Exclusion and Limitation of Liability 10.1 SUPPLIER DOES NOT EXCLUDE OR LIMIT ITS LIABILITY (IF ANY) TO BUYER FOR ANY MATTER FOR WHICH IT WOULD BE ILLEGAL FOR SUPPLIER TO EXCLUDE OR LIMIT OR TO ATTEMPT TO EXCLUDE OR LIMIT ITS LIABILITY.
10.2 OTHER THAN ANY LIABILITY OF SUPPLIER ARISING UNDER CLAUSE 10.1, WHICH SHALL NOT BE LIMITED, AND WITHOUT PREJUDICE TO THE OTHER PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY), SUPPLIER'S AGGREGATE LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) UNDER EACH CONTRACT WILL BE LIMITED TO AN AMOUNT EQUAL TO THE GREATER OF 115% OF THE AMOUNT PAID BY BUYER TO SUPPLIER UNDER THAT CONTRACT OR $10,000.00.
10.3 EXCEPT AS PROVIDED IN CLAUSE 10.1, SUPPLIER WILL BE UNDER NO LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) TO BUYER WHATSOEVER IN RESPECT OF
10.3.1 ANY CLAIM ARISING OUT OF AN EVENTWHICH IS CAUSED, OR CONTRIBUTED TO, BY THE GOODS AND SUCH EVENT OCCURS AFTER THE COMMENCEMENT OF THE LAUNCH PROCEDURE OF THE VEHICLE CARRYING SUCH GOODS INTO SPACE;
10.3.2 PURE ECONOMIC LOSS, LOSS OF PROFITS, LOSS OF BUSINESS, LOSS OF REVENUE, LOSS OF CONTRACTS, LOSS OF GOODWILL, LOSS OF ANTICIPATED EARNINGS OR SAVINGS (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.3 LOSS OF USE OR VALUE OR DAMAGE OF ANY DATA OR EQUIPMENT (INCLUDING SOFTWARE), WASTED MANAGEMENT, OPERATION OR OTHER TIME (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.4 ANY SPECIAL, INDIRECT, PUNITIVE, INCIDENTAL OR CONSEQUENTIAL LOSS, IN EACH CASE HOWSOEVER CAUSED ARISING OUT OF OR IN CONNECTION WITH:
10.3.5 ANY OF THE WORKS, OR THE MANUFACTURE OR SALE OR SUPPLY, OR FAILURE OR DELAY IN SUPPLY, OF THE WORKS BY SUPPLIER OR ON THE PART OF SUPPLIER’S EMPLOYEES, AGENTS OR SUBCONTRACTORS;
10.3.6 ANY BREACH BY SUPPLIER OF ANY OF THE EXPRESS OR IMPLIED TERMS OF THE CONTRACT;
10.3.7 ANY USE MADE OR RESALE BY BUYER OF ANY OF THE WORKS, OR OF ANY PRODUCT INCORPORATING ANY OF THE WORKS; OR
10.3.8 ANY STATEMENT MADE OR NOT MADE, OR ADVICE GIVEN OR NOT GIVEN, BY OR ON BEHALF OF SUPPLIER.
10.4 EXCEPT AS EXPRESSLY SET OUT IN THE CONTRACT, SUPPLIER HEREBY EXCLUDES TO THE FULLEST EXTENT PERMISSIBLE IN LAW, ALL CONDITIONS, WARRANTIES AND STIPULATIONS, EXPRESS (OTHER THAN THOSE SET OUT IN THE CONTRACT) OR IMPLIED, STATUTORY, CUSTOMARY OR OTHERWISE WHICH, BUT FOR SUCH EXCLUSION, WOULD OR MIGHT SUBSIST IN FAVOR OF BUYER, INCLUDING, WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.
