Purchaser's Election to Delay Foreclosure Proceedings (a) The Purchaser shall be deemed to direct the Company to direct (to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement) the related Servicer that in the event that the Company does not receive written notice of the Purchaser's election pursuant to subsection (b) below within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01 (a) (ii) subject to extension as set forth in Section 2.02(b), the related Servicer may proceed with the Commencement of Foreclosure in respect of such Mortgage Loan in accordance with its normal foreclosure policies without further notice to the Purchaser. Any foreclosure that has been initiated may be discontinued (i) without notice to the Purchaser if the Mortgage Loan has been brought current or if a refinancing or prepayment occurs with respect to the Mortgage Loan (including by means of a short payoff approved by the related Servicer) or (ii) if the related Servicer has reached the terms of a forbearance agreement with the borrower. In the latter case, the related Servicer may complete such forbearance agreement unless instructed otherwise by the Purchaser within two Business Days notification.
Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Completion of Due Diligence Each Purchaser shall have completed its legal, business and financial due diligence of the Company to its full satisfaction and shall be fully satisfied with the results thereof.
Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Six-Month Delay Notwithstanding anything to the contrary in this Agreement, no compensation or benefits, including without limitation any severance payments or benefits payable under this Section 4, shall be paid to the Executive during the six-month period following the Executive’s Separation from Service if the Company determines that paying such amounts at the time or times indicated in this Agreement would be a prohibited distribution under Section 409A(a)(2)(B)(i) of the Code. If the payment of any such amounts is delayed as a result of the previous sentence, then on the first day of the seventh month following the date of Separation from Service (or such earlier date upon which such amount can be paid under Section 409A without resulting in a prohibited distribution, including as a result of the Executive’s death), the Company shall pay the Executive a lump-sum amount equal to the cumulative amount that would have otherwise been payable to the Executive during such period.
