Rights and Term. ALZA would be granted the exclusive right (including the right to sublicense such right to a third party) to market the Product in the Territory. Upon receipt of regulatory approvals, ALZA would use commercially reasonable efforts (consistent with the efforts ALZA devotes to products of similar market potential and in similar product lifecycle positions and based on conditions then prevailing with respect to the applicable Product and the relevant markets) to commence and continue diligent commercialization of the Product during the term of the Agreement. The term of the Agreement would be for the commercial life of the Product.

Rights and Term is hereby amended to read in its entirety as follows (bracketed wording has been deleted and added wording has been underlined):

Rights and Term. SPONSOR to be the exclusive official sponsor of the WEC and shall have the rights to sponsor seven (7) World Extreme Cagefighting events (“Event(s)”) as aired on the Versus network in 2010 within the continental US (or similarly distributed North American cable/satellite network in the event the Event(s) are not broadcast on Versus in 2010, but not including pay-per-view distribution). SPONSOR will be referred to in-arena as the “Official Nutritional Supplement Company of the WEC” and shall have further rights to market its products as the “Official Sponsor,” “Official Partner,” or another term mutually agreed upon by the parties. For the avoidance of doubt and in furtherance to paragraph 4 of this Agreement, it is understood that all uses of “Official Sponsor” on any products, advertising or marketing must be pre-approved in writing by WEC. SPONSOR shall have exclusive sponsorship of WEC Event(s) in the Nutritional Supplement Category and have a non-exclusive, limited license to use prior-approved WEC trademarks and the fact of its sponsorship (including sponsorship taglines) in connection with the sales of SPONSOR’s products. The grant of Sponsorship Rights under this Agreement are solely limited to the WEC brand and the Sponsorship Rights do not extend to any other mixed martial arts organizations or brands now or at any time in the future affiliated with WEC, including and not limited to Ultimate Fighting Championship® or Pride Fighting Championship®. This Agreement does not include any other category of sponsorship and is limited exclusively to Nutritional Supplements. This Agreement shall terminate on the seventh Event(s) that Sponsor’s logo is displayed or December 31, 2010, whichever is earlier (the “Term”).

Rights and Term. Upon receipt of regulatory approvals, BioMedicines will proceed with diligence to commence and continue diligent commercialization of the Product during the term of the Agreement as follows: Basic Term: BioMedicines will be granted the exclusive right to market the Product until (i) in each of Subterritories A, B, and C, [ * ] after the first commercial sale of the Product in the first Major Market Country of such Subterritory, and (ii) in Subterritory D, [ * ] after the first commercial sale of the Product in the first Major Market Country anywhere in the Territory. BioMedicines shall have the right to assign or transfer such right to a third party, subject to ALZA’s approval, such approval not to be unreasonably withheld (it being understood that reasonable bases for withholding such approval shall include, without limitation, a transfer to a competitor of ALZA in the drug delivery business, a transfer to a company with whom ALZA is engaged in significant litigation, or any other legitimate business reason). *France, Germany, Italy, Japan, United Kingdom and United States.