10.5 EACH OF SUPPLIER’S EMPLOYEES, AGENTS AND SUBCONTRACTORS MAY RELY UPON AND ENFORCE THE EXCLUSIONS AND RESTRICTIONS OF LIABILITY IN THE CONTRACT IN THAT PERSON’S OWN NAME AND FOR THAT PERSON’S OWN BENEFIT, AS IF THE WORDS “ITS EMPLOYEES, AGENTS AND SUBCONTRACTORS” FOLLOWED THE WORD SUPPLIER WHEREVER IT APPEARS IN THOSE CLAUSES SAVE FOR EACH REFERENCE IN CLAUSE10.3.5.
10.6 BUYER ACKNOWLEDGES THAT THE ABOVE PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY) ARE REASONABLE AND REFLECTED IN THE PRICE WHICH WOULD BE HIGHER WITHOUT THOSE PROVISIONS, AND BUYER WILL ACCEPT SUCH RISK AND/OR INSURE ACCORDINGLY.
10.7 BUYER IS SOLELY RESPONSIBLE AND LIABLE FOR THE PROPER LEGAL DISPOSAL OF ALL MATERIALS PURCHASED FROM SUPPLIER AT THE END-OF- LIFE CYCLE OF SUCH MATERIALS.
LIMITATION AND EXCLUSION OF LIABILITY 1. 6. 1. Traction Software Limited does not exclude its liability (if any) to you:
1. 6. 1. 1. for personal injury or death resulting from Traction Software Limited’s negligence;
2. 6. 1. 2. for any matter for which it would be illegal for Traction Software Limited to exclude or to attempt to exclude its liability; or
3. 6. 1. 3. for fraud.
2. 6. 2. Traction Software Limited makes no express warranties with respect to the Software and Traction Software Limited hereby excludes (to the fullest extent permissible in law), all conditions, warranties (including without limitation any warranty that the Software will meet your requirements or that its operation will be uninterrupted or error free) and stipulations, express (other than those set out in this License) or implied, statutory, customary or otherwise which, but for such exclusion, would or might subsist in favour of you. Except as set out in this License you assume the entire risk as to the quality and performance of the Software.
3. 6. 3. Subject to clause 6. 1 Traction Software Limited will be under no liability to you whatsoever (whether in contract, tort (including negligence), breach of statutory duty, restitution or otherwise) for any injury, death, damage or direct, indirect or consequential loss (all three of which terms include, without limitation, pure economic loss, loss of profits, loss of business, loss of data, loss of savings, depletion of goodwill and like loss) howsoever caused arising out of or in connection with:
1. 6. 3. 1. the Software, or the manufacture or sale or supply, or failure or delay in supply, of the Software by Traction Software Limited or on the part of Traction Software Limited’s employees, agents or sub-contractors;
2. 6. 3. 2. any breach by Traction Software Limited of any of the express or implied terms of this License;
3. 6. 3. 3. any use made of the Software; or
4. 6. 3. 4. any statement made or not made, or advice given or not given, by or on behalf of Traction Software Limited.
4. 6. 4. Subject to clause 6. 1 and without prejudice to clauses 6. 2 and 6. 3 , Traction Software Limited’s aggregate liability under this License(whether in contract, tort (including negligence), breach of statutory duty, restitution or otherwise) for any injury, death, damage or direct or consequential loss (all three of which terms include without limitation of profits, loss of business, depletion of goodwill and like loss) howsoever caused (other than for death or personal injury caused by Traction Software Limited’s negligence) will be limited to the higher of the price paid by you to use the Software or USD $1 00.
5. 6. 5. You acknowledge that the above provisions of this clause 6 are reasonable given the charges made (if any) for the Software and you will accept such risk and/or insure accordingly.
6. 6. 6. Any rights that you have as a consumer are not affected by this clause 6.
Indemnification and Limitation of Liability (a) In the absence of willful misfeasance, bad faith, gross negligence or reckless disregard of obligations or duties hereunder on the part of FSSC and its trustees, officers, employees, agents and representatives, the Funds agree to indemnify FSSC and its trustees, officers, employees, agents and representatives against any and all claims, demands, liabilities and reasonable expenses (including attorneys’ fees), related to or otherwise connected with (i) any breach by the Funds of any provision of this Agreement; or (ii) any action by a Fund’s Shareholder against FSSC.
