Selection of Subcontractors Procurement of Materials and Leasing of Equipment: The contractor shall not discriminate on the grounds of race, color, religion, sex, sexual orientation, gender identity, national origin, age, or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
a. The contractor shall notify all potential subcontractors, suppliers, and lessors of their EEO obligations under this contract.
b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Purpose; Incorporation by Reference of Auction Procedures and Settlement Procedures (a) The Statement for each series of MuniPreferred will provide that the Applicable Rate for such series for each Subsequent Rate Period thereof shall, except under certain conditions, be the rate per annum that a bank or trust company appointed by the Fund advises results from implementation of the Auction Procedures for such series. The Board of Directors or Board of Trustees, as the case may be, of the Fund has adopted a resolution appointing the Auction Agent as auction agent for purposes of the Auction Procedures for each series of MuniPreferred. The Auction Agent accepts such appointment and agrees to follow the procedures set forth in this Section 2 and the Auction Procedures for the purpose of determining the Applicable Rate for each series of MuniPreferred for each Subsequent Rate Period thereof for which the Applicable Rate is to be determined by an Auction. Each periodic implementation of such procedures is hereinafter referred to as an "Auction."
(b) All of the provisions contained in the Auction Procedures and the Settlement Procedures are incorporated herein by reference in their entirety and shall be deemed to be a part hereof to the same extent as if such provisions were fully set forth herein.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Contractor Selection In this section, please describe the selection process, including other sources considered and the rationale for selecting the contractor. Please answer all questions:
a. What specific skill set does this contractor bring to the project? Please attach a copy of the contractor’s resume if an individual or link to contractor website if a company: Little to Great Scientists is an international leader in early childhood, elementary, middle and high school science education. xxxxx://xxxxxxxxxxxxxxxxxxxxxxx.xxx/
b. How was the Contractor selected? Quotes, RFP/RFQ, Sealed Bid or Sole Source designation from the City of New Haven Purchasing Department? This contractor was selected because of their continued commitment to NHPS. They possess the knowledge base, resources, and motivation to support hands-on science education in New Haven. No other contractors were considered for this partnership.
c. Is the contractor the lowest bidder? N/A If no, why? Why was this contractor selected? This contractor was selected because of their unique expertise in hands-on science learning and their continued commitment to New Haven Public Schools. They possess the knowledge and resources to support science learning at Xxxxxxx Xxxxxx School.
d. Who were the members of the selection committee that scored bid applications? N/A
e. If the contractor is Sole Source, please attach a copy of the Sole Source designation letter from the City of New Haven Purchasing Department. N/A
Tenants Selection of Contractors Tenant shall retain Landlord’s contractor, Commerce Construction Co., L.P. (the “Contractor”), as general contractor for the performance of the Work.
Inspection of Agreement A copy of this Agreement shall be available at all reasonable times at the principal corporate trust office of the Warrant Agent for inspection by the holder of any Warrant Certificate. The Warrant Agent may require such holder to submit his Warrant Certificate for inspection by it.
Presentation of Potential Target Businesses The Company shall cause each of the Initial Shareholders to agree that, in order to minimize potential conflicts of interest which may arise from multiple affiliations, the Initial Shareholders will present to the Company for its consideration, prior to presentation to any other person or company, any suitable opportunity to acquire an operating business, until the earlier of the consummation by the Company of a Business Combination or the liquidation of the Company, subject to any pre-existing fiduciary obligations the Initial Shareholders might have.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract.
b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
Certification of the Settlement Class For purposes of this Settlement only, the Parties stipulate to the certification of the Settlement Class, which is contingent upon the Court entering the Final Approval Order and Judgment of this Settlement and the occurrence of the Effective Date.