Related to Rights and Term

Grant and Term 2.1 In consideration of the payment of the Site Fee, the Owner grants the Principal Occupant a licence to store the Dwelling on the Site subject to the terms of this Agreement. 2.2 This Agreement commences on the Commencement Date and shall continue until the Expiry Date or such earlier date upon which it is terminated in accordance with this Agreement or as specified in the Schedule. 2.3 For the avoidance of doubt, the Owner and the Principal Occupant acknowledge that they each enter into this Agreement based on their common intention that the Site is to be used for storing the Dwelling for the Term and that the use of the Dwelling by the Occupants as permitted by this Agreement shall be for holidaying purposes only and under no circumstances shall any person who has the right to use the Site under this Agreement be or become a resident or a site tenant within the meaning of the Residential Tenancies Act 1997 (Vic).
Agreement and Term This Agreement records the Parties' agreement that:
Terms and Termination (a) Either party may terminate this Agreement without cause on or after July 31, 2002 by giving 180 days written notice to the other party; (b) Either party may terminate this Agreement if the other party has materially breached the Agreement by giving the defaulting party 30 days written notice and the defaulting party has failed to cure the breach within 60 days thereafter; and (c) Any written notice of termination shall specify the date of termination. The Fund shall provide notice of the successor transfer agent within 30 days of the termination date. Upon termination, FDISG will deliver to such successor a certified list of shareholders of the Fund (with names, addresses and taxpayer identification of Social Security numbers and such other federal tax information as FDISG may be required to maintain), an historical record of the account of each shareholder and the status thereof, and all other relevant books, records, correspondence, and other data established or maintained by the books, records, correspondence, and other data established or maintained by FDISG under this Agreement in the form reasonably acceptable to the Fund, and will cooperate in the transfer of such duties and responsibilities, including provisions for assistance from FDISG's personnel in the establishment of books, records and other data by such successor or successors. FDISG shall be entitled to its out-of-pocket expenses set forth in Schedule C incurred in the delivery of such records net of the fees owed to FDISG for the last month of service if this Agreement is terminated pursuant to paragraph (b) immediately above. (d) If a majority of the non-interested trustees of any of the Funds determines, in the exercise of their fiduciary duties and pursuant to their reasonable business judgement after consultation with Eaton Vance Management, that the perxxxxxxxx xf FDISG has been unsatisfactory or adverse to the interests of shareholders of any Fund or Funds or that the terms of the Agreement are no longer consistent with publicly available industry standards, then the Fund or Funds shall give written notice to FDISG of such determination and FDISG shall have 60 days (or such longer period if the non-interested Trustees so determine) to (1) correct such performance to the satisfaction of the non-interested trustees or (2) renegotiate terms which are satisfactory to the non-interested trustees of the Funds. If the conditions of the preceding sentence are not met then the Fund or Funds may terminate this Agreement on sixty (60) days written notice provided, however, that the provisions of Paragraph 11(c) shall remain outstanding for an additional 30 days if necessary to transfer records to a successor transfer agent. (e) If the Board of Trustees hereafter establishes and designates a new Fund, FDISG agrees that it will act as transfer agent and shareholder servicing agent for such new Fund in accordance with the terms set forth herein. The Trustees shall cause a written notice to be sent to FDISG to the effect that it has established a new Fund and that it appoints FDISG as transfer agent and shareholder servicing agent for the new Fund. Such written notice must be received by FDISG in a reasonable period of time prior to the commencement of operations of the new Fund to allow FDISG, in the ordinary course of its business, to prepare to perform its duties.
Premises and Term a. Landlord, in consideration of the Rent hereinafter reserved to be paid and of the covenants, conditions and agreements to be kept and performed by Tenant, hereby leases, lets and demises to Tenant, and Tenant hereby leases and hires from Landlord, the Project. Upon the Commencement Date for Phase 1, Tenant shall be entitled to the exclusive use and occupancy of Phase 1 and that portion of the Parking Area allocated for Phase 1 plus such spaces in addition to the spaces allocated for Phase 1, if any, that may be constructed by Landlord at the time, so long as Tenant’s use of such spaces in addition to the spaces allocated for Phase 1 does not interfere with the construction of the remainder of the Project by Landlord. Upon the Commencement Date for Phase 2, Tenant shall be entitled to the exclusive use and occupancy of Phase 2 and the entire Parking Area, and at which time