(b) FSSC shall not be liable for any error of judgment or mistake of law or for any loss suffered by any Fund in connection with the matters to which this Agreement relates, except a loss resulting from willful misfeasance, bad faith or gross negligence on its part in the performance of its duties or from reckless disregard by it of its obligations and duties under this Agreement. In no event shall FSSC be liable for indirect or consequential damages.
(c) Any person, even though also an officer, trustee, partner, employee or agent of FSSC, who may be or become an officer, employee or agent of any Fund or a member of a Fund's Board, shall be deemed, when rendering services to such Fund or acting on any business of such Fund (other than services or business in connection with the duties of FSSC hereunder) to be rendering such services to or acting solely for such Fund and not as an officer, trustee, partner, employee or agent or one under the control or direction of FSSC even though paid by FSSC.
(d) FSSC is expressly put on notice of the limitation of liability as set forth in the Declaration of Trust of each Fund that is a Massachusetts business trust and agrees that the obligations assumed by each such Fund pursuant to this Agreement shall be limited in any case to such Fund and its assets and that FSSC shall not seek satisfaction of any such obligations from the Shareholders of such Fund, the Trustees, Officers, Employees or Agents of such Fund, or any of them.
(e) The provisions of this Section shall survive the termination of this Agreement.
Compensation and Limitation of Liability 14 Section 1.
Disclaimers and Limitation of Liability EXCEPT AS EXPRESSLY SET FORTH HEREIN, ALL SERVICES TO BE PROVIDED BY FLG AND FLG MEMBER (FOR PURPOSES OF THIS PARAGRAPH 6, COLLECTIVELY “FLG”) HEREUNDER ARE PROVIDED “AS IS” WITHOUT ANY WARRANTY WHATSOEVER. CLIENT RECOGNIZES THAT THE “AS IS” CLAUSE OF THIS AGREEMENT IS AN IMPORTANT PART OF THE BASIS OF THIS AGREEMENT, WITHOUT WHICH FLG WOULD NOT HAVE AGREED TO ENTER INTO THIS AGREEMENT. FLG EXPRESSLY DISCLAIMS ALL OTHER WARRANTIES, TERMS OR CONDITIONS, WHETHER EXPRESS, IMPLIED, OR STATUTORY, REGARDING THE PROFESSIONAL SERVICES, INCLUDING ANY, WARRANTIES OF MERCHANTABILITY, TITLE, FITNESS FOR A PARTICULAR PURPOSE AND INFRINGEMENT. NO REPRESENTATION OR OTHER AFFIRMATION OF FACT REGARDING THE SERVICES PROVIDED HEREUNDER SHALL BE DEEMED A WARRANTY FOR ANY PURPOSE OR GIVE RISE TO ANY LIABILITY OF FLG WHATSOEVER. IN NO EVENT SHALL FLG BE LIABLE FOR ANY INCIDENTAL, INDIRECT, EXEMPLARY, SPECIAL, PUNITIVE OR CONSEQUENTIAL DAMAGES, UNDER ANY CIRCUMSTANCES, INCLUDING, BUT NOT LIMITED TO: LOST PROFITS; REVENUE OR SAVINGS; WAIVER BY CLIENT, WHETHER INADVERTENT OR INTENTIONAL, OF CLIENT’S ATTORNEY-CLIENT PRIVILEGE THROUGH CLIENT’S DISCLOSURE OF LEGALLY PRIVILEGED INFORMATION TO FLG; OR THE LOSS, THEFT, TRANSMISSION OR USE, AUTHORIZED OR OTHERWISE, OF ANY DATA, EVEN IF CLIENT OR FLG HAVE BEEN ADVISED OF, KNEW, OR SHOULD HAVE KNOWN, OF THE POSSIBILITY THEREOF. NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, FLG’S AGGREGATE CUMULATIVE LIABILITY HEREUNDER, WHETHER IN CONTRACT, TORT, NEGLIGENCE, MISREPRESENTATION, STRICT LIABILITY OR OTHERWISE, SHALL NOT EXCEED AN AMOUNT EQUAL TO THE LAST TWO (2) MONTHS OF FEES PAYABLE BY CLIENT UNDER PARAGRAPH 2(A) OF THIS AGREEMENT. CLIENT ACKNOWLEDGES THAT THE COMPENSATION PAID BY IT UNDER THIS AGREEMENT REFLECTS THE ALLOCATION OF RISK SET FORTH IN THIS AGREEMENT AND THAT FLG WOULD NOT ENTER INTO THIS AGREEMENT WITHOUT THESE LIMITATIONS ON ITS LIABILITY. THIS PARAGRAPH SHALL NOT APPLY TO EITHER PARTY WITH RESPECT TO A BREACH OF ITS CONFIDENTIALITY OBLIGATIONS.
