Vendor’s Specific Warranties, Terms, and License Agreements Because TIPS serves public entities and non-profits throughout the nation all of which are subject to specific laws and policies of their jurisdiction, as a matter of standard practice, TIPS does not typically accept a Vendor’s specific “Sale Terms” (warranties, license agreements, master agreements, terms and conditions, etc.) on behalf of all TIPS Members. TIPS may permit Vendor to attach those to this Agreement to display to interested customers what terms may apply to their Supplemental Agreement with Vendor (if submitted by Vendor for that purpose). However, unless this term of the Agreement is negotiated and modified to state otherwise, those specific Sale Terms are not accepted by TIPS on behalf of all TIPS Members and each Member may choose whether to accept, negotiate, or reject those specific Sale Terms, which must be reflected in a separate agreement between Vendor and the Member in order to be effective.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Penalties for Non-compliance to Service Level Agreement Where the Supplier/Service Provider fails to deliver the Goods/Services within the agreed and accepted milestone timelines and provided that the cause of the delay was not due to a fault of Transnet, penalties shall be imposed at …………………………………………………… .
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
SUPPLIER’S WARRANTIES 16.1 The Supplier represents, warrants and undertakes to the Authority that:
16.1.1 the Supplier has the full right, power and authority to enter into and perform this Agreement and to grant all of the Authority Rights to the Authority and for the Authority to use and exploit the same as contemplated in this Agreement;
16.1.2 all information, representations, warranties and other matters of fact contained in the Supplier’s tender submission as part of the competitive tender process referred to in the recitals to this Agreement are true, complete and accurate in all respects and the Supplier agrees to be bound by the obligations and statements made in such tender submission as if the same were set out in this Agreement, save where there is any inconsistency between the terms of this Agreement and such tender submission the terms of this Agreement shall prevail;
16.1.3 save in respect of any Third Party Content, no Deliverable has and no Deliverable will have been broadcast, released or otherwise exploited in any Broadcast Media anywhere in the world prior to the relevant Delivery Date;
16.1.4 there is no contract or arrangement to which the Supplier is a party and the Supplier will not enter into any contract or arrangement and there is and will be no other encumbrance or restriction which could in any way interfere with or inhibit the full exercise or exploitation of any and all of the Authority Rights by the Authority;
16.1.5 the Supplier has paid and shall promptly pay all sums due to any person who is or may be entitled to any payment in respect of services or facilities rendered or goods supplied or rights granted in connection with the Deliverables or on the exercise by the Authority of any of the Authority Rights or in respect of any tax, duty, levy, national insurance or any similar payment in connection with the Deliverables required to be made by the Supplier;
16.1.6 the Supplier will have, by and as at the relevant Delivery Date, obtained all necessary consents, grants, clearances and rights (including any rights in musical compositions contained within the Deliverables (if any) which are controlled by the Performing Right Society or its affiliated bodies) to enable it to produce and deliver the Deliverables and to grant to and enable the Authority to exercise the Authority Rights free from any liens, claims and encumbrances;
16.1.7 to the extent any musical compositions are contained in the Deliverables:
16.1.7.1 all recording synchronisation and dubbing licences have been obtained and licence fees have been paid; and
16.1.7.2 the performing rights in such compositions shall throughout the Term be controlled (i) by the Performing Right Society or its affiliated bodies; or (ii) by the Supplier; or (iii) are in the public domain, in all cases to the extent required for the purposes of the Authority's full exercise of its rights as contemplated by this Agreement;
16.1.8 no claim or litigation is pending or threatened in respect of the Deliverables or any the Authority Rights;
16.1.9 the Deliverables will be produced in accordance with all Laws (including with respect to health and safety);
16.1.10 the Deliverables will be free from all Viruses;
16.1.11 the Deliverables will not contain anything which is in contravention of the Codes and Guidelines or any Laws or which is obscene, blasphemous, seditious, racially inflammatory, defamatory or which infringes the rights of any person, including rights of copyright or trade marks or service marks, privacy, publicity or confidentiality or any other civil or common law or statutory right whatsoever or breaches any contract or is in contempt of court;
16.1.12 the Supplier has not entered and will not enter into any co-production, co-financing, pre-sale or other arrangement or agreement which involves the surrender by the Supplier of any control of the Deliverables;
16.1.13 all information, records and data provided to the Authority and with respect to the Deliverables and the production process will be accurate in all respects, full and up to date;
16.1.14 the Supplier is not insolvent nor unable to pay its debts as they fall due and no steps have been taken with a view to the winding-up or administration of the Supplier or the making of any composition or arrangement with any creditors of the Supplier; and
16.1.15 the Supplier will not at any time do or say anything which is or may be considered by the Authority (acting reasonably) to be detrimental or prejudicial to or to affect adversely the name, image, reputation or business of the Authority or otherwise to bring the Authority or any member of the Authority Group into disrepute.
16.2 The Supplier's warranties shall be deemed repeated on each Delivery Date (or, if any Deliverables are delivered to the Authority after the scheduled Delivery Date and the Authority has not exercised any right under this Agreement to treat such delay as an Event of Default under clause 27.1, within ten Working Days of the date of actual delivery) and on every occasion when the Authority exercises its Authority Rights.
Manufacturer’s Warranties If a Lease Vehicle is covered by a Manufacturer’s warranty, the Lessee, during the Vehicle Term for such Lease Vehicle, shall have the right to make any claims under such warranty that the Lessor could make.
