Shipment Terms and Costs. Solution is delivered DDP, Delivered Duty Paid, from the Company’s manufacturing plant in Zapopan, Mexico to Distributor’s warehouse in Rialto, California.
Shipment Terms and Costs Sample Clauses
Related to Shipment Terms and Costs
Manufacturing Costs In the event of termination by Merck pursuant to Section 6.2, 6.3 or 6.6 above, Merck shall be entitled to [*****] (as defined herein) incurred by Merck for its Compound Delivered for the Study. [*****]
Manufacturing Services Jabil will manufacture the Product in accordance with the Specifications and any applicable Build Schedules. Jabil will reply to each proposed Build Schedule that is submitted in accordance with the terms of this Agreement by notifying Company of its acceptance or rejection within three (3) business days of receipt of any proposed Build Schedule. In the event of Jabil’s rejection of a proposed Build Schedule, Jabil’s notice of rejection will specify the basis for such rejection. When requested by Company, and subject to appropriate fee and cost adjustments, Jabil will provide Additional Services for existing or future Product manufactured by Jabil. Company shall be solely responsible for the sufficiency and adequacy of the Specifications [***].
Quality Agreement Each Party will comply with the terms of the Quality Agreement in the performance of its obligations hereunder including record retention, audits and inspections, change control, adverse events and product recall. The Parties will conduct periodic Product quality reviews in accordance with the terms of the Quality Agreement.
Development Plan As defined in Section 3.2(a).
Contract Terms To Be Exclusive This written agreement contains the sole and entire agreement between the parties, and supersedes any and all other agreements between them. The parties acknowledge and agree that neither of them has made any representation with respect to the subject matter of this agreement or any representations inducing the execution and delivery hereof except such representations as are specifically set forth herein, and each party acknowledges that he or it has relied on his or its own judgment in entering into the agreement. The parties further acknowledge that any statements or representations that may have heretofore been made by either of them to the other are void and of no effect and that neither of them has relied thereon in connection with his or its dealings with the other.
Project Plan Based on the Project Specifications, Omnicare CR has provided a description of services to be performed for Sponsor’s “A multi-center, randomized, double-blind, double-dummy, vehicle-controlled sequential cohort study to determine the safety of PEP005 0.025% and 0.05% topical gel in patients with actinic keratoses” (hereinafter “the Project”) and associated costs. Changes made in the Project scope, at any time during the Project, will result in a corresponding adjustment to the Project costs.
Additional Products Throughout the Term, Rockwell shall provide to DaVita and the DaVita Facilities the right to purchase and/or lease all current or new products manufactured, utilized, licensed, sold or distributed by Rockwell or any of its Affiliates (including products and product lines acquired by Rockwell or any of its Affiliates as a result of an acquisition, merger or other transaction involving Rockwell or any of its Affiliates) that are or that become Commercially Available and which are not already covered by this Agreement or by any other agreement, whether written or oral, between the parties hereto (such products are collectively referred to as “Additional Products” and individually as an “Additional Product”). Rockwell agrees to include DaVita in all of its and its Affiliates distributions of customer announcements regarding Rockwell’s or its Affiliates’ Additional Products. The purchase price for any such Additional Products shall be negotiated by the parties hereto in good faith and the agreed upon purchase price shall be memorialized in writing as a supplement or amendment to this Agreement. Rockwell covenants and agrees that it shall only make an offer for the sale of any Additional Product(s) to DaVita’s Vice-President of Clinical Operations, Chief Medical Officer, or Vice-President of Purchasing, and not to any DaVita Facility directly; provided that the purchase of any Additional Product by DaVita or any DaVita Facility through a Rockwell product catalog made generally available to the dialysis community shall not be a breach by Rockwell of this Section 8.1. If Rockwell or any of its Affiliates acquires any Additional Product(s) as a result of an acquisition, merger or other transaction involving Rockwell or any of its Affiliates with a Person with which DaVita or a DaVita Facility, as applicable, already has a purchase or rebate arrangement whether written or oral (a “Prior Agreement”), Rockwell or such Affiliate covenants and agrees that it shall continue to abide by all of the terms and conditions of such Prior Agreement or if DaVita requests, such Additional Product(s) shall be included in this Agreement on terms to be negotiated and determined by the parties hereto as provided in this Section 8.1.
