Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
ADJUSTMENT OF THE DISTRIBUTOR’S ALLOCABLE PORTION AND EACH SUCCESSOR DISTRIBUTOR’S ALLOCABLE PORTION The parties to the Distribution Agreement recognize that, if the terms of any distributor’s contract, any distribution plan, any prospectus, the FINRA Conduct Rules or any other applicable law change so as to disproportionately reduce, in a manner inconsistent with the intent of this Distribution Agreement, the amount of the Distributor’s Allocable Portion or any Successor Distributor’s Allocable Portion had no such change occurred, the definitions of the Distributor’s Allocable Portion and/or the Successor Distributor’s Allocable Portion in respect of the Class C shares relating to a Fund shall be adjusted by agreement among the relevant parties; provided, however, if the Distributor, the Successor Distributor and the Fund cannot agree within thirty (30) days after the date of any such change in applicable laws or in any distributor’s contract, distribution plan, prospectus or the FINRA Conduct Rules, they shall submit the question to arbitration in accordance with the commercial arbitration rules of the American Arbitration Association and the decision reached by the arbitrator shall be final and binding on each of them. The following relates solely to Class 529-C shares. The Distributor’s Allocable Portion of Distribution Fees and CDSCs in respect of Class 529-C shares shall be 100% until such time as the Distributor shall cease to serve as exclusive distributor of Class 529-C shares; thereafter, collections that constitute CDSCs and Distribution Fees relating to Class 529-C shares shall be allocated among the Distributor and any successor distributor (“Successor Distributor”) in accordance with this Schedule. At such time as the Distributor’s Allocable Portion of the Distribution Fees equals zero, the Successor Distributor shall become the Distributor for purposes of this Allocation Schedule. Defined terms used in this Schedule and not otherwise defined herein shall have the meanings assigned to them in the Principal Underwriting Agreement (the “Distribution Agreement”), of which this Schedule is a part. As used herein the following terms shall have the meanings indicated:
Right to Proceed The Sponsor acknowledges the rights of Holders to institute a Direct Action as set forth in Section 2.8(d) hereto.
Cost Responsibility for Interconnection Facilities and Distribution Upgrades 4.1 Interconnection Facilities 4.2 Distribution Upgrades
Additional Access Rights For the avoidance of doubt any grant of Access Rights not covered by the Grant Agreement or this Consortium Agreement shall be at the absolute discretion of the owning Party and subject to such terms and conditions as may be agreed between the owning and receiving Parties.
Right to Insure The Company shall have the right to secure, in its own name or otherwise, and at its own expense, life, health, accident or other insurance covering Executive, and Executive shall have no right, title or interest in and to such insurance. Executive shall assist the Company in procuring such insurance by submitting to examinations and by signing such applications and other instruments as may be required by the insurance carriers to which application is made for any such insurance.
Right to Access the right to request (i) copies of the information we hold about you at any time, or (ii) that we modify, update or delete such information. If we provide you with access to the information we hold about you, we will not charge you for this, unless your request is “manifestly unfounded or excessive.” Where we are legally permitted to do so, we may refuse your request. If we refuse your request, we will tell you the reasons why.
Reactive Power and Primary Frequency Response 9.6.1 Power Factor Design Criteria
