Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Attachment C_ CONTRACT AFFIRMATIONS For purposes of these Contract Affirmations, HHS includes both the Health and Human Services Commission (HHSC) and the Department of State Health Services (DSHS). System Agency refers to HHSC, DSHS, or both, that will be a party to this Contract. These Contract Affirmations apply to all Contractors and Grantees (referred to as “Contractor”) regardless of their business form (e.g., individual, partnership, corporation). By entering into this Contract, Contractor affirms, without exception, understands, and agrees to comply with the following items through the life of the Contract:
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Drug-Free Workplace Certification As required by Executive Order No. 90-5 dated April 12, 1990, issued by the Governor of Indiana, the Company hereby covenants and agrees to make a good faith effort to provide and maintain a drug-free workplace at the Project Location. The Company will give written notice to the IEDC within ten (10) days after receiving actual notice that the Company, or an employee of the Company in the State of Indiana, has been convicted of a criminal drug violation occurring in the workplace. False certification or violation of this certification may result in sanctions including, but not limited to, suspension of payments under the Agreement, termination of the Agreement and/or debarment of contracting opportunities with the State for up to three (3) years. In addition to the provisions of the above paragraph, if the total amount set forth in the Agreement is in excess of $25,000.00, the Company agrees that it will provide a drug-free workplace by:
A. Publishing and providing to all of its employees a statement notifying them that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Company’s workplace, and specifying the actions that will be taken against employees for violations of such prohibition;
Additional Reporting Requirements Contractor agrees to submit written quarterly reports to H-GAC detailing all transactions during the previous three (3) month period. Reports must include, but are not limited, to the following information:
a. Customer Name b. Product/Service purchased, including Product Code if applicable c. Customer Purchase Order Number
Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse.
B. Grantee shall use the Texas Abuse Hotline Website located at xxxxx://xxx.xxxxxxxxxxxxxx.xxx/Login/Default.aspx as required by the System Agency. Grantee shall retain reporting documentation on site and make it available for inspection by the System Agency.
CERTIFICATION REGARDING USE OF CONTRACT FUNDS FOR LOBBYING This provision is applicable to all Federal-aid construction contracts and to all related subcontracts which exceed $100,000 (49 CFR 20).
1. The prospective participant certifies, by signing and submitting this bid or proposal, to the best of his or her knowledge and belief, that:
a. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement.
b. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL, "Disclosure Form to Report Lobbying," in accordance with its instructions.
2. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by 31 U.S.C. 1352. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure.
3. The prospective participant also agrees by submitting its bid or proposal that the participant shall require that the language of this certification be included in all lower tier subcontracts, which exceed $100,000 and that all such recipients shall certify and disclose accordingly. This provision is applicable to all Federal-aid projects funded under the Appalachian Regional Development Act of 1965.
1. During the performance of this contract, the contractor undertaking to do work which is, or reasonably may be, done as on-site work, shall give preference to qualified persons who regularly reside in the labor area as designated by the DOL wherein the contract work is situated, or the subregion, or the Appalachian counties of the State wherein the contract work is situated, except:
a. To the extent that qualified persons regularly residing in the area are not available.
b. For the reasonable needs of the contractor to employ supervisory or specially experienced personnel necessary to assure an efficient execution of the contract work.
c. For the obligation of the contractor to offer employment to present or former employees as the result of a lawful collective bargaining contract, provided that the number of nonresident persons employed under this subparagraph (1c) shall not exceed 20 percent of the total number of employees employed by the contractor on the contract work, except as provided in subparagraph (4) below.
2. The contractor shall place a job order with the State Employment Service indicating (a) the classifications of the laborers, mechanics and other employees required to perform the contract work, (b) the number of employees required in each classification, (c) the date on which the participant estimates such employees will be required, and (d) any other pertinent information required by the State Employment Service to complete the job order form. The job order may be placed with the State Employment Service in writing or by telephone. If during the course of the contract work, the information submitted by the contractor in the original job order is substantially modified, the participant shall promptly notify the State Employment Service.
3. The contractor shall give full consideration to all qualified job applicants referred to him by the State Employment Service. The contractor is not required to grant employment to any job applicants who, in his opinion, are not qualified to perform the classification of work required.
4. If, within one week following the placing of a job order by the contractor with the State Employment Service, the State Employment Service is unable to refer any qualified job applicants to the contractor, or less than the number requested, the State Employment Service will forward a certificate to the contractor indicating the unavailability of applicants. Such certificate shall be made a part of the contractor's permanent project records. Upon receipt of this certificate, the contractor may employ persons who do not normally reside in the labor area to fill positions covered by the certificate, notwithstanding the provisions of subparagraph (1c) above.
5. The provisions of 23 CFR 633.207(e) allow the contracting agency to provide a contractual preference for the use of mineral resource materials native to the Appalachian region.
6. The contractor shall include the provisions of Sections 1 through 4 of this Attachment A in every subcontract for work which is, or reasonably may be, done as on-site work.
