Sovereign Immunity The State reserves all immunities, defenses, rights or actions arising out of the State’s sovereign status or under the Eleventh Amendment to the United States Constitution. No waiver of the State’s immunities, defenses, rights or actions shall be implied or otherwise deemed to exist by reason of the State’s entry into this Agreement.
Limited Waiver of Sovereign Immunity Ex Contractu Contractor acknowledges and agrees that Owner is an agency or instrumentality of the State of Georgia, and as such is entitled to the protection of sovereign immunity. As set forth in Article I, Section II, Paragraph IX of the 1983 Georgia Constitution, sovereign immunity is waived “as to any action ex contractu for the breach of any written contract.” Contractor specifically acknowledges the constitutional and contractual requirements that written changes, modifications, and waivers to this Contract must be specifically executed by the Owner as set forth in the Contract Documents. Accordingly, Contractor specifically acknowledges the constitutional prohibitions against claims against Owner based solely upon oral statement, course of conduct, customs of the trade, quasi-contract, quantum meruit, or O.C.G.A § 13-4-4 (mutual departure from contract terms).
Waiver of Sovereign Immunity Each Loan Party that is incorporated outside the United States, in respect of itself, its Subsidiaries, its process agents, and its properties and revenues, hereby irrevocably agrees that, to the extent that such Loan Party or its respective Subsidiaries or any of its or its respective Subsidiaries’ properties has or may hereafter acquire any right of immunity, whether characterized as sovereign immunity or otherwise, from any legal proceedings, whether in the United States or elsewhere, to enforce or collect upon the Loans or any Loan Document or any other liability or obligation of such Loan Party or any of their respective Subsidiaries related to or arising from the transactions contemplated by any of the Loan Documents, including, without limitation, immunity from suit, immunity from service of process, immunity from jurisdiction or judgment of any court or tribunal, immunity from execution of a judgment, and immunity of any of its property from attachment prior to any entry of judgment, or from attachment in aid of execution upon a judgment, such Loan Party, for itself and on behalf of its Subsidiaries, hereby expressly waives, to the fullest extent permissible under applicable law, any such immunity, and agrees not to assert any such right or claim in any such proceeding, whether in the United States or elsewhere. Without limiting the generality of the foregoing, each Loan Party further agrees that the waivers set forth in this Section 10.25 shall have the fullest extent permitted under the Foreign Sovereign Immunities Act of 1976 of the United States and are intended to be irrevocable for purposes of such Act.
OF CLEAN AIR ACT AND FEDERAL WATER POLLUTION CONTROL ACT This provision is applicable to all Federal-aid construction contracts and to all related subcontracts. By submission of this bid/proposal or the execution of this contract, or subcontract, as appropriate, the bidder, proposer, Federal-aid construction contractor, or subcontractor, as appropriate, will be deemed to have stipulated as follows:
Clean Air Act and Federal Water Pollution Control Act 1. The contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act, as amended, 42 U.S.C. § 7401 et seq.
BUY AMERICA REQUIREMENT (Applies only to Federally Funded Highway and Transit Projects) With respect to products purchased by Customer for use in federally funded highway projects, Contractor shall comply with all federal procurement laws and regulations with respect to such projects, including the Buy American provisions set forth in 23 U.S.C. Section 313, 23 C.F.R. Section 635.410, as amended, and the Steel and Iron Preference provisions of Texas Transportation Code Section 223.045, to the extent applicable. Contractor agrees to provide all certifications required by Customer regarding such programs. With respect to products purchased by Customer for use in federally funded transit projects, Contractor shall comply with all federal procurement laws and regulations with respect to such projects, including the Buy American provisions set forth in 49 U.S.C. Section 5323(j)(1), 49 C.F.R. Sections 661.6 or 661.12, to the extent applicable. Contractor agrees to provide all certifications required by Customer regarding such programs.
Program Requirements Provided At No Charge to the Judicial Council A. The Contractor shall provide the following items during the Program at no charge to the Judicial Council:
Please see the current Washtenaw Community College catalog for up-to-date program requirements Secondary / Post-Secondary Program Alignment Welding HIGH SCHOOL COURSE SEQUENCE 9th Grade 10th Grade 11th Grade 12th Grade English 9 Algebra I World History/Geography Biology World Language Phys Ed/Health English 10 Geometry U.S. History/Geography Physics or Chemistry World Language Visual/Performing/Applied Arts English 11 Algebra II Civics/Economics Welding English 12 Math Credit Science Credit Welding WASHTENAW COMMUNITY COLLEGE Welding Associate in Applied Science Semester 1 Math Elective(s)* 3 WAF 105 Introduction to Welding Processes 2 WAF 111 Oxy-fuel Welding 4 WAF 112 Shielded Metal Arc Welding 4 Semester Total 13 Semester 2 Speech Elective(s) 3 WAF 106 Blueprint Reading for Welders 3 WAF 123 Advanced Oxy-fuel Welding 4 WAF 124 Advanced Shielded Metal Arc Welding 4 Semester Total 14 Semester 3 Arts/Human. Elective(s) 3 Computer Lit. Elective(s) 3 WAF 215 Advanced Gas Tungsten Arc Welding 4 WAF 288 Gas Metal Arc Welding 4 Semester Total 14 Semester 4 WAF 200 Layout Theory Welding 3 WAF 210 Welding Metallurgy 3 Soc. Sci. Elective(s) 3 WAF 226 Specialized Welding Procedures 4 Semester Total 13 Semester 5 Nat. Sci. Elective(s) 4 WAF 227 Basic Fabrication 3 WAF 229 Shape Cutting Operations 3 Writing Elective(s) 3 Semester Total 13 Program Totals 67
No Waiver of Sovereign Immunity or Powers Nothing in this agreement will be deemed to constitute a waiver of sovereign immunity or powers of licensee, the Xxxxxxxxxx County Commissioners Court, or the Xxxxxxxxxx County Judge.
No Waiver of Sovereign Immunity Nothing in the Contract will be construed as a waiver of the System Agency’s or the State’s sovereign immunity. This Contract shall not constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas under the Contract or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. System Agency does not waive any privileges, rights, defenses, or immunities available to System Agency by entering into the Contract or by its conduct prior to or subsequent to entering into the Contract.
