Seller's Quarterly Maintenance Schedule Sample Clauses

Seller's Quarterly Maintenance Schedule. By each March 1st, June 1st, September 1st and December 1st (as applicable, subsequent to the Commercial Operations Date), Seller shall provide to Company in writing a projection of maintenance outages and reductions in capacity for the next calendar quarter, including the estimated MW that is anticipated to be off-line for each projected maintenance event. Seller shall provide Company with prompt written notice of any deviation from its quarterly maintenance schedule, but in any case Seller shall provide such written notice not less than one (1) week prior to commencing any such rescheduled maintenance event. During any scheduled or rescheduled maintenance event, Seller shall provide updates to Company's operating personnel in the event there are any delays or changes to the proposed schedule, and shall promptly respond to any requests from Company for updates regarding the status of such maintenance event.
Sample 1Sample 2Sample 3See All (24)
AutoNDA by SimpleDocs
Seller's Quarterly Maintenance Schedule. If changes are required to the Seller’s Annual Maintenance Schedule after concurrence by Buyer in accordance with Section 5.3.1, Seller shall provide to Buyer in writing a projection of maintenance outages and reductions in capacity for the next calendar quarter in which such change in the Seller’s Annual Maintenance Schedule shall occur, including the estimated MW that is anticipated to be off-line for each projected maintenance event. If required, Seller’s Quarterly Maintenance Schedule shall be provided to Buyer by March 1st, June 1st, September 1st or December 1st, as applicable. Seller’s inclusion of a maintenance event in its quarterly maintenance schedule shall not excuse any failure to satisfy the Committed MW/MVAR during such maintenance event, except that Seller shall be excused from any failure to satisfy the Committed MW/MVAR if Buyer fails to raise a concern regarding the occurrence of a maintenance event upon thirty (30) Business Days prior written notice to Seller. During any scheduled maintenance event, Sell-er shall provide updates to Buyer’s operating personnel in the event there are any delays or changes to the proposed schedule, and shall promptly respond to any requests from Buyer for updates regarding the status of such maintenance event.
Sample 1Sample 2

Related to Seller's Quarterly Maintenance Schedule

  • INTERIM MAINTENANCE PERIOD During the interim maintenance period between obtaining of the completion certificate of Project and formation and operationalization of the Association the Promoter shall through itself or through a facility management company constitute a committee to run, operate, manage and maintain the Common Areas.

  • Five Day Work Week Schedule When working under the five (5) day work week schedule, Employees shall receive one and one-half (1.5x) times their regular rate of pay for the first two (2) hours of overtime Monday through Friday. All other overtime Monday through Friday shall be paid at double time (2x).

  • Milestone schedule Please state the status and progress of each Milestone and identify any completed Milestone(s) for the previous calendar quarter.

  • Contract Quarterly Sales Reports The Contractor shall submit complete Quarterly Sales Reports to the Department’s Contract Manager within 30 calendar days after the close of each State fiscal quarter (the State’s fiscal quarters close on September 30, December 31, March 31, and June 30). Reports must be submitted in MS Excel using the DMS Quarterly Sales Report Format, which can be accessed at xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. Initiation and submission of the most recent version of the Quarterly Sales Report posted on the DMS website is the responsibility of the Contractor without prompting or notification from the Department’s Contract Manager. If no orders are received during the quarter, the Contractor must email the DMS Contract Manager confirming there was no activity.

  • Planned Maintenance (a) Sellers may designate up to twenty (20) Days of Planned Maintenance on Sellers’ Facilities during each Contract Year. Sellers shall be entitled to reduce (including down to zero (0)) its Gas scheduling under Clause 8 and Exhibit 3 for each Day of Planned Maintenance.

  • Scheduled Maintenance Maintenance window for disruptive work to Service will be limited 12:00 A.M. to 4:00 A.M., Central Daylight Time (CDT), any day with requirement of one (1) calendar week notification to Customer prior to maintenance. LightEdge will send an e-mail notification of such disruptive maintenance to Service to Authorized Contacts of Customer. Once notification is sent to Customer this will be considered a “Scheduled Maintenance”. Any Service SLAs will NOT apply during a Scheduled Maintenance.

  • Maintenance Scheduling The NTO shall schedule maintenance of its facilities designated as NTO Transmission Facilities Under ISO Operational Control and schedule any outages (other than forced transmission outages) of said transmission system facilities in accordance with outage schedules approved by the ISO. The NTO shall comply with maintenance schedules coordinated by the ISO, pursuant to this Agreement, for NTO Transmission Facilities Under ISO Operational Control. The NTO shall be responsible for providing notification of maintenance schedules to the ISO for NTO Transmission Facilities Requiring ISO Notification. The NTO shall provide notification of maintenance schedules to affected Transmission Owners for NTO Transmission Facilities Requiring ISO Notification and Local Area Transmission Facilities pursuant to Section 3.5.3 of the ISO Services Tariff.

  • Performance Schedule The Parties will perform their respective responsibilities in accordance with the Performance Schedule. By executing this Agreement, Customer authorizes Motorola to proceed with contract performance.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!