Certification Regarding Termination of Contract for Non-Compliance (Tex Gov. Code 552.374)
Annual Reports on Assessment of Compliance with Servicing Criteria (a) On or before March 1 of each year commencing in March 2018, the Master Servicer, the Special Servicer, the Certificate Administrator, the Custodian, the Operating Advisor and, if it has made (or is required to make) an Advance during the applicable calendar year, the Trustee, each at its own expense, shall furnish (and each of the preceding parties, as applicable, (i) with respect to any Servicing Function Participant of such party that is a Mortgage Loan Seller Sub-Servicer, shall use commercially reasonable efforts to cause such Servicing Function Participant to furnish, and (ii) with respect to any other Servicing Function Participant of such party (other than any party to this Agreement), shall cause such Servicing Function Participant to furnish) (each Master Servicer, the Special Servicer, the Certificate Administrator, the Custodian, the Operating Advisor, any Servicing Function Participant and, if it has made (or is required to make) an Advance during the applicable calendar year, the Trustee, as the case may be, a “Reporting Servicer”) to the Certificate Administrator, the Trustee, the Serviced Companion Loan Holders (or, in the case of a Serviced Companion Loan that is part of an Other Securitization Trust, the applicable Other Depositor and Other Exchange Act Reporting Party), the Operating Advisor (only in the case of a report furnished by the Special Servicer) and the Depositor, a report on an assessment of compliance with the Relevant Servicing Criteria (together with a copy thereof in XXXXX-Compatible Format, or in such other format as otherwise agreed upon by the Depositor, the Certificate Administrator, the applicable Other Depositor, the applicable Other Exchange Act Reporting Party and the applicable Certifying Servicer) that complies in all material respects with the requirements of Item 1122 of Regulation AB and contains (A) a statement by such Reporting Servicer of its responsibility for assessing compliance with the Relevant Servicing Criteria, (B) a statement that such Reporting Servicer used the Servicing Criteria to assess compliance with the Relevant Servicing Criteria, (C) such Reporting Servicer’s assessment of compliance with the Relevant Servicing Criteria as of the end of and for the preceding calendar year, including, if there has been any material instance of noncompliance with the Relevant Servicing Criteria, a discussion of each such failure and the nature and status thereof and (D) a statement that a registered public accounting firm has issued an attestation report on such Reporting Servicer’s assessment of compliance with the Relevant Servicing Criteria as of and for such period. Copies of all compliance reports delivered pursuant to this Section 10.09 shall be provided to any Certificateholder, upon the written request thereof, by the Certificate Administrator. Each such report shall be addressed to the Depositor and each Other Depositor (if addressed) and signed by an authorized officer of the applicable company, and shall address each of the Relevant Servicing Criteria specified on a certification substantially in the form of Exhibit O to this Agreement delivered to the Depositor on the Closing Date. Promptly after receipt of each such report, (i) the Depositor and each Other Depositor may review each such report and, if applicable, consult with the each Reporting Servicer as to the nature of any material instance of noncompliance with the Relevant Servicing Criteria, and (ii) the Certificate Administrator shall confirm that the assessments, taken individually address the Relevant Servicing Criteria for each party as set forth on Exhibit O to this Agreement and notify the Depositor of any exceptions. For the avoidance of doubt, the Trustee shall have no obligation or duty to determine whether any such report (other than any such report furnished by the Trustee or any Servicing Function Participant of the Trustee) is in form and substance in compliance with the requirements of Regulation AB.
(b) On the Closing Date, the Master Servicer, the Special Servicer, the Certificate Administrator, the Custodian, the Trustee and the Operating Advisor each acknowledge and agree that Exhibit O to this Agreement sets forth the Relevant Servicing Criteria for such party.
(c) No later than the end of each fiscal year for the Trust, the Master Servicer, the Special Servicer, the Certificate Administrator, the Custodian, the Operating Advisor and, if it has made (or is required to make) an Advance during such fiscal year, the Trustee shall notify the Certificate Administrator, the Depositor, each Other Exchange Act Reporting Party and each Other Depositor as to the name of each Servicing Function Participant utilized by it, and the Certificate Administrator shall notify the Depositor and each Other Depositor as to the name of each Servicing Function Participant utilized by it, during such fiscal year, and each such notice will specify what specific Servicing Criteria will be addressed in the report on assessment of compliance prepared by such Servicing Function Participant. When the Master Servicer, the Special Servicer, the Certificate Administrator, the Custodian, the Trustee (if applicable), the Operating Advisor and any Servicing Function Participant submit their assessments pursuant to Section 10.09(a) of this Agreement, such parties will also at such time include the assessment (and related attestation pursuant to Section 10.10 of this Agreement) of each Servicing Function Participant engaged by it. The fiscal year for the Trust shall be January 1 through and including December 31 of each calendar year.
(d) In the event the Master Servicer, the Special Servicer, the Certificate Administrator, the Custodian, the Trustee (if it has made, or is required to make, an Advance during the applicable period) or the Operating Advisor is terminated or resigns pursuant to the terms of this Agreement, such party shall provide, and each such party shall cause (or, if the Servicing Function Participant is a Mortgage Loan Seller Sub-Servicer, shall use commercially reasonable efforts to cause) any Servicing Function Participant of such party to provide (and the Master Servicer, the Special Servicer and the Certificate Administrator shall, with respect to any Servicing Function Participant that resigns or is terminated under any applicable servicing agreement, cause such Servicing Function Participant (or, in the case of each Servicing Function Participant that is a Mortgage Loan Seller Sub-Servicer, shall use commercially reasonable efforts to cause such Servicing Function Participant) to provide) an annual assessment of compliance pursuant to this Section 10.09, coupled with an attestation as required in Section 10.10 of this Agreement with respect to the period of time that the Master Servicer, the Special Servicer, the Certificate Administrator, the Custodian, the Trustee (if it has made, or is required to make, an Advance during such period of time) or the Operating Advisor was subject to this Agreement or the period of time that the applicable Servicing Function Participant was subject to such other servicing agreement. With respect to each Outside Serviced Mortgage Loan serviced under the applicable Outside Servicing Agreement, the Certificate Administrator shall use commercially reasonable efforts to obtain, and upon receipt deliver to the Depositor, an annual report on assessment of compliance as described in this Section and an attestation as described in Section 10.10 from the related Outside Servicer, Outside Special Servicer, Outside Custodian, Outside Trustee and Outside Paying Agent or Outside Certificate Administrator and in form and substance similar to the annual report on assessment of compliance described in this Section 10.09 and the attestation described in Section 10.10.
