Settlement of Third Party Claims Notwithstanding any other provision of this Agreement, the Indemnifying Party shall not enter into settlement of any Third Party Claim without the prior written consent of the Indemnified Party, except as provided in this Section 8.05(b). If a firm offer is made to settle a Third Party Claim without leading to liability or the creation of a financial or other obligation on the part of the Indemnified Party and provides, in customary form, for the unconditional release of each Indemnified Party from all liabilities and obligations in connection with such Third Party Claim and the Indemnifying Party desires to accept and agree to such offer, the Indemnifying Party shall give written notice to that effect to the Indemnified Party. If the Indemnified Party fails to consent to such firm offer within ten days after its receipt of such notice, the Indemnified Party may continue to contest or defend such Third Party Claim and in such event, the maximum liability of the Indemnifying Party as to such Third Party Claim shall not exceed the amount of such settlement offer. If the Indemnified Party fails to consent to such firm offer and also fails to assume defense of such Third Party Claim, the Indemnifying Party may settle the Third Party Claim upon the terms set forth in such firm offer to settle such Third Party Claim. If the Indemnified Party has assumed the defense pursuant to Section 8.05(a), it shall not agree to any settlement without the written consent of the Indemnifying Party (which consent shall not be unreasonably withheld or delayed).
Delay Claim Must Be In Writing Any claim to extend the Contract Time and Material Completion and Occupancy Date must be in writing, must set forth in detail the basis for the claim and the number of days of delay claimed, must be correlated with the approved Overall Project Schedule, must be executed by the Contractor and delivered to the Design Professional and the Owner, and must be reviewed and an appropriate time assessed by the Design Professional.
Settlement of Disputes between the Parties 1. Any dispute between the Parties concerning the interpretation or application of this Chapter shall, as far as possible, be settled with consultation through diplomatic channel. 2. If a dispute cannot thus be settled within 6 months, it shall, upon the request of either Party, be submitted to an ad hoc arbitral tribunal. 3. Such tribunal comprises of 3 arbitrators. Within 2 months of the receipt of the written notice requesting arbitration, each Party shall appoint one arbitrator. Those 2 arbitrators shall, within further 2 months, together select a national of a third State having diplomatic relations with both Parties who, upon approval by the Parties, shall be appointed as Chairman of the arbitral tribunal. 4. If the arbitral tribunal has not been constituted within 4 months from the receipt of the written notice requesting arbitration, either Party may, in the absence of any other agreement, invite the President of the International Court of Justice to make any necessary appointments. If the President is a national of either Party or is otherwise prevented from discharging the said functions, the Member of the International Court of Justice next in seniority who is not a national of either Party or is not otherwise prevented from discharging the said functions shall be invited to make such necessary appointments. 5. The arbitral tribunal shall determine its own procedure. The arbitral tribunal shall reach its award in accordance with the provisions of this Agreement and the principles of international law recognized by both Parties. 6. The arbitral tribunal shall reach its award by a majority of votes. Such award shall be final and binding upon both Parties. The arbitral tribunal shall, upon the request of either Party, explain the reasons of its award. 7. Each Party shall bear the costs of its appointed arbitrator and of its representation in arbitral proceedings. The relevant costs of the Chairman and tribunal shall be borne in equal parts by the Parties.
Settlement of Dispute Any disputes under the Agreement shall be settled at first through friendly consultation between the parties hereto. In case no settlement can be reached through consultation, each party shall have the right to submit such disputes to China International Economic and Trade Arbitration Commission in Beijing. The Place of arbitration is Beijing. The arbitration award shall be final and binding on both parties.
Settlement of Disputes between the Contracting Parties 1. Disputes between the Contracting Parties concerning the interpretation or application of this Agreement should, if possible, be settled through diplomatic channels.
Settlement of Disputes between Contracting Parties (1) Disputes between Contracting Parties regarding the interpretation or application of the provisions of this Agreement shall be settled through official channels.
Settlement of Disputes between an Investor and a Contracting Party
SINGLE FAMILY SHARED-LOSS AGREEMENT This agreement for the reimbursement of loss sharing on certain single family residential mortgage loans (the “Single Family Shared-Loss Agreement”) shall apply when the Assuming Institution purchases Single Family Shared-Loss Loans as that term is defined herein. The terms hereof shall modify and supplement, as necessary, the terms of the Purchase and Assumption Agreement to which this Single Family Shared-Loss Agreement is attached as Exhibit 4.15A and incorporated therein. To the extent any inconsistencies may arise between the terms of the Purchase and Assumption Agreement and this Single Family Shared-Loss Agreement with respect to the subject matter of this Single Family Shared-Loss Agreement, the terms of this Single Family Shared-Loss Agreement shall control. References in this Single Family Shared- Loss Agreement to a particular Section shall be deemed to refer to a Section in this Single Family Shared-Loss Agreement, unless the context indicates that it is intended to be a reference to a Section of the Purchase and Assumption Agreement.
Shared Transport The Shared Transport Network Element (“Shared Transport”) provides the collective interoffice transmission facilities shared by various Carriers (including Qwest) between end-office switches and between end-office switches and local tandem switches within the Local Calling Area. Shared Transport uses the existing routing tables resident in Qwest switches to carry the End User Customer’s originating and terminating local/extended area service interoffice Local traffic on the Qwest interoffice message trunk network. CLEC traffic will be carried on the same transmission facilities between end- office switches, between end-office switches and tandem switches and between tandem switches on the same network facilities that Qwest uses for its own traffic. Shared Transport does not include use of tandem switches or transport between tandem switches and end-office switches for Local Calls that originate from end users served by non- Qwest Telecommunications Carriers (“Carrier(s)”) which terminate to QLSP End Users.
Submitting False Claims The full text of San Francisco Administrative Code Chapter 21, Section 21.35, including the enforcement and penalty provisions, is incorporated into this Agreement. Pursuant to San Francisco Administrative Code §21.35, any contractor or subcontractor who submits a false claim shall be liable to the City for the statutory penalties set forth in that section. A contractor or subcontractor will be deemed to have submitted a false claim to the City if the contractor or subcontractor: (a) knowingly presents or causes to be presented to an officer or employee of the City a false claim or request for payment or approval;