Cloud Computing State Risk and Authorization Management Program In accordance with Senate Bill 475, Acts 2021, 87th Leg., R.S., pursuant to Texas Government Code, Section 2054.0593, Contractor acknowledges and agrees that, if providing cloud computing services for System Agency, Contractor must comply with the requirements of the state risk and authorization management program and that System Agency may not enter or renew a contract with Contractor to purchase cloud computing services for the agency that are subject to the state risk and authorization management program unless Contractor demonstrates compliance with program requirements. If providing cloud computing services for System Agency that are subject to the state risk and authorization management program, Contractor certifies it will maintain program compliance and certification throughout the term of the Contract.
HHSC and Contractor Agreements HHSC and Contractor hereby agree:
A. That in the event any provision of this Contract becomes unenforceable or void all other provisions of this Contract will remain ineffect.
B. That the Contractor may not transfer or assign this Contract without the express prior written approval of HHSC.
C. That this Contract may be assigned to a state agency or agencies.
D. That HHSC may amend this Contract by written notice to the Contractor. HHSC reserves the right to amend this Contract through execution of a unilateral amendment signed by an HHSC person with delegated signature authority and provided to the Contractor under the following circumstances:
1. to correct an obvious clerical error in the Contract;
2. to incorporate new or revised federal or state statutes, rules or policies;
3. to comply with a court order or judgment; and
4. to change the name of the Contractor to reflect the Contractor's name as recorded by the Texas Secretary of State.
E. That nothing in this Contract or any conduct by a representative of HHSC relating to this Contract shall be construed as a waiver of the state's sovereign immunity to suit.
F. That neither party to this Contract waives its right to enforce a right under this Contract by failing to enforce or delaying the enforcement of any other right under this Contract.
G. That the Contractor is an independent contractor and not an employee of HHSC for any purpose. The Contractor and HHSC agreethat:
1. HHSC will not withhold or pay on behalf of the Contractor any sums for income tax, unemployment insurance, Social Security or any other withholding, or make available to the Contractor any of the benefits, including workers' compensation insurance coverage and health and retirement benefits, afforded to HHSC employees; and
2. the Contractor must indemnify HHSC from any liability, including attorneys' fees and legal expenses, incurred by HHSC with respect to claims that HHSC should have been withholding or making payments on behalf of the Contractor or providing benefits to the Contractor's employees.
H. That nothing in this Contract is intended to create a joint venture, a partnership or a principal-agent relationship.
I. That the Contractor assigns to HHSC all claims for overcharges associated with this Contract arising under the anti-trust laws of the United States, 15 U.S.C. §§ 1-38, or the anti-trust laws of the state of Texas, Tex. Bus. & Com. Code, §§ 15.01-.40.
J. That HHSC has authority to monitor and conduct fiscal and program compliance reviews of the Contractor and its subcontractor(s) to the extent of services provided under the terms of this Contract. The Contractor will grant on-site access at reasonable times to all records relating to services provided and payments received under the terms of this Contract to state and federal auditing agencies and personnel and representatives of HHSC and HHS when it is deemed necessary by such agencies for purposes of inspection, monitoring, auditing or evaluating Contractor's performance under this Contract and compliance with applicable state and federal laws, rules and regulations; the applicable HHSC provider handbook or manual; and this Contract. That for Title XX programs, HHSC shall, by Form 2029, Information Worksheet – POS Contract, set the rate or maximum amount of funds or both available to be paid to Contractor by HHSC. Form 2029 is incorporated into and made a part of this Contract and is effective for the time stated on the form. Form 2029 may be amended by HHSC as necessary to comply with state and federal laws and regulations or renewed by HHSC by a new Form 2029 and incorporated into and made part of this Contract.