Tenant will have the exclusive use and occupancy of the entire Project. b. Promptly after the actual Commencement Date for each Phase, the parties shall execute an instrument in which the Commencement Date and expiration date for such Phase will be specified, as well as any adjustments to the Rentable Area of the Premises as described above and any corresponding adjustments to the Base Rent. c. Notwithstanding anything to the contrary contained in this Lease, although Landlord has estimated a completion date for Phase 1 of October 1, 1999, the parties agree that if Landlord has not achieved Substantial Completion of Phase 1 on or before November 1, 1999 (the “Phase 1 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 1999, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 1, such credit to be equal to one (1) day’s Base Rent for Phase 1 for each day of Landlord’s delay beyond the Phase 1 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. d. If Landlord has not achieved Substantial Completion of Phase 1 on or before November 15, 1999 (the “Phase 1 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 1999, the Base Rent credit available to Tenant for Phase 1 shall be increased to two (2) days’ Base Rent for each day of Landlord’s delay beyond the Phase 1 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. e. If Landlord has not achieved Substantial Completion of Phase 1 on or before December 17, 1999 (the “Phase 1 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 1999, (x) the Base Rent credit available to Tenant for Phase 1 shall be decreased back to one (1) day’s Base Rent for each day of Landlord’s delay beyond the Phase 1 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below. f. If Landlord has not achieved Substantial Completion of Phase 1 on or before January 17, 2000 (the “Phase 1 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 1 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. g. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 1 on or before May 17, 2000 (the “Phase 1 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Extended Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2000 and May 1, 2000 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right. h. Although Landlord has estimated a completion date for Phase 2 of October 1, 2001, the parties agree that if Landlord has not achieved Substantial Completion of Phase 2 on or before November 1, 2001 (the “Phase 2 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 2001, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 2, such credit to be equal to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. i. If Landlord has not achieved Substantial Completion of Phase 2 on or before November 15, 2001 (the “Phase 2 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 2001, the Base Rent credit available to Tenant for Phase 2 shall be increased to two (2) days’ Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. j. If Landlord has not achieved Substantial Completion of Phase 2 on or before December 17, 2001 (the “Phase 2 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 2001, (x) the Base Rent credit available to Tenant shall be decreased back to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below. k. If Landlord has not achieved Substantial Completion of Phase 2 on or before January 17, 2002 (the “Phase 2 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 2 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. l. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 2 on or before May 17, 2002 (the “Phase 2 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Extended Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2002 and May 1, 2002 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right. m. The abatements, liquidated damages and termination rights in favor of Tenant as described above shall be Tenant’s sole and exclusive remedies in the event of any late delivery of the Buildings by Landlord, and notwithstanding anything to the contrary contained in this Lease, in no event shall the entire liability of Landlord in connection with the total aggregate amounts of the Base Rent credits, plus the $10,000.00 per day damages, plus the out-of-pocket costs incurred by Tenant exceed a total amount of Seven Hundred Fifty Thousand and No/100 ($750,000.00) Dollars in the aggregate, regardless of the length of time such rent credits, and/or liquidated damages and/or out-of-pocket costs actually accrue and regardless of whether Tenant terminates this Lease. n. Although the completion date for Phase 2 is intended to be October 1, 2001, Tenant may notify Landlord in writing of Tenant’s election to have the Commencement Date for Phase 2 be on October 1, 2000. Tenant must provide such notice no later than April 1, 1999. If Tenant timely provides such notice, then the anticipated Commencement Date for Phase 2 will be deemed to be October 1, 2000, and subparagraphs 2.h through 2.I above will be deemed to be modified as follows: All references to the year “2001” in such subparagraphs will be deemed to be “2000,” and all references to the year “2002” in such subparagraphs will be deemed to be “2001.”
Commencement and Term This Agreement shall commence upon the Effective Date and continue for the Agreement Term.
