Purchase Order Requirements Customers shall use a Request for Quote per section 287.056(2), Florida Statutes, when making purchases off of this State Term Contract. Customers shall issue Request for Quotes to at least 25 vendors approved to provide IT Staff Augmentation services in accordance with section 287.0591(5), Florida Statutes. Customers shall order services from the Request for Quote via a Purchase Order with the Customers’ selected Contractor. The terms of the Purchase Order shall not conflict with the terms and conditions established by this Contract. In accepting a Purchase Order, the Contractor recognizes its responsibility for all tasks and deliverables contained therein, warrants that it has fully informed itself of all relevant factors affecting accomplishment of the tasks and deliverables and agrees to be fully accountable for the performance thereof.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Development Standards For any structure built on the Property following the Effective Date, it shall comply with the requirements contained in Exhibit B, “Building Materials,” attached hereto and incorporated herein. The Parties agree and acknowledge that the provisions of this Paragraph shall apply to any structure constructed subsequent to the execution of this Agreement. Nothing in this Agreement shall be deemed to modify or otherwise amend any zoning regulation duly adopted by the Town, previously or in the future.
Quality Control Program Engineer shall have a quality control program in place that ensures that all deliverable work is of high quality. Engineer shall submit a plan detailing its program to the Inspection Branch of the TxDOT Bridge Division for review and approval prior to beginning work. State may review or audit the programs.
Approved Services; Additional Services Registry Operator shall be entitled to provide the Registry Services described in clauses (a) and (b) of the first paragraph of Section 2.1 in the Specification 6 attached hereto (“Specification 6”) and such other Registry Services set forth on Exhibit A (collectively, the “Approved Services”). If Registry Operator desires to provide any Registry Service that is not an Approved Service or is a material modification to an Approved Service (each, an “Additional Service”), Registry Operator shall submit a request for approval of such Additional Service pursuant to the Registry Services Evaluation Policy at xxxx://xxx.xxxxx.xxx/en/registries/rsep/rsep.html, as such policy may be amended from time to time in accordance with the bylaws of ICANN (as amended from time to time, the “ICANN Bylaws”) applicable to Consensus Policies (the “RSEP”). Registry Operator may offer Additional Services only with the written approval of ICANN, and, upon any such approval, such Additional Services shall be deemed Registry Services under this Agreement. In its reasonable discretion, ICANN may require an amendment to this Agreement reflecting the provision of any Additional Service which is approved pursuant to the RSEP, which amendment shall be in a form reasonably acceptable to the parties.
Product Specifications (a) Supplier shall manufacture all Products according to the Specifications in effect as of the date of this Agreement, with such changes or additions to the Specifications of the Products related thereto as shall be requested by Buyer in accordance with this Section or as otherwise agreed in writing by the Parties. All other Products shall be manufactured with such Specifications as the Parties shall agree in writing. (b) Buyer may request changed or additional Specifications for any Product by delivering written notice thereof to Supplier not less than one hundred twenty (120) days in advance of the first Firm Order for such Product to be supplied with such changed or additional Specifications. Notwithstanding the foregoing, if additional advance time would reasonably be required in order to implement the manufacturing processes for production of a Product with any changed or additional Specifications, and to commence manufacture and delivery thereof, Supplier shall so notify Buyer, and Supplier shall not be required to commence delivery of such Product until the passage of such additional time. (c) Supplier shall be required to accommodate any change of, or additions to, the Specifications for any Product, if and only if (i) in Supplier’s good faith judgment, such changed or additional Specifications would not require Supplier to violate good manufacturing practice, (ii) the representation and warranty of Buyer deemed made pursuant to Subsection (e) below is true and correct, and (iii) Buyer agrees to reimburse Supplier for the incremental costs and expenses incurred by Supplier in accommodating the changed or additional Specifications, including the costs of acquiring any new machinery and tooling. For the avoidance of doubt, such costs and expenses shall be payable by Buyer separately from the cost of Products at such time or times as Supplier shall request. (d) Supplier shall notify Buyer in writing within thirty (30) days of its receipt of any request for changed or additional Specifications (i) whether Supplier will honor such changed or additional Specifications, (ii) if Supplier declines to honor such changed or additional Specifications, the basis therefor and (iii) if applicable, the estimated costs and expenses that Buyer will be required to reimburse Supplier in respect of the requested changes or additions, as provided in Subsection (c) above. Buyer shall notify Supplier in writing within fifteen (15) days after receiving notice of any required reimbursement whether Buyer agrees to assume such reimbursement obligation. (e) By its request for any changed or additional Specifications for any Product, Buyer shall be deemed to represent and warrant to Supplier that the manufacture and sale of the Product incorporating Buyer’s changed or additional Specifications, as a result of such incorporation, will not and could not reasonably be expected to (i) violate or conflict with any contract, agreement, arrangement or understanding to which Buyer and/or any of its Affiliates is a party, including this Agreement and any other contract, agreement, arrangement or understanding with Supplier and/or its Affiliates, (ii) infringe on any trademark, service xxxx, copyright, patent, trade secret or other intellectual property rights of any Person, or (iii) violate any Applicable Law. Buyer shall indemnify and hold Supplier and its Affiliates harmless (including with respect to reasonable attorneys’ fees and disbursements) from any breach of this representation and warranty.
Commercialization Reports Throughout the term of this Agreement and during the Sell-Off Period, and within thirty (30) days of December 31st of each year, Company will deliver to University written reports of Company’s and Sublicensees’ efforts and plans to develop and commercialize the innovations covered by the Licensed Rights and to make and sell Licensed Products. Company will have no obligation to prepare commercialization reports in years where (a) Company delivers to University a written Sales Report with active sales, and (b) Company has fulfilled all Performance Milestones. In relation to each of the Performance Milestones each commercialization report will include sufficient information to demonstrate achievement of those Performance Milestones and will set out timeframes and plans for achieving those Performance Milestones which have not yet been met.
REGULATORY ADMINISTRATION SERVICES BNY Mellon shall provide the following regulatory administration services for each Fund and Series: Assist the Fund in responding to SEC examination requests by providing requested documents in the possession of BNY Mellon that are on the SEC examination request list and by making employees responsible for providing services available to regulatory authorities having jurisdiction over the performance of such services as may be required or reasonably requested by such regulatory authorities; Assist with and/or coordinate such other filings, notices and regulatory matters and other due diligence requests or requests for proposal on such terms and conditions as BNY Mellon and the applicable Fund on behalf of itself and its Series may mutually agree upon in writing from time to time; and
Computer Equipment Recycling Program If this Contract is for the purchase or lease of computer equipment, then Contractor certifies that it is in compliance with Subchapter Y, Chapter 361 of the Texas Health and Safety Code related to the Computer Equipment Recycling Program and the Texas Commission on Environmental Quality rules in 30 TAC Chapter 328.
Manufacturing Services Jabil will manufacture the Product in accordance with the Specifications and any applicable Build Schedules. Jabil will reply to each proposed Build Schedule that is submitted in accordance with the terms of this Agreement by notifying Company of its acceptance or rejection within three (3) business days of receipt of any proposed Build Schedule. In the event of Jabil’s rejection of a proposed Build Schedule, Jabil’s notice of rejection will specify the basis for such rejection. When requested by Company, and subject to appropriate fee and cost adjustments, Jabil will provide Additional Services for existing or future Product manufactured by Jabil. Company shall be solely responsible for the sufficiency and adequacy of the Specifications [***].