K. That in compliance with §2262.003, Texas Government Code:
1. the state auditor may conduct an audit or investigation of any entity receiving funds from the state directly under the Contract or indirectly through a subcontract under the Contract;
2. acceptance of funds directly under the Contract or indirectly through a subcontract under the Contract acts as acceptance of the authority of the state auditor, under the direction of the legislative audit committee, to conduct an audit or investigation in connection with those funds; and
3. under the direction of the legislative audit committee, an entity that is the subject of an audit or investigation by the state auditor must provide the state auditor with access to any information the state auditor considers relevant to the investigation or audit.
L. That this Contract shall continue subject to the availability of appropriated funds or until the federal or state governments or both cease to participate in the program.
M. That any breach or violation of any of the provisions of this Contract or state or federal regulations shall make this entire Contract, at HHSC's option, subject to termination.
N. That if HHSC does not renew the Contractor's contract due to the Contractor's noncompliance with applicable federal or Texas statutes or rules, the Contractor cannot enter into another contract for a Community Services program until the application denial period established by HHSC expires.
O. That the venue for any lawsuit between HHSC and the Contractor shall be Travis County, Texas.
P. That this Contract may be terminated by:
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms.
b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage.
c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications.
d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders.
e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims.
f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc.
g. Assist in community outreach meetings and media relations
h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Management and Control Systems Grantee will:
1. maintain an appropriate contract administration system to ensure that all terms, conditions, and specifications are met during the term of the contract through the completion of the closeout procedures.
2. develop, implement, and maintain financial management and control systems that meet or exceed the requirements of Uniform Statewide Accounting System (UGMS). Those requirements and procedures include, at a minimum, the following:
i. Financial planning, including the development of budgets that adequately reflect all functions and resources necessary to carry out authorized activities and the adequate determination of costs;
ii. Financial management systems that include accurate accounting records that are accessible and identify the source and application of funds provided under each Contract of this Contract, and original source documentation substantiating that costs are specifically and solely allocable to a Contract and its Contract and are traceable from the transaction to the general ledger;
iii. Effective internal and budgetary controls;
iv. Comparison of actual costs to budget; determination of reasonableness, allowableness, and allocability of costs;
v. Timely and appropriate audits and resolution of any findings;
vi. Billing and collection policies; and
vii. Mechanism capable of billing and making reasonable efforts to collect from clients and third parties.
STUDENTS AND APPRENTICES Payments which a student or business apprentice who is or was immediately before visiting a Contracting State a resident of the other Contracting State and who is present in the first-mentioned State solely for the purpose of his education or training receives for the purpose of his maintenance, education or training shall not be taxed in that State, provided that such payments arise from sources outside that State.
Management and Control (a) Management and control of the business of the Fund shall be vested in the Board, which shall have the right, power, and authority, on behalf of the Fund and in its name, to exercise all rights, powers, and authority of managers under the Delaware Act and to do all things necessary and proper to carry out the objective and business of the Fund and their duties hereunder. No Manager shall have the authority individually to act on behalf of or to bind the Fund except within the scope of such Manager's authority as delegated by the Board. The parties hereto intend that, except to the extent otherwise expressly provided herein, (i) each Manager shall be vested with the same powers, authority, and responsibilities on behalf of the Fund as are customarily vested in each director of a Delaware corporation and (ii) each Independent Manager shall be vested with the same powers, authority and responsibilities on behalf of the Fund as are customarily vested in each director of a closed-end Management investment company registered under the 1940 Act that is organized as a Delaware corporation who is not an "interested person" of such company, as such term is defined by the 1940 Act. During any period in which the Fund shall have no Managers, CSFB Alternative Capital, as the initial Member, shall have the authority to manage the business and affairs of the Fund.
(b) Members, in their capacity as Members, shall have no right to participate in and shall take no part in the management or control of the Fund's business and shall have no right, power or authority to act for or bind the Fund. Members shall have the right to vote on any matters only as provided in this Agreement or on any matters that require the approval of the holders of voting securities under the 1940 Act or as otherwise required in the Delaware Act.
(c) The Board may delegate to any other person any rights, power and authority vested by this Agreement in the Board to the extent permissible under applicable law, and may appoint persons to serve as officers of the Fund, with such titles and authority as may be determined by the Board consistent with applicable law.