Forecasts and Purchase Orders On or before the twelfth (12th) day of each month, beginning on January 12, 2022, Indivior shall furnish to Curia a written twelve (12) month rolling forecast of the quantities of Product that Indivior intends to order from Curia during such period ("Rolling Forecast"). The first six (6) months of such Rolling Forecast shall constitute a firm and binding commitment to order quantities of Product specified therein ("Firm Period Forecast"), and the following six (6) months of the Rolling Forecast shall be non-binding, good faith estimates. Each month of the Rolling Forecast shall begin on the twelfth (12th) of the calendar month in which such Rolling Forecast is submitted and end on the eleventh (11th) day of the following calendar month. With exception to the Firm Period Forecast, Curia reserves the right to reject any Rolling Forecast that does not align with the physical Processing capabilities of the Facility(ies) and the parties shall work in good faith to adjust the Rolling Forecast based on available resources, Facility capacity and other relevant factors. Indivior shall have the right to request an increase of the Firm Period Forecast to include additional units of Product. Curia may, in its sole discretion, supply such additional quantities, subject to Curia's other supply commitments and manufacturing capacity. In the event Curia agrees to supply such additional quantities, Indivior shall submit a Purchase Order for such additional quantities, with the required lead times as specified below. In no event shall Curia's inability to fulfill Purchase Orders for quantities in excess of the Firm Period Forecast be deemed a breach of this Agreement, nor relieve Indivior of its obligations under this Agreement. Indivior shall submit with each Rolling Forecast, a non-cancelable Purchase Order for the Firm Period Forecast (or such portion of the Firm Period Forecast not covered by previously submitted Purchase Orders). Indivior may alternatively submit Purchase Orders for certain portions of the Firm Period Forecast subsequent to the submission of the Rolling Forecast, provided the Purchase Orders provide the required lead time for Processing as set forth below. Curia shall notify Indivior of acceptance of the Rolling Forecast and any Purchase Order within seven (7) business days of receipt. Curia shall be deemed to have accepted Purchase Orders which it does not acknowledge within seven (7) business days of receipt. Curia shall have the right to reject Rolling Forecasts and Purchase Orders that are inconsistent with this Agreement. Each Purchase Order shall specify the quantity of Product being ordered, and the desired delivery date. Upon mutual agreement in writing for additional quantities of Product beyond the Firm Period Forecast, including projected delivery date(s), Indivior shall issue the applicable Purchase Order to be accepted by Curia as described above. Once placed, all Purchase Orders for Product shall be non-cancelable. No different or additional terms or conditions set forth in any Purchase Order shall modify in any way the terms and conditions of this Agreement, and in the event of a conflict between terms in any Purchase Order and this Agreement, the terms of this Agreement shall control. All Purchase Orders submitted in accordance with the terms of this Agreement shall be effective and binding on the parties upon acceptance by Curia. Except as otherwise provided herein, neither party shall have the right or power to refuse, reduce, or otherwise modify their obligations under any Purchase Order; however, Purchase Orders may be amended (i) upon written mutual agreement regarding such modification that is signed by both parties; or (ii) as otherwise provided in this Section 4.3 or Section 4.4.
Work Orders There are no outstanding work orders or contracts relating to any portion of the Assets from or required by any policy of insurance, fire department, sanitation department, health authority or other Governmental Authority nor is there any matter under discussion with any such parties or authorities relating to work orders or contracts.
Shipment If any of the Major Components associated with any Unit is not Shipped on or before (with the prior approval of the Buyer) the Scheduled Major Component Shipment Date set forth in Attachment 1 for reasons attributable to the Seller and not excused elsewhere in this Contract, the Seller shall pay as liquidated damages, and not as a penalty, a sum calculated in accordance with the table below for each Unit for each day of delay after the Scheduled Major Component Shipment Date as set forth in Attachment 1 until actual Shipment of the last Major Component for such Unit: Days after Scheduled Major Component Shipment Date Liquidated Damages (per day or partial day) *** *** *** *** *** *** Such liquidated damages, if any, shall be computed based on the date of Shipment of the last Major Component for a given Unit and such computations shall disregard any part of or accessory to the Major Component which may be shipped separately and arrive later unless such part of or accessory to the Major Component is necessary for the installation of the Major Component.