Representations, Warranties and Covenants of the Special Servicer (a) The Special Servicer hereby represents and warrants to, and covenants with, the Trustee, for its own benefit and the benefit of the Certificateholders and the Serviced Companion Loan Holders, and to and with the Depositor, the Master Servicer, the Operating Advisor, the Asset Representations Reviewer and the Certificate Administrator, as of the Closing Date, that:
(i) The Special Servicer is a limited liability company, duly organized, validly existing and in good standing under the laws of the State of Delaware, and the Special Servicer is in compliance with the laws of each jurisdiction in which a Mortgaged Property is located to the extent necessary to perform its obligations under this Agreement;
(ii) The execution and delivery of this Agreement by the Special Servicer do not, and the performance and compliance with the terms of this Agreement by the Special Servicer will not, (A) violate the Special Servicer’s organizational documents or by-laws or (B) constitute a default (or an event that, with notice or lapse of time, or both, would constitute a default) under, or result in the breach of, any material agreement or other material instrument to which it is a party or that is applicable to it or any of its assets, in each case, which does or is likely to materially and adversely affect either the ability of the Special Servicer to perform its obligations under this Agreement or the financial condition of the Special Servicer;
(iii) The Special Servicer has the full power and authority to enter into and consummate all transactions to be performed by it as contemplated by this Agreement, has duly authorized the execution, delivery and performance of this Agreement, and has duly executed and delivered this Agreement;
(iv) This Agreement, assuming due authorization, execution and delivery by each of the other parties hereto, constitutes a valid, legal and binding obligation of the Special Servicer, enforceable against the Special Servicer in accordance with the terms hereof, subject to (A) applicable bankruptcy, receivership, insolvency, liquidation, fraudulent transfer, reorganization, moratorium and other laws affecting the enforcement of creditors’ (including bank creditors’) rights generally, (B) general principles of equity, regardless of whether such enforcement is considered in a proceeding in equity or at law and (C) public policy considerations regarding the enforceability of provisions providing or purporting to provide indemnification or contribution with respect to violations of securities laws;
(v) The Special Servicer is not in violation of, and its execution and delivery of this Agreement do not, and its performance and compliance with the terms of this Agreement will not, constitute a violation of, any law, any order or decree of any court or arbiter, or any order, regulation or demand of any federal, state or local governmental or regulatory authority, which violation, in the Special Servicer’s good faith and reasonable judgment, is likely to affect materially and adversely either the ability of the Special Servicer to perform its obligations under this Agreement or the financial condition of the Special Servicer;
(vi) No litigation is pending or, to the best of the Special Servicer’s knowledge, threatened against the Special Servicer that would prohibit the Special Servicer from entering into this Agreement or, in the Special Servicer’s good faith and reasonable judgment, is likely to materially and adversely affect either the ability of the Special Servicer to perform its obligations under this Agreement or the financial condition of the Special Servicer;
(vii) Each officer or employee of the Special Servicer that has or, following a transfer of servicing responsibilities to the Special Servicer pursuant to Section 3.22 of this Agreement, would have, responsibilities concerning the servicing and administration of Mortgage Loans and Serviced Companion Loans is covered by errors and omissions insurance in the amounts and with the coverage required by Section 3.08(c) of this Agreement or the Special Servicer self-insures for such errors and omissions coverage in compliance with the requirements of Section 3.08(c) of this Agreement; and
(viii) No consent, approval, authorization or order of, or filing or registration with, any state or federal court or governmental agency or body is required for the consummation by the Special Servicer of the transactions contemplated by this Agreement, except for those consents, approvals, authorizations and orders that previously have been obtained and those filings and registrations that previously have been completed and except for consents, approvals, authorizations, orders, filings or registrations which are not required in order for the Special Servicer to enter into this Agreement but may be required (and if so required, will be obtained) in connection with the Special Servicer’s subsequent performance of this Agreement.
(b) The representations and warranties set forth in paragraph (a) above shall survive the execution and delivery of this Agreement. Upon discovery by the Depositor, the Master Servicer, the Special Servicer or a Responsible Officer of the Trustee or the Certificate Administrator (or upon written notice thereof from any Certificateholder or any Serviced Companion Loan Holder) of a breach of any of the representations and warranties set forth in this Section which materially and adversely affects the interests of any party to this Agreement, the Certificateholders or any Serviced Companion Loan Holder or the interests of the Master Servicer, the Special Servicer or the Trustee in any Mortgage Loan, the party discovering such breach shall give prompt written notice to the other parties hereto, each Certifying Certificateholder, the Serviced Companion Loan Holders and, prior to the occurrence and continuance of a Consultation Termination Event, the Controlling Class Representative.
Nonsurvival of Representations, Warranties and Agreements None of the representations, warranties, covenants and agreements in this Agreement or in any instrument delivered pursuant to this Agreement shall survive the Effective Time, except for those covenants and agreements contained herein and therein which by their terms apply in whole or in part after the Effective Time.
Incorporation of Representations and Warranties From Credit Agreement The representations and warranties contained in Section 5 of the Credit Agreement are and will be true, correct and complete in all material respects on and as of the First Amendment Effective Date to the same extent as though made on and as of that date, except to the extent such representations and warranties specifically relate to an earlier date, in which case they were true, correct and complete in all material respects on and as of such earlier date.
Non-Survival of Representations, Warranties and Agreements None of the representations, warranties, covenants and other agreements in this Agreement or in any instrument delivered pursuant to this Agreement, including any rights arising out of any breach of such representations, warranties, covenants and other agreements, shall survive the Effective Time, except for those covenants and agreements contained herein and therein that by their terms apply or are to be performed in whole or in part after the Effective Time and this Article VIII.