(d) The Board shall have full power and authority to adopt By-Laws providing for the conduct of the business of the Fund and containing such other provisions as they deem necessary, appropriate or desirable, and, subject to the voting powers of one or more Classes created pursuant to this section 3.1, to amend and repeal such By-Laws. Unless the By-Laws specifically require that Members authorize or approve the amendment or repeal of a particular provision of the By-Laws, any provision of the By-Laws may be amended or repealed by the Board without Member authorization or approval.
(e) The Board shall have the full power and authority, without Member approval, to authorize one or more Classes of Units; Units of each such Class having such preferences, voting powers and special or relative rights or privileges (including conversion rights, if any) as the Board may determine and as shall be set forth in a resolution adopted in accordance with the By-Laws.
Quality Management System Supplier hereby undertakes, warrants and confirms, and will ensue same for its subcontractors, to remain certified in accordance with ISO 9001 standard or equivalent. At any time during the term of this Agreement, the Supplier shall, if so instructed by ISR, provide evidence of such certifications. In any event, Supplier must notify ISR, in writing, in the event said certification is suspended and/or canceled and/or not continued.
Procurement of Small Works Works estimated to cost $250,000 equivalent or less per contract, up to an aggregate amount not to exceed $800,000 equivalent, may be procured under lump-sum, fixed-price contracts awarded on the basis of quotations obtained from three (3) qualified domestic contractors in response to a written invitation. The invitation shall include a detailed description of the works, including basic specifications, the required completion date, a basic form of agreement acceptable to the Bank, and relevant drawings, where applicable. The award shall be made to the contractor who offers the lowest price quotation for the required work, and who has the experience and resources to complete the contract successfully. Part D: Review by the Bank of Procurement Decisions
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Provisions governing staff and subcontractors A. To require any subcontractor to execute documents that binds the subcontractor to comply with the provisions of this Contract. Subcontractor means an individual or entity to which the Contractor has contracted with or delegated some of its management functions or responsibilities of providing all or a part of the services required of the Contractor under this Contract.
B. That it is responsible for the behavior of its staff and subcontractors to ensure a violence-free contractual relationship. The Contractor understands that any remarks, gestures or actions toward HHSC employees, volunteers or clients that carry an implied threat of any kind, even if intended to be in jest, will be taken seriously and may lead to corrective action, up to and including terminating this contractor.
C. To comply with the requirements of the Immigration Reform and Control Act of 1986 regarding employment verification and retention of verification forms for an individual hired on or after November 6, 1986, who will perform any labor or services under this Contract.
D. To certify and ensure that it utilizes and will continue to utilize, for the term of this Contract, the U. S. Department of Homeland Security's e- Verify system to determine the eligibility of:
1. all people employed during the Contract term to perform duties within Texas; and
2. all people (including subcontractors).
E. That representatives of HHSC, AG-MFCU and HHS may conduct interviews of Contractor personnel, subcontractors and their personnel, witnesses, and clients without a Contractor's representative present unless the person interviewed voluntarily requests that the representative be present. The Contractor must not coerce its personnel, subcontractors and their personnel, witnesses, or clients to accept representation by the Contractor, and the Contractor agrees that no retaliation will occur to a person who denies the Contractor's offer of representation. Nothing in the Contract limits a person's right to counsel of his or her choice. Requests for interviews are to be complied with in the form and the manner requested. The Contractor must ensure by contract or other means that its personnel and subcontractors cooperate fully in any investigation conducted by representatives of HHSC, AG-MFCU and HHS.
F. That if it is a Home and Community Support Services agency ("HCSSA"), the Contractor will hire Personal Assistance Services and Community Support Services providers chosen by the client or the client's legally authorized representative, if requested, and provided the individual who will provide the services:
1. meets minimum qualifications for the service;
2. is willing to be employed as an attendant by the Contractor; and
3. is willing, and determined competent by the Contractor, to deliver the service(s) according to the client's individual service plan.