Appointment and Term The Members will be entitled to appoint from time to time persons to serve as the managers (each, a "Manager") on the Board of Managers. Managers will serve until their respective successors are appointed by the Members, as provided under Section 4.11 herein, or until their earlier death, disability, resignation, retirement or removal, pursuant to Section 4.10 herein. Each Manager is hereby designated as a "manager" of the Company within the meaning of Section 18-101(10) of the Act.
Election and Term The President, Treasurer and Secretary shall, and the Chairman of the Board may, be appointed by and shall hold office at the pleasure of the Manager or the Board. The Manager, the Board, or the President may each appoint such other officers and agents as such person shall deem desirable, who shall hold office at the pleasure of the Manager, the Board, or the President, and who shall have such authority and shall perform such duties as from time to time shall, subject to the provisions of Section 5(d) hereof, be prescribed by the Manager, the Board, or the President.
Purpose and Term The purpose to be conducted or promoted by the Company is to engage solely in the following activities: (a) (i) to engage in any lawful act or activity for which a limited liability company may be organized under the Act, including, but not limited to, owning and operating the Property; (ii) to engage in any other lawful act or activity and to exercise any powers permitted by the Act that are related or incidental to and necessary, convenient or advisable for the accomplishment of the above-mentioned purposes. (b) The term of the Company shall commence on the date the Certificate of Formation was filed with the Secretary of State of the State of Delaware and will continue to the earlier of the date on which the Company is dissolved in accordance with the Act or this Agreement.
Effective Date and Term of Agreement This Agreement is effective and binding on the Company and Employee as of the date hereof; provided, however, that, subject to Section 2(d), the provisions of Sections 3 and 4 shall become operative only upon the Change in Control Date.
Demise and Term A. For and during the term established below, Sublessor leases to Subtenant the Demised Premises, consisting of 362,155 rentable square feet ("RSF of the Demised Premises") of space at the Building. The leasing of the Demised Premises by Subtenant shall include the right of Subtenant (a) to access the Building common areas in common with the other tenants in the Building and (b) to use all fixtures, improvements and 2 betterments owned or leased by Overlandlord which, at any time during the term of this Sublease, are attached to or installed in the Demised Premises, all subject to such restrictions, rules, regulations, security arrangements and charges (if any) as are provided for in the Ovexxxxxx. B. The term (subject to extension as provided herein, the "Term") of this Sublease shall commence on May 19, 2001 (the "Commencement Date ") and expire on November 17, 2021 (the "Expiration Date"), unless sooner canceled or otherwise terminated as provided in this Sublease. C. Sublessor shall have a one time right to cancel this Sublease effective as of May 31, 2011 by giving written notice (the "Sublessor Cancellation Notice") to Subtenant by no later than May 1, 2008, time being of the essence as to the giving of such notice, which notice shall state that Sublessor unconditionally elects to cancel this Sublease effective as of May 31, 2011. In the event Sublessor fails to timely deliver a Sublessor Cancellation Notice in compliance herewith, and unless Subtenant has delivered the Subtenant Cancellation Notice (as hereinafter defined), this Sublease shall continue until the Expiration Date, unless otherwise terminated as provided in this Sublease. In the event Sublessor timely delivers a Sublessor Cancellation Notice in compliance herewith, the Expiration Date as defined herein shall for all purposes mean May 31, 2011. D. Subtenant shall have a one time right to cancel this Sublease effective as of May 31, 2011 by giving written notice (the "Subtenant Cancellation Notice") to Sublessor by no later than April 1, 2008, time being of the essence as to the giving of such notice, which notice shall state that Subtenant unconditionally elects to cancel this Sublease effective as of May 31, 2011. In the event Subtenant fails to timely deliver a Subtenant Cancellation Notice in compliance herewith, and unless Sublessor has delivered the Sublessor Cancellation Notice, this Sublease shall continue until the Expiration Date, unless otherwise terminated as provided in this Sublease. In the event Subtenant timely delivers a Subtenant Cancellation Notice in compliance herewith, the Expiration Date as defined herein shall for all purposes mean May 31, 2011. E. In the event that Sublessor cancels this Sublease pursuant to Article 2.C hereof, Sublessor shall pay to Subtenant, by no later than June 30, 2011, an amount (the "Sales Price") equal to twenty-five percent (25%) of the unamortized value (as of May 31, 2011) of the leasehold improvements (the "Remaining Leasehold Improvements") which remain in the Demised Premises following Subtenant's vacation of the Demised Premises

Rights and Term Sample Clauses

Filter & Search

Related Clauses

Parent Clauses

Related to Rights and Term