A. As a condition for recovery of any amount by Client against FLG, Client shall give FLG written notice of the alleged basis for liability within ninety (90) days of discovering the circumstances giving rise thereto, in order that FLG will have the opportunity to investigate in a timely manner and, where possible, correct or rectify the alleged basis for liability; provided that the failure of Client to give such notice will only affect the rights of Client to the extent that FLG is actually prejudiced by such failure. Notwithstanding anything herein to the contrary, Client must assert any claim against FLG by the sooner of: (i) ninety (90) days after discovery; (ii) ninety (90) days after the termination of this Agreement; (iii) ninety (90) days after the last date on which the Services were performed; or, (iv) sixty (60) days after completion of a financial or accounting audit for the period(s) to which a claim pertains.
Warranty and Limitation of Liability PBI PROVIDES YOU WITH THE LIMITED WARRANTIES IN SECTION 1. PBGFS MAKES NO WARRANTIES, EXPRESS OR IMPLIED, INCLUDING ANY WARRANTY OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, OR FREEDOM FROM INTERFERENCE OR INFRINGEMENT, AND PBGFS ISN’T LIABLE FOR ANY LOSS, DAMAGE (INCLUDING INCIDENTAL, CONSEQUENTIAL OR PUNITIVE DAMAGES) OR EXPENSE CAUSED DIRECTLY OR INDIRECTLY BY THE EQUIPMENT.
Limitation of Liability and Indemnification State Street shall be held to a standard of reasonable care in carrying out its duties under this Agreement. State Street shall be responsible for the performance of only such duties as are set forth in this Agreement and, except as otherwise provided under Section XVI, shall have no responsibility for the actions or activities of any other party, including other service providers. State Street shall have no liability for any error of judgment or mistake of law or for any loss or damage resulting from the performance or nonperformance of its duties hereunder unless caused by or resulting from the negligence, reckless misconduct, willful malfeasance or lack of good faith of State Street, its officers or employees and, in such event, such liability will be subject to the limitations set forth in Section XIII herein. STATE STREET SHALL NOT BE LIABLE FOR ANY SPECIAL, INDIRECT, INCIDENTAL, OR CONSEQUENTIAL DAMAGES OF ANY KIND WHATSOEVER (INCLUDING, WITHOUT LIMITATION, ATTORNEYS’ FEES) IN ANY WAY DUE TO THE TRUST’S USE OF THE SERVICES DESCRIBED HEREIN OR THE PERFORMANCE OF OR FAILURE TO PERFORM STATE STREET’S OBLIGATIONS UNDER THIS AGREEMENT. This disclaimer applies without limitation to claims regardless of the form of action, whether in contract (including negligence), strict liability, or otherwise and regardless of whether such damages are foreseeable. The Trust, or, if applicable, the relevant Portfolio, will indemnify and hold harmless State Street and its stockholders, directors, officers, employees, agents, and representatives (collectively, the “Trust Indemnified Persons”) for, and will pay to the Trust Indemnified Persons the amount of, any actual and direct damages, whether or not involving a third-party claim (collectively, the “Damages”), arising from or in connection with (i) any act or omission by State Street (or any of its affiliates) pursuant to this Agreement which does not constitute negligence, reckless misconduct, willful malfeasance or lack of good faith in fulfilling the terms and obligations of this Agreement, (ii) any act or omission by the Trust (or any of its affiliates) which constitutes a breach of any representation, warranty, term, or obligation contained in this Agreement, or (iii) any act or omission by the Trust (or any of its affiliates) which constitutes negligence, reckless misconduct, willful malfeasance, or lack of good faith in fulfilling the terms and obligations of this Agreement. The remedies provided in this paragraph are not