Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
Determination of One-Month LIBOR Pursuant to the terms of the Global Agency Agreement, the Global Agent shall calculate the Class Coupons for the applicable Classes of Notes (including MAC Notes on which the Exchange Administrator has directed the Global Agent to make payments) for each Accrual Period (after the first Accrual Period) on the applicable LIBOR Adjustment Date. U.S. dollar deposits with a maturity of one month set by ICE Benchmark Administration Limited (“ICE”) as of 11:00 a.m. (London time) on the LIBOR Adjustment Date (the “ICE Method”). ICE’s Interest Settlement Rates are currently displayed on Bloomberg L.P.’s page “BBAM.” That page, or any other page that may replace page BBAM on that service or any other service that ICE nominates as the information vendor to display the ICE’s Interest Settlement Rates for deposits in U.S. dollars, is a “Designated Page.” ICE’s Interest Settlement Rates currently are rounded to five decimal places. If ICE’s Interest Settlement Rate does not appear on the Designated Page as of 11:00 a.m. (London time) on a LIBOR Adjustment Date, or if the Designated Page is not then available, One-Month LIBOR for that date will be the most recently published Interest Settlement Rate. If ICE no longer sets an Interest Settlement Rate, Xxxxxxx Mac will designate an alternative index that has performed, or that Xxxxxxx Mac (or its agent) expects to perform, in a manner substantially similar to ICE’s Interest Settlement Rate.
Sector Sub-Sector Industry Classification Level of Government Type of Obligation Description of Measure Source of Measure All sectors : : - : Central : National Treatment Senior Management and Board of Directors : National Treatment and the Senior Management and Board of Directors obligations shall not apply to any measure relating to small and medium sized domestic market enterprise2. Foreign equity is restricted to a maximum of 40% for domestic market enterprises with paid-in equity capital of less than the equivalent of USD 200,000 Note: Members of the Board of Directors or governing body of corporation or associations shall be allowed in proportion to their allowable participation or share in the capital of such enterprises. : -1987 Constitution of the Republic of the Philippines. - Foreign Investments Act of 1991 (R.A. No. 7042, as amended by R.A. No. 8179). -Presidential and Administrative Issuances. ∞ 2 The concept of a small and medium sized domestic market enterprise is an enterprise with paid in equity capital of less than the equivalent of USD 200,000.00.
Interest Rates and Letter of Credit Fee Rates Payments and Calculations (a) Interest Rates. Except as provided in Section 2.13(c) and Section 2.15(a), all Obligations (except for the undrawn portion of the face amount of Letters of Credit) that have been charged to the Loan Account pursuant to the terms hereof shall bear interest at a per annum rate equal to the lesser of (i) the LIBOR Rate plus the Applicable Margin, or (ii) the maximum rate of interest allowed by applicable laws; provided, that following notice to Borrower in accordance with Section 2.15(a) hereof, all Obligations that have been charged to the Loan Account pursuant to the terms hereof shall bear interest at a per annum rate equal, during the duration of the circumstances described in Section 2.15(a), to the lesser of (A) the Base Rate plus the Applicable Margin as calculated pursuant to Section 2.15(a) or (B) the maximum rate of interest allowable by applicable laws.
Accounting Terms; Utilization of GAAP for Purposes of Calculations Under Agreement Except as otherwise expressly provided in this Agreement, all accounting terms not otherwise defined herein shall have the meanings assigned to them in conformity with GAAP. Financial statements and other information required to be delivered by Company to Lenders pursuant to clauses (ii), (iii) and (xii) of subsection 6.1 shall be prepared in accordance with GAAP as in effect at the time of such preparation (and delivered together with the reconciliation statements provided for in subsection 6.1(v)). Calculations in connection with the definitions, covenants and other provisions of this Agreement shall utilize GAAP as in effect on the date of determination, applied in a manner consistent with that used in preparing the financial statements referred to in subsection 5.3. If at any time any change in GAAP would affect the computation of any financial ratio or requirement set forth in any Loan Document, and Company, Administrative Agent or Requisite Lenders shall so request, Administrative Agent, Lenders and Company shall negotiate in good faith to amend such ratio or requirement to preserve the original intent thereof in light of such change in GAAP (subject to the approval of Requisite Lenders), provided that, until so amended, such ratio or requirement shall continue to be computed in accordance with GAAP prior to such change therein and Company shall provide to Administrative Agent and Lenders reconciliation statements provided for in subsection 6.1(v).
Definition of Grievance A grievance shall be defined as any difference arising out of the interpretation, application, administration, or alleged violation of the Collective Agreement.
Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
How Are Contributions to a Xxxx XXX Reported for Federal Tax Purposes You must file Form 5329 with the IRS to report and remit any penalties or excise taxes. In addition, certain contribution and distribution information must be reported to the IRS on Form 8606 (as an attachment to your federal income tax return.)
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.