Report Cards and Liquidated Damages
Report Cards and Liquidated Damages Sample Clauses
Related to Report Cards and Liquidated Damages
Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Reports; Payment of Royalty During the Term following the First Commercial Sale of a Product, Merck shall furnish to Ambrx a quarterly written report for the Calendar Quarter showing the Net Sales of all Royalty Products subject to royalty payments sold by Merck and its Related Parties in the Territory for use in the Field during the reporting period and the royalties payable under this Agreement. Reports shall be due on the [***] day following the close of each Calendar Quarter. Royalties shown to have accrued by each royalty report shall be due and payable on the date such royalty report is due. Merck shall keep complete and accurate records in sufficient detail to enable the royalties payable hereunder to be determined.
Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all tax benefits and other reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Certain Rules Relating to the Payment of Additional Amounts (a) Upon the request, and at the expense of the Borrower, each Lender and Agent to which the Borrower is required to pay any additional amount pursuant to Subsection 4.10 or 4.11, and any Participant in respect of whose participation such payment is required, shall reasonably afford the Borrower the opportunity to contest, and reasonably cooperate with the Borrower in contesting, the imposition of any Non-Excluded Tax giving rise to such payment; provided that (i) such Lender or Agent shall not be required to afford the Borrower the opportunity to so contest unless the Borrower shall have confirmed in writing to such Lender or Agent its obligation to pay such amounts pursuant to this Agreement and (ii) the Borrower shall reimburse such Lender or Agent for its reasonable attorneys’ and accountants’ fees and disbursements incurred in so cooperating with the Borrower in contesting the imposition of such Non-Excluded Tax; provided, however, that notwithstanding the foregoing no Lender or Agent shall be required to afford the Borrower the opportunity to contest, or cooperate with the Borrower in contesting, the imposition of any Non-Excluded Taxes, if such Lender or Agent in its sole discretion in good faith determines that to do so would have an adverse effect on it.
No Duty to Collect Amounts Due From Dividend and Transfer Agent The Custodian shall not be under any duty or obligation to take action to effect collection of any amount due to the Trust from any Dividend and Transfer Agent of the Trust nor to take any action to effect payment or distribution by any Dividend and Transfer Agent of the Trust of any amount paid by the Custodian to any Dividend and Transfer Agent of the Trust in accordance with this Agreement.
Payments Royalties and Reports 3.0 Coordination of Payments under the US Agreement. The license fee, milestone payments and royalties payable by SPL under this Article III are in consideration for the rights and licenses granted to SPL under this Agreement and are in addition to any amounts payable to Licensor under the US Agreement. It is understood and agreed that, with respect to the development milestone payable under Section 3.2(a)(i) and the sales milestones payable under Section 3.2(b) the occurrence of one or more of such milestone events will result in milestone payment obligations under both this Agreement and the corresponding provisions of the US Agreement. It is further understood that SPL's financial obligations with respect to development costs under Article II shall be [ * ] apportioned between SPL and the corresponding obligations of Schering Corporation under the US Agreement.
Payment of Royalties To the best of Seller’s knowledge, all royalties and in-lieu royalties with respect to the Assets which accrued or are attributable to the period prior to the Effective Time have been properly and fully paid, or are included within the suspense amounts being conveyed to Buyer pursuant to Section 11.4.