exclusive of or limit any other remedies that may be available to State Street or any other Trust Indemnified Person. State Street will indemnify and hold harmless the Trust, and its respective shareholders, trustees, directors, officers, agents, and representatives (collectively, the “State Street Indemnified Persons”) for, and will pay to the State Street Indemnified Persons the amount of, any Damages, arising from or in connection with (i) any act or omission by State Street (or any of its affiliates) which constitutes a breach of any representation, warranty, term, or obligation contained in this Agreement or (ii) any act or omission by State Street (or any of its affiliates) which constitutes negligence, reckless misconduct, willful malfeasance, or lack of good faith in fulfilling the terms and obligations of this Agreement; provided, however, that State Street shall not be required to provide indemnification for damages arising from errors caused by inaccurate prices received from independent pricing services and reasonably relied upon by State Street. In the event that State Street is required to provide indemnification under this Section XII, its liability shall be limited as described under Section XIII below. The remedies provided in this paragraph are not exclusive of or limit any other remedies that may be available to the Trust or any other State Street Indemnified Person. The indemnification and limitation of liability contained herein shall survive the termination of this Agreement.
Limited Warranty and Limitation of Liability Veeam warrants that it has the right and authority to grant the License under this XXXX. Veeam will defend or, at its option, settle any action against End User based upon a claim that its use of the Software infringes any patent, copyright or other intellectual property right of a third party, and will indemnify End User against any amounts awarded against End User as a result of the claim, provided Veeam is promptly notified of the assertion of the claim and has control of its defense or settlement. Veeam warrants that the Software, in its unmodified form as initially delivered or made available to End User, will perform substantially in accordance with the Documentation for a warranty period of ninety (90) days from the date the Software is delivered to End User. In the event the Software fails in a material respect to operate in accordance with the Documentation during the warranty period and Veeam is unable to correct the defect, Veeam’s sole and exclusive liability and End User’s sole and exclusive remedy shall be a refund of the License fee, if any, paid by End User for the Software. In the event a reported problem with the Software is End User’s fault, End User agrees to reimburse Veeam for its correction efforts in accordance with its then standard rates. The foregoing limited warranty will not apply if failure of the Software is the result of damage or misuse caused by End User. EXCEPT FOR THE LIMITED WARRANTY SET FORTH ABOVE, THE SOFTWARE IS PROVIDED 'AS IS”, WITHOUT WARRANTY OF ANY KIND, EXPRESS OR IMPLIED, INCLUDING WITHOUT LIMITATION ANY IMPLIED WARRANTY THAT THE SOFTWARE IS FREE OF DEFECTS, MERCHANTABLE OR FIT FOR A PARTICULAR PURPOSE. NO ORAL OR WRITTEN INFORMATION OR ADVICE GIVEN BY VEEAM OR ANY THIRD PARTY, INCLUDING, WITHOUT LIMITATION, ANY VEEAM DISTRIBUTORS OR RESELLERS, SHALL CREATE ANY WARRANTY IN ADDITION TO, OR IN ANY WAY INCREASE THE SCOPE OF, THE LIMITED WARRANTY. In no event will Veeam, its affiliates, resellers, or distributors or suppliers be liable for any indirect, special, incidental or consequential damages arising out of the use of or inability to use the Software, including, without limitation, damages for lost profits, loss of goodwill, work stoppage, computer failure or malfunction, or any and all other commercial damages or losses, even if advised of the possibility thereof.
