatisfactory, and The Agency considers that the Client is unreasonable in his repeated rejection of the work, the contract will be deemed to have expired and The Agency can take any legal measures to recover both payment for the completed work and reasonable expenses incurred in recovering payment.
Rejected WorkThe Contractor shall promptly correct Work rejected by the Architect, the Owner or any governmental authority, or that does not conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear the costs of correcting such rejected Work, including additional testing and inspections and compensation for the Architect's services and expenses made necessary thereby.
Rejected Work. 14.01. All work deemed not in conformity with this Contract as determined by the City in its sole discretion, may be rejected by the City. City's Representative may reject any work found to be defective or not in accordance with the Contract Documents, regardless of the stage of the work's completion or the time or place of discovery of such defects or inconsistencies and regardless of whether City's Representative has previously accepted the work through oversight or otherwise. Neither observations nor inspections, tests, or approvals made by City's Representative, or other persons authorized under this Contract to make such observations, inspections, tests, or approvals, shall relieve the Contractor from the obligation to perform the work in accordance with the requirements of this Contract and the other Contract Documents. 14.02. If the work or any part thereof is rejected by the City, it shall be deemed by City's Representative as not in conformity with this Contract. Any remedial action required, as set forth herein, shall be at the Contractor's expense, as follows: (a) The Contractor may be required, at the City's option, after notice from City's Representative, to remedy such work so that it shall be in full compliance with this Contract. All rejected work or materials shall be immediately replaced in order to conform with this Contract. (b) If the City deems it inexpedient to correct work damaged or not done in accordance with this Contract, an equitable deduction from the agreed sum may be made by the City at the City's sole discretion.
Rejected Work. .1 Remove defective work, whether incorporated into the work or not, which has been rejected by Coast Guard as failing to comply with the contract documents. Replace or re-execute in accordance with the Contract Documents.
Rejected Work. ‌ In the case that Works are not according to standard or otherwise have been determined to be unacceptable, the Contractor must: a. Promptly remove, re-execute or replace any and all rejected Work or Product whether incorporated in the Work or not, which has been identified by the City as not conforming to the Contract Documents. b. Bear all costs related to the removal, re-fabrication or replacement of rejected Work or Product including delays or damage to the Work of any other contractor. Correction is required whether or not the rejected Work or Product was previously overlooked by the City or did not become apparent until a later time. c. Reimburse the City for any additional engineering, inspection, testing or other related costs incurred in respect of rejected Work or Product whether or not the Work or Product are rejected or are accepted at a reduced price.
Rejected Work. Within twenty-four (24) hours after receiving written notice from Contractor, Subcontractor shall proceed to remove all portions of rejected Work and remove from the Project site all materials, whether worked or unworked, related thereto, and shall make good all such work and all other work damaged or destroyed in removing or making good such rejected work. Subcontractor shall not remove any other material from the site without Contractor’s written permission. If Subcontractor fails to correct its Work within three (3) days from the date of written notice, Contractor may correct the Work with all related costs charged to Subcontractor, but such correction shall not affect Contractor’s ability to seek reimbursement from Subcontractor for such correction.