Work Orders. If the Contract is for indefinite quantities of Services, as specified in the Signature Document, all Work will be performed in accordance with properly executed Work Orders.
Work Orders. To the extent the Contract is for indefinite quantities of services, as specified in the Signature Document, all Work will be performed in accordance with Work Orders.
a. Upon identification of a Project, the System Agency will request that Contractor submit a proposal, including pricing and a project plan, to System Agency.
b. If Contractor is selected to carry out an individual Project, a Work Order will be issued. Multiple Work Orders may be issued during the term of this Contract, all of which will be in writing and signed by the Parties. Each Work Order will include a scope of services; a list of tasks required; a time schedule; a list of Deliverables, if any; a detailed Project budget; and such other information or special conditions as may be necessary for the work assigned.
c. Nothing in this Contract expresses or guarantees that the System Agency will issue Work Orders to Contractor for any of the tasks set forth in the Signature Document. All work requested under this Contract will be required on an irregular and as needed basis throughout the Contract term, and the System Agency makes no guarantee of volume or usage under this Contract.
Work Orders. There are no outstanding work orders or contracts relating to any portion of the Assets from or required by any policy of insurance, fire department, sanitation department, health authority or other Governmental Authority nor is there any matter under discussion with any such parties or authorities relating to work orders or contracts.
Work Orders. The Products to be supplied and/or the Services to be performed under this Agreement shall be detailed or specified in one or more Work Orders, the first of which is attached to this Agreement as Exhibit A. Work Orders under this Agreement shall be issued in writing and shall reference this Agreement and shall become effective upon the signature of both Xxxxxxx and PPD. Any Work Order, or any part thereof, may be revised, supplemented or amended as reasonably required to achieve the Development Plan, but only through a Work Order amendment mutually agreed to in writing by both Parties (an “Amendment”), provided that Xxxxxxx shall not withhold their agreement to any Amendment to the extent reasonably necessary to enable PPD’s performance of the Development Plan in a manner resulting in the generation of the Option Criteria. In the event that PPD requests an Amendment to a given Work Order, the Parties shall draft a written change order (“Change Order”) containing an estimate of any Cost changes, effects on existing Deliverables and associated Deliverable Dates, as applicable. The Change Order will be the basis of the Amendment to the applicable Work Order and, upon the Parties agreement with respect to such Amendment, the services set forth therein shall be deemed to be Services as part of such Work Order. In the event there is a dispute regarding the Change Order or its terms, the dispute shall be resolved as specified in Article 14. In the event of any inconsistency between the terms of a Work Order and this Agreement, the terms of this Agreement shall govern.
Work Orders. The specific details of each project under this Agreement (each “Project”) shall be separately negotiated and specified in writing on terms and in a form acceptable to the parties (each such writing, a “Work Order”). A sample Work Order is attached hereto as Exhibit A. Each Work Order will include, as appropriate, the scope of work, time line, and budget and payment schedule. Each Work Order shall be subject to all of the terms and conditions of this Agreement, in addition to the specific details set forth in the Work Order. To the extent any terms or provisions of a Work Order conflict with the terms and provisions of this Agreement, the terms and provisions of this Agreement shall control, except to the extent that the applicable Work Order expressly and specifically states an intent to supersede the Agreement on a specific matter. All Work Orders and other exhibits hereto shall be deemed to be incorporated herein by reference.
Work Orders. When the Contractor believes extra work is warranted he shall promptly notify the Engineer in writing within 2 days of such a determination. Should the Engineer agree with the Contractor’s assessment of extra work then within 7 days or as mutually decided with the Engineer, the Contractor shall determine the extent of such work and detail in his request what additional compensation and/or time he seeks, if any, relative to his determination. The Contractor’s submittal shall be in sufficient detail to enable the Engineer to determine the basis for entitlement. Failure on the part of the Contractor to furnish sufficient documentation or to qualify his reason for failure to do so will delay the determination of entitlement for such work. If such delay occurs, it will in no way relieve the Contractor of his obligation to meet the time limits or other requirements established for the contract or constitute basis for a delay claim on the part of the Contractor. Prior to the actual execution of a work order the Engineer will require the Contractor to provide unit prices for the proposed work that shall be based on the unit prices submitted with the Contractor’s bid (Schedule of Bid items) , and any requested Contract Time extension. If the Contractor requests a time extension, the proposed time extension will only be considered if the work is a controlling work item or affects the critical path for a project milestone or project completion. Any justifiable time extension given must be included at the time the work order is developed. For projects without a critical path method scheduling specification, the Contractor shall include detailed information on how the controlling item of work was affected in accordance with the requirements detailed in that specification. Any time extension given on a Fixed Date contract, including time extensions in accordance with the requirements of Section 108.04 of the Specifications, must be added to the contract by work order. Upon receipt and review of the Contractor’s costs for the proposed work, if it is found that the Contractor’s prices and/or the time differ considerably from the Department’s estimate, the Engineer may request the Contractor to provide support for his unit prices and/or his requested time extension. Where the Department and the Contractor can determine and agree upon an accurate cost and time estimation for the proposed work the Engineer will issue a bilateral work order to authorize the work. When the Con...
Work Orders. School library assistants shall receive work orders only from the principal, the assistant principal or the head teacher-librarian.
Work Orders a) The GLO may directly assign a Work Order to Provider or may request from Provider a statement of its qualifications (“SOQ”) to complete a Work Order. SOQs must fully describe Xxxxxxxx’s demonstrated competence and qualifications to complete the Work Order.
b) If the GLO determines Provider is the most highly qualified to perform the services described in the Work Order, on the basis of demonstrated competence and qualifications, the GLO shall then attempt to negotiate with Provider a fair and reasonable price to complete the Work Order. Upon successful negotiation of a fair and reasonable price, the GLO shall issue a Work Order to Provider. The GLO may issue multiple Work Orders during the term of this Contract, all of which shall be in writing and signed by the Parties. Each Work Order shall include: a scope of services; a list of tasks required; a time schedule; a list of Deliverables, if any; a detailed budget; and other information or conditions necessary for the work. Upon execution by both Parties, each Work Order shall become an Attachment hereto, with this Contract and all Attachments thereafter being referred to collectively as the “Contract.” Provider may not begin work or incur costs related to a Work Order before supplying the GLO with documentation that, in the GLO’s sole judgment, demonstrates that Provider obtained all insurance specified in the Work Order.
c) Nothing in this Contract expresses or guarantees that the GLO will issue Work Orders to Provider. All work requested under this Contract will be requested on an irregular and as-needed basis throughout the Contract term, and the GLO makes no guarantee of volume or usage under this Contract.
Work Orders. There are no outstanding work orders relating to any of the Subject Properties from or required by any Governmental Entity, nor does the Borrower or any Subsidiary have notice of any possible impending or future work order, that in either case, could reasonably be expected to have a Material Adverse Effect.
Work Orders. The SUBCONSULTANT, at the request of the CONSULTANT, shall submit a cost estimate for their portion of the work order cost estimate.