Disclaimer and Limitation of Liability PROVIDER DISCLAIMS ALL WARRANTIES, EXPRESS,IMPLIED, STATUTORY OR ARISING FROM A COURSE OF DEALING OR PERFORMANCE OR CUSTOM, WITH RESPECT TO THE SERVICES, EQUIPMENT, AND ANY OTHER PROVIDER PRODUCTS, SERVICES OR EQUIPMENT PROVIDED HEREUNDER, INCLUDING, BUT NOT LIMITED TO, WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, PERFORMANCE IN A XXXXXXX-LIKE MANNER, COMPLIANCE WITH LAWS, QUALITY, ACCURACY, COMPLETENESS OR CURRENCY OF INFORMATION, SYSTEM INTEGRABILITY, TITLE, QUIET ENJOYMENT AND NON-INFRINGEMENT. PROVIDERDOES NOT REPRESENT, WARRANT OR COVENANT THAT THE PRODUCTS, SERVICES OR EQUIPMENT PROVIDED WILL OPERATE UNINTERRUPTED, ERROR FREE OR WITHOUT DEGRADATION OR LOSS OF DATA, OR BE SECURE. NEITHER PROVIDER NOR ITS SERVICE PROVIDERS WILL BE LIABLE FOR UNAUTHORIZED ACCESS TO OR ALTERATION, THEFT OR DESTRUCTION OF CUSTOMER’S OR A USER’S DATA FILES, PROGRAMS, PROCEDURES OR INFORMATION, INCLUDING, WITHOUT LIMITATION, ANY SUCH DATA IN PROVIDER’S POSSESSION, CUSTODY OR CONTROL, THROUGH ACCIDENT, FRAUDULENT MEANS OR DEVICES, OR ANY OTHER METHOD, REGARDLESS OF WHETHER SUCH DAMAGE OCCURS AS A RESULT OF PROVIDER’S OR ITS SERVICE PROVIDER’S NEGLIGENCE. IN NO EVENT WILL PROVIDER OR ITS AFFILIATE, SERVICE PROVIDER, FACILITY OPERATOR OR CARRIER, OR THEIR RESPECTIVE OWNERS, DIRECTORS, MANAGERS, OFFICERS, EMPLOYEES OR AGENTS (COLLECTIVELY, “PROVIDER PARTIES”) BE LIABLE FOR ANY DIRECT, ACTUAL, INDIRECT, CONSEQUENTIAL, SPECIAL, PUNITIVE OR OTHER DAMAGES, OR FOR ANY COST OF COVER OR LOST PROFITS OF ANY KIND OR NATURE WHATSOEVER, ARISING FROM OR RELATED TO THIS AGREEMENT OR A PROVIDER PARTY’S PERFORMANCE OR NONPERFORMANCE OF OBLIGATIONS HEREUNDER, A FAILURE OF OR A DEFECT IN THE SERVICES, EQUIPMENT OR ANY PRODUCT, A PROVIDER PARTY’S VIOLATION OF A THIRD PARTY’S RIGHT, OR A PROVIDER PARTY’S ACTS OR OMISSIONS. PROVIDER WILL NOT BE LIABLE FOR THE ACTS OR OMISSIONS OF, A FAILURE OF OR A DEFECT IN ANY PRODUCT OR SERVICE PROVIDED BY, OR VIOLATION OF ANY THIRD PARTY’S RIGHTS BY ANY THIRD-PARTY SERVICE PROVIDER, FACILITY OPERATOR OR CARRIER. THE PROVIDER PARTIES’ MAXIMUM TOTAL LIABILITY TO CUSTOMER WILL NOT EXCEED THE AMOUNTS PAID BY CUSTOMER TO PROVIDER IN THE THREE (3) MONTHS PRECEDING THE DATE THE CLAIM ACCRUED. THE PROVIDER PARTIES WILL NOT BE LIABLE IN ANY WAY TO ANY USER.
