Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
Correction of Errors Contractor shall perform, at its own cost and expense and without reimbursement from the District, any work necessary to correct errors or omissions which are caused by the Contractor’s failure to comply with the standard of care required herein.
Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected. 35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.
Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11: (a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event; (b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5; (c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party. (d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.
Definition of a Grievance A grievance is defined as a dispute or disagreement as to the interpretation or application of the specific terms and conditions of this AGREEMENT.
Reportable Events Involving the Xxxxx Law Notwithstanding the reporting requirements outlined above, any Reportable Event that involves solely a probable violation of section 1877 of the Social Security Act, 42 U.S.C. §1395nn (the Xxxxx Law) should be submitted by Practitioner to CMS through the self-referral disclosure protocol (SRDP), with a copy to the OIG. If Practitioner identifies a probable violation of the Xxxxx Law and repays the applicable Overpayment directly to the CMS contractor, then Practitioner is not required by this Section III.G to submit the Reportable Event to CMS through the SRDP.
Classification of Goods The classification of goods in trade between the Parties shall be in conformity with the Harmonized System.
JOC Pricing of Itemized List of RS Means Non-Prepriced Items No response The Vendor may download the optional Pricing of Itemized List of RS Means Non-Prepriced Items form from the attachment tab, fill in the requested information, and upload the completed spreadsheet. DO NOT UPLOAD encrypted or password protected files. Valid Reference Email addresses are REQUIRED on the spreadsheet. The vendor must download the References spreadsheet from the attachment tab, fill in the requested information and upload the completed spreadsheet. DO NOT UPLOAD encrypted or password protected files.
New Job Classifications When a new classification (which is covered by the terms of this collective agreement) is established by the Hospital, the Hospital shall determine the rate of pay for such new classification and notify the local Union of the same. If the local Union challenges the rate, it shall have the right to request a meeting with the Hospital to endeavour to negotiate a mutually satisfactory rate. Such request will be made within ten (10) days after the receipt of notice from the Hospital of such new occupational classification and rate. Any change mutually agreed to resulting from such meeting shall be retroactive to the date that notice of the new rate was given by the Hospital. If the parties are unable to agree, the dispute concerning the new rate may be submitted to arbitration as provided in the agreement within fifteen (15) days of such meeting. The decision of the arbitrator (or board of arbitration as the case may be) shall be based on the relationship established by comparison with the rates for other classifications in the bargaining unit having regard to the requirements of such classification. When the Hospital makes a substantial change in the job content of an existing classification which in reality causes such classification to become a new classification, the Hospital agrees to meet with the Union if requested to permit the Union to make representation with respect to the appropriate rate of pay. If the matter is not resolved following the meeting with the Union, the matter may be referred to arbitration as provided in the agreement within fifteen (15) days of such meeting. The decision of the arbitrator (or board of arbitration as the case may be) shall be based on the relationship established by comparison with the rates for other classifications in the bargaining unit having regard to the requirements of such classifications. The parties further agree that any change mutually agreed to or awarded as a result of arbitration shall be retroactive only to the date that the Union raised the issue with the Hospital. The parties further agree that the above process as provided herein shall constitute the process for Pay Equity Maintenance as required by the Pay Equity Act.
Description of Goods or Services and Additional Terms and Conditions The Contractor shall perform as set forth in Exhibit A. For purposes of this Contract, to perform and the performance in Exhibit A is referred to as “Perform” and the “Performance.”
