Shipment Terms Seller shall ship Goods in the method identified by AGILENT to permit Seller to meet the delivery date(s) identified by AGILENT on the face of this Order (“Delivery Date”). If Seller ships by any other method, Seller shall pay any resulting increase in the cost of freight. Except as specified below, shipments of Goods shall be FCA (as that term is defined in the Incoterms 2010 handbook) Seller's place of shipment/export, and title and risk of loss or damage shall pass from Seller to AGILENT upon Seller's delivery of the Goods to the designated carrier at the place of shipment/export. If AGILENT agrees to pay for applicable freight charges and duties as part of the purchase price, shipment shall be DDP, and title and risk of loss or damage shall pass from Seller to AGILENT upon Seller’s delivery of the Goods to the "Ship To" address identified by AGILENT on the face of this Order.
Shipment Dell will ship the APEX System to the Site when included as part of the APEX Service. The terms and process for shipment and delivery of the APEX System will be stated in the applicable Service Offering Description.
API If the Software offers integration capabilities via an API, your use of the API may be subject to additional costs or Sage specific policies and terms and conditions (which shall prevail in relation to your use of the API). You may not access or use the API in any way that could cause damage to us or the Software, or in contravention of any applicable laws. We reserve the right in our sole discretion, to: (i) update any API from time to time; (ii) place limitations around your use of any API; and (iii) deny you access to any API in the event of misuse by you or to otherwise protect our legitimate interests.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Packing Materials and Containers for Shipment Packing materials and containers in which the good is packed for shipment shall be disregarded in determining whether-- (i) the non-originating materials used in the production of the good undergo an applicable change in tariff classification set out in subdivision (t) of this note; and (ii) the good satisfies a regional value-content requirement.
Shipments The Vendor shall ship, deliver or provide ordered products or services within a commercially reasonable time after the receipt of the order from the TIPS Member. If a delay in said delivery is anticipated, the Vendor shall notify TIPS Member as to why delivery is delayed and shall provide an estimated time for completion of the order. TIPS or the requesting entity may cancel the order if estimated delivery time is not acceptable or not as agreed by the parties.
WHEXXXX xs xxxx of a plan of reorganization, RESTART PARTNERS V, L.P., a Delaware Limited Partnership ("Restart V"), may acquire an ownership interest in Elsinore Corporation ("Elsinore") or the Four Queens, Inc. ("FQI");
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and
Manufacturer A firm that operates or maintains a factory or establishment that produces on the premises, the materials or supplies obtained by the Contractor. Regular Dealer - A firm that owns, operates, or maintains a store, warehouse, or other establishment in which the materials or supplies required for the performance of the contract are bought, kept in stock, and regularly sold to the public in the usual course of business. A regular dealer engages in, as its principal business and in its own name, the purchase and sale or lease of the products in question. A regular dealer in such bulk items as steel, cement, gravel, stone, and petroleum products need not keep such products in stock, if it owns and operates distribution equipment for the products. Brokers and packagers are not regarded as manufacturers or regular dealers within the meaning of this section. United States Department of Transportation (USDOT) - Federal agency responsible for issuing regulations (49 CFR Part 26) and official guidance for the DBE program.
Purchase Order A Customer may use purchase orders to buy commodities or contractual services pursuant to the Contract and, if applicable, the Contractor must provide commodities or contractual services pursuant to purchase orders. Purchase orders issued pursuant to the Contract must be received by the Contractor no later than the close of business on the last day of the Contract’s term. The Contractor is required to accept timely purchase orders specifying delivery schedules that extend beyond the Contract term even when such extended delivery will occur after expiration of the Contract. Purchase orders shall be valid through their specified term and performance by the Contractor, and all terms and conditions of the Contract shall survive the termination or expiration of the Contract and apply to the Contractor’s performance. The duration of purchase orders for recurring deliverables shall not exceed the expiration of the Contract by more than twelve months. Any purchase order terms and conditions conflicting with these Special Contract Conditions shall not become a part of the Contract.