Standard of Care, Limitation of Liability and Indemnification (a) The Sub-Adviser shall exercise its best judgment in rendering the services under this Agreement. The Sub-Adviser shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Trust, the Adviser or the Fund, or affiliated persons of the Adviser or the Fund (collectively, the "Adviser Indemnitees") in connection with the matters to which this Agreement relates except a loss resulting from the Sub-Adviser's willful misfeasance, bad faith or gross negligence in the performance of its obligations and duties, or by reason of its reckless disregard of its obligations and duties, under this Agreement; provided, however, that nothing herein shall be deemed to protect or purport to protect the Sub-Adviser against any liability to the Adviser Indemnitees for, and the Sub-Adviser shall indemnify and hold harmless the Adviser Indemnitees from, any and all claims, losses, expenses, obligations and liabilities (including reasonable attorney's fees) to which any of the Adviser Indemnitees may become subject arising out of or resulting from (i) the Sub-Adviser causing the Fund to be in violation of any applicable federal or state law, rule or regulation or any investment policy or restriction set forth in the Fund's current Registration Statement or the most current written guidelines, policies or instruction provided in writing by the Board or the Adviser, (ii) the Sub-Adviser causing the Fund to fail to satisfy the requirements set forth in Section 2(i) hereof, (iii) any untrue statement of a material fact contained in the Registration Statement, proxy materials, reports, advertisements, sales literature, or other materials pertaining to the Sub-Adviser or the Portfolio managed by the Sub-Adviser or the omission to state therein a material fact known to the Sub-Adviser that was required to be stated therein or necessary to make the statements therein not misleading, if such statement or omission was made in reliance upon information furnished to the Adviser or the Trust by the Sub-Adviser for use therein, or (iv) a breach of this Agreement by the Sub-Adviser. In addition, the Sub-Adviser shall indemnify and hold harmless the Trust and the Fund from any and all claims, losses, expenses, obligations and liabilities (including reasonable attorney's fees) to which either the Trust or the Fund may become subject directly arising out of or resulting from a breach of fiduciary duty by the Sub-Adviser under Section 36(b) of the 1940 Act with respect to the receipt of compensation for its services under this Agreement. Notwithstanding the foregoing, nothing contained in this Agreement shall constitute a waiver or limitation of rights that the Trust or the Fund may have under federal or state securities laws.
(b) The Sub-Adviser is hereby expressly put on notice of the limitation of shareholder liability as set forth in the Trust Instrument or other organizational document of the Trust and agrees that any obligations of the Trust or the Fund arising in connection with this Agreement shall be limited in all cases to the Fund and its assets, and the Sub-Adviser shall not seek satisfaction of any such obligation from any other fund of the Trust or the shareholders or any individual shareholder of the Fund. Nor shall the Sub-Adviser seek satisfaction of any such obligation from the trustees of the Trust (each, a "Trustee" and, together, the "Trustees") or any individual Trustee or any officers.
(c) As used in this Section 6, the term "Sub-Adviser" shall include any officers, directors, employees, independent contractors or other affiliates of the Sub-Adviser performing services with respect to the Fund.
(d) The Adviser agrees to indemnify and hold harmless the Sub-Adviser from and against any and all claims, losses, expenses, obligations and liabilities (including reasonable attorney's fees) to which the Sub-Adviser may become subject directly arising out of or resulting from, the Adviser's willful misfeasance, bad faith or gross negligence in the performance of its obligations and duties under this Agreement, or by reason of its reckless disregard of its obligations and duties under this Agreement.
