Responsibility for Costs The Servicer is responsible for collection from such Borrower of any recording or similar costs or expenses incidental to the granting of relief with respect to a delinquent Mortgage Loan.
Maintenance of Operations The Company shall maintain operations at the Project for a minimum of ten (10) years beginning on the date the Project is Placed in Service. In addition to any other rights the Department may have under the terms of this Agreement, in the event that the Company discontinues of operations at the Project, such discontinuation may subject the Company to certain statutory provisions, including:
1. Pursuant to the Corporate Accountability for Tax Expenditures Act, 20 ILCS 715, et seq., a discontinuance of operations at the Project during the five-year period after the beginning of the first Taxable Year for which the Department issues a Certificate of Verification shall result in all Credits taken by the Company during such five-year period being deemed Wrongfully Exempted Illinois State Income Taxes and shall subject said Wrongfully Exempted Illinois State Income Taxes to the forfeiture provisions of Section VIII.D hereof.
2. Pursuant to Section 5-65 of the Act, discontinuance by the Company of operations at the Project during the term of this Agreement with the intent to terminate operations in the State of Illinois shall result in all Credits taken by the Company being deemed Wrongfully Exempted Illinois State Income Taxes and shall subject said Wrongfully Exempted Illinois State Income Taxes to the forfeiture provisions of Section VIII.D hereof.
Responsibility for Content Vendor is solely responsible for administration, content, intellectual property rights, and all materials at Vendor’s website. DIR reserves the right to require a change of listed content if, in the opinion of DIR, it does not adequately represent the Contract.
Responsibility for Charges 4.1 CBB shall be responsible for and pay to Verizon all charges for any Telecommunications Services provided by Verizon or provided by persons other than Verizon and billed for by Verizon, that are ordered, activated or used by CBB, CBB Customers or any other persons, through, by means of, or in association with, Telecommunications Services provided by Verizon to CBB pursuant to this Resale Attachment.
4.2 Upon request by CBB, Verizon will provide for use on resold Verizon retail Telecommunications Service dial tone lines purchased by CBB such Verizon retail Telecommunications Service call blocking and call screening services as Verizon provides to its own end user retail Customers, where and to the extent Verizon provides such Verizon retail Telecommunications Service call blocking services to Verizon’s own end user retail Customers. CBB understands and agrees that certain of Verizon’s call blocking and call screening services are not guaranteed to block or screen all calls and that notwithstanding CBB’s purchase of such blocking or screening services, CBB’s end user Customers or other persons ordering, activating or using Telecommunications Services on the resold dial tone lines may complete or accept calls which CBB intended to block. Notwithstanding the foregoing, CBB shall be responsible for and shall pay Verizon all charges for Telecommunications Services provided by Verizon or provided by persons other than Verizon and billed for by Verizon in accordance with the terms of Section 4.1 above.
Responsibilities of the Contractor The Contractor shall provide all technical and professional expertise, knowledge, management, and other resources required for accomplishing all aspects of the tasks and associated activities identified in the Scope of Work. In the event that the need arises for the Contractor to perform services beyond those stated in the Scope of Work, the Contractor and the City shall negotiate mutually agreeable terms and compensation for completing the additional services.
Responsibilities of Contractor A. The Contractor shall perform all work on the described project as required by the Contract documents. The work to be performed includes the labor and services necessary to produce such replacement, and all materials, supplies, tools, transportation, equipment, and machinery required for replacement.
B. This project bid includes all materials, labor and equipment to complete the reconstruction and resurfacing of streets as outlined in the Project Manual for WWREYN - XXXXXXXX SANITARY SEWER - PHASE 1 dated March 25th, 2021 as outlined in Attachment A.
Client’s Responsibilities (a) Client agrees to advise Consultant regarding Client's Project requirements and to provide all relevant information, surveys, data and previous reports accessible to Client which Consultant may reasonably require.
(b) Client shall designate a Project Representative to whom all communications from Consultant shall be directed and who shall have limited administrative authority on behalf of Client to receive and transmit information and make decisions with respect to the Project. Said representative shall not, however, have authority to bind Client as to matters of governmental policy or fiscal policy, nor to contract for additions or obligations exceeding a value which is the lesser of $5000 or 5% of the maximum contract price.
(c) Client shall examine all documents presented by Consultant, and render decisions pertaining thereto within a reasonable time. The Client's approval of any drawings, specifications, reports, documents or other materials or product furnished hereunder shall not in any way relieve Consultant of responsibility for the professional adequacy of its work.
(d) Client shall perform its obligations and render decisions within a reasonable time under the circumstances presented. Based upon the nature of Client and its requirements, a period of 14 days shall be presumed reasonable for any decision not involving policy decision or significant financial impact, when all information reasonably necessary for Client to responsibly render a decision has been furnished. A period of 46 days shall be presumed reasonable for Client to act with respect to any matter involving policy or significant financial impact. The above periods of presumed reasonableness shall be extended where information reasonably required is not within the custody or control of Client but must be procured from others.
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Continuity of Operations Engage in any business activities substantially different than those in which Borrower is presently engaged, (2) cease operations, liquidate, merge, transfer, acquire or consolidate with any other entity, change its name, dissolve or transfer or sell Collateral out of the ordinary course of business, or (3) pay any dividends on Borrower's stock (other than dividends payable in its stock), provided, however that notwithstanding the foregoing, but only so long as no Event of Default has occurred and is continuing or would result from the payment of dividends, if Borrower is a "Subchapter S Corporation" (as defined in the Internal Revenue Code of 1986, as amended), Borrower may pay cash dividends on its stock to its shareholders from time to time in amounts necessary to enable the shareholders to pay income taxes and make estimated income tax payments to satisfy their liabilities under federal and state law which arise solely from their status as Shareholders of a Subchapter S Corporation because of their ownership of shares of Borrower's stock, or purchase or retire any of Borrower's outstanding shares or alter or amend Borrower's capital structure.
Responsibility for Property Except as expressly set forth in Section 3.25, Contractor shall limit its operations to the Stage 2 Site. Contractor shall plan and conduct its operations so that neither Contractor nor any of its Subcontractors or Sub-subcontractors shall (i) enter upon lands (other than the Stage 2 Site and Off-Site Rights of Way and Easements) or waterbodies in their natural state unless authorized by the appropriate owner or entity; (ii) close or obstruct any utility installation, highway, waterway, harbor, road or other property unless Permits are obtained and authorized by the appropriate entity or authority; or (iii) disrupt or otherwise interfere with the operation of any portion of any pipeline, telephone, conduit or electric transmission line, ditch, navigational aid, dock or structure unless otherwise specifically authorized by the appropriate entity or authority. The foregoing includes damage arising from performance of the Work through operation of Construction Equipment or stockpiling of materials. If damage occurs to Subproject 1 or Subproject 2 prior to substantial completion of such applicable Subproject 1 or Subproject 2, liability for such damage shall be governed by the Stage 1 EPC Agreement.
