Obligations relating to Change in Ownership 5.3.1 The Concessionaire shall not undertake or permit any Change in Ownership, except with the prior approval of the Authority.
Existing utilities and roads Notwithstanding anything to the contrary contained herein, the Concessionaire shall ensure that the respective entities owning the existing roads, right of way or utilities on, under or above the Site are enabled by it to keep such utilities in continuous satisfactory use, if necessary, by providing suitable temporary or permanent diversions with the authority of the controlling body of that road, right of way or utility, and the Authority shall, upon written request from the Concessionaire, initiate and undertake at the Concessionaire’s cost, legal proceedings for acquisition of any right of way necessary for such diversion.
New utilities and roads 11.3.1 The Concessionaire shall allow, subject to such conditions as the Authority may specify, access to, and use of the Site for laying telephone lines, water pipes, electric cables or other public utilities. Where such access or use causes any financial loss to the Concessionaire, it may require the user of the Site to pay compensation or damages as per Applicable Laws. For the avoidance of doubt, it is agreed that use of the Site under this Clause shall not in any manner relieve the Concessionaire of its obligation to maintain the Bus Terminal in accordance with this Agreement and any damage caused by such use shall be restored forthwith.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
Insurance, Subcontractor's Public Liability and Property Damage The Contractor shall require each of its subcontractors to secure and maintain during the life of the subcontract, insurance of the type specified in this Contract, or, the Contractor may insure the activities of its subcontractors in the Contractor’s policy, as specified in this Contract.
Shifting of obstructing utilities The Concessionaire shall, subject to Applicable Laws and with assistance of the Authority, undertake shifting of any utility including electric lines, water pipes and telephone cables, to an appropriate location or alignment within or outside the Site if and only if such utility causes or shall cause a material adverse effect on the construction, operation or maintenance of the Project. The cost of such shifting shall be borne by the Authority or by the entity owning such utility, if the Authority so directs, and in the event of any delay in shifting thereof, the Concessionaire shall be excused for failure to perform any of its obligations hereunder if such failure is a direct consequence of delay on the part of the entity owning such electric lines, water pipes or telephone cables, as the case may be.
Goods, Standards and Appurtenances Any Goods delivered must be standard new Goods, latest model, except as otherwise specifically stated in the Contract. Remanufactured, refurbished or reconditioned equipment may be accepted but only to the extent allowed under the Contract. Where the Contract does not specifically list or describe any parts or nominal appurtenances of equipment for the Goods, it shall be understood that the Contractor shall deliver such equipment and appurtenances as are usually provided with the manufacturer's stock model.
Legal Action; Utilization of Special Receivership Powers The Assuming Institution shall notify the Receiver in writing (such notice to be given in accordance with Article V below and to include all relevant details) prior to utilizing in any legal action any special legal power or right which the Assuming Institution derives as a result of having acquired an asset from the Receiver, and the Assuming Institution shall not utilize any such power unless the Receiver shall have consented in writing to the proposed usage. The Receiver shall have the right to direct such proposed usage by the Assuming Institution and the Assuming Institution shall comply in all respects with such direction. Upon request of the Receiver, the Assuming Institution will advise the Receiver as to the status of any such legal action. The Assuming Institution shall immediately notify the Receiver of any judgment in litigation involving any of the aforesaid special powers or rights.
Services and Utilities Landlord shall furnish all normal services and utilities such as elevator service, lighting replacement for building standard lights, restroom supplies, window washing, janitorial services, heating, ventilation and air conditioning (“HVAC”) maintenance, landscape maintenance, parking lot sweeping, pest control services, and fire alarm monitoring (if installed and required) in a manner that such services are customarily furnished to comparable office buildings in the area. Landlord shall also provide water, sewer, electric, gas and trash removal services to the building as required. Provided that Tenant is not in default hereunder, Landlord agrees to furnish to the Premises at all times , electricity for normal desk top office equipment, .normal copying equipment, technical equipment, and “HVAC” as is reasonably required for the comfortable use and occupancy of the Premises. The normally recognized business hours for the Building are as follows: 7:00 am to 6:00 pm Monday through Friday (except Holidays), and 8:00 am to 1:00 p.m. on Saturdays. If Tenant desires HVAC and/or electricity at any other time, Tenant may override the HVAC and/or electricity system for additional heating, cooling or electricity outside of the normal business hours. Such additional HVAC and/or electricity usage shall be electronically monitored, and Tenant shall pay Landlord’s direct charges therefore on demand. Landlord shall also maintain and keep lighted the common stairs, common entries and restrooms in the Building. Landlord shall not be in default hereunder or be liable for any damages directly or indirectly resulting from, nor shall the Rent be abated by reason of (i) the installation, use or interruption of use of any equipment in connection with the furnishing of any of the foregoing services, (ii) failure to furnish or delay in furnishing any such services where such failure or delay is caused by accident or any condition or event beyond the reasonable control of Landlord, or by the making of necessary repairs or improvements to the Premises, Building or Project, or (iii) the limitation, curtailment or rationing of, or restrictions on, use of water, electricity, gas or any other form of energy serving the Premises, Building or Project, which has been imposed upon the Landlord. Landlord shall not be liable except where Landlord is found to be grossly negligent for a loss of or injury to property or business, however occurring, through or in connection with or incidental to failure to furnish any such services. If Tenant uses heat generating machines or equipment in the Premises which affect the temperature otherwise maintained by the HVAC system, Landlord reserves the right to install supplementary air conditioning units in the Premises and the cost thereof, including the cost of installation, operation and maintenance thereof, shall be paid by Tenant to Landlord upon demand by Landlord. Should Tenant consume water or electric current in excess of that usually furnished or supplied for the use of premises as general office space Landlord may have installed a water meter or electrical current meter in the Premises to measure the amount of water or electric current consumed. The cost of any such meter and its installation, maintenance and repair shall be paid for by the Tenant and Tenant agrees to pay to Landlord promptly upon demand for all such water and electric current consumed as shown by said meters, at the rates charged for such services by the local public utility. If a separate meter is not installed, the excess cost for such water and electric current shall be established by an estimate made by a utility company or an electrical engineer hired jointly by Landlord and Tenant and at Tenant’s expense. Nothing contained in this Section shall restrict Landlord’s right to require at any time separate metering of utilities furnished to the Premises. In the event utilities are separately metered, Tenant shall pay promptly upon demand for all utilities consumed at utility rates charged by the local public utility plus any additional expense incurred by Landlord in keeping account of the utilities so consumed. Tenant shall be responsible for the maintenance and repair of any such meters at its sole cost.
Technical Standards Applicable to a Wind Generating Plant i. Low Voltage Ride-Through (LVRT) Capability A wind generating plant shall be able to remain online during voltage disturbances up to the time periods and associated voltage levels set forth in the standard below. The LVRT standard provides for a transition period standard and a post-transition period standard.
