Attachment C, Standard State Provisions for Contracts and Grants Attachment C is hereby deleted in its entirety and replaced by the Attachment C December 15, 2017 attached to this Amendment. Child Support (Applicable to natural persons only; not applicable to corporations, partnerships or LLCs). Contractor is under no obligation to pay child support or is in good standing with respect to or in full compliance with a plan to pay any and all child support payable under a support order as of the date of this amendment.
Certain State Law Requirements for Contracts The contents of this Section are required by Texas Law and are included by County regardless of content. For purposes of Sections 2252.152, 2271.002, and 2274.002, Texas Government Code, as amended, C&T hereby verifies that C&T and any parent company, wholly owned subsidiary, majority-owned subsidiary, and affiliate:
a. Unless affirmatively declared by the United States government to be excluded from its federal sanctions regime relating to Sudan or Iran or any federal sanctions regime relating to a foreign terrorist organization, is not identified on a list prepared and maintained by the Texas Comptroller of Public Accounts under Sections 806.051, 807.051, or 2252.153 of the Texas Government Code.
b. If employing ten (10) or more full-time employees and this Agreement has a value of
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Special Provisions Check if Required ✔ If checked, the Supplemental State Terms and attached hereto as Exhibit “G” are hereby incorporated by reference into this DPA in their entirety. ✔ If checked, the Provider, has signed Exhibit “E” to the Standard Clauses, otherwise known as General Offer of Privacy Terms
Special Provisions for Affected Systems For the re-payment of amounts advanced to Affected System Operator for System Upgrade Facilities or System Deliverability Upgrades, the Developer and Affected System Operator shall enter into an agreement that provides for such re-payment, but only if responsibility for the cost of such System Upgrade Facilities or System Deliverability Upgrades is not to be allocated in accordance with Attachment S to the ISO OATT. The agreement shall specify the terms governing payments to be made by the Developer to the Affected System Operator as well as the re-payment by the Affected System Operator.
Other Definitional Provisions; Construction Whenever the context so requires, the neuter gender includes the masculine and feminine, the single number includes the plural, and vice versa. The words “hereof”, “herein” and “hereunder” and words of similar import when used in this Agreement shall refer to this Agreement as a whole and not to any particular provision of this Agreement, and references to Article, Section, Subsection, Annex, Schedule, Exhibit and like references are references to this Agreement unless otherwise specified. Wherever the word “include,” “includes” or “including” is used in this Agreement, it will be deemed to be followed by the words “without limitation.” An Event of Default shall “continue” or be “continuing” until such Event of Default has been waived in accordance with Section 13.3 hereof. References in this Agreement to any party shall include such party’s successors and permitted assigns. References to any “Section” shall be a reference to such Section of this Agreement unless otherwise stated. To the extent any of the provisions of the other Loan Documents are inconsistent with the terms of this Agreement, the provisions of this Agreement shall govern.
General Provisions Applicable to Loans Section 6.1 Minimum Amounts for Committed Borrowings, Conversions or Continuations and Prepayments.
General Contract Provisions Any and all Schedules to this Agreement form a part hereof. No amendment, waiver, discharge or release of this Agreement shall be binding or enforceable unless made in writing signed by all of the parties hereto. Time is and shall remain of the essence under and pursuant to this Agreement; provided that the time for performing or completing any matter under or pursuant to this Agreement may be extended or abridged by an agreement in writing by the parties or their respective solicitors. Failure by any party to strictly enforce any provisions hereof shall not operate as a waiver or limitation of such party's rights hereunder in respect of any subsequent default. If any provision of this Agreement or the application thereof to any person or circumstance is to any extent held or rendered invalid, unenforceable or illegal, same shall be considered separate and severable herefrom and all other provisions of this Agreement shall remain in full force and effect and be binding upon the parties hereof. The headings set forth in this Agreement are inserted for convenience and reference only and shall in no way define or limit the intent or interpretation of any of the provisions hereof. Wherever in this Agreement any subject matter is described as including specifically described persons, things, events or other items, unless expressly stated to the contrary, the word “including” or any other derivation or variation of that word means, as the case may be, “including, without limitation,” or “including, without limiting the generality of the foregoing,” or such derivation or variation thereof as required by the context. This Agreement shall be read and construed with all changes of gender and number of the party or parties referred to in each case as required by the context, and the covenants and agreements of each party shall be deemed to be joint and several where such party is more than one person, firm or corporation. With respect to each party which is a partnership, each person who is presently a partner of such partnership and each person who becomes a partner of such partnership shall be and continue to be jointly and severally liable for all covenants and agreements of such party notwithstanding that any such person subsequently ceases to be a partner of such partnership, subject to and only to the extent of the limited liability of any such person that is a limited partner of such partnership.
Additional Provisions Respecting Insurance (a) All insurance required by this Tenant Agency Compliance Agreement shall be procured and maintained in financially sound and generally recognized responsible insurance companies authorized to write such insurance in the State and selected by the entity required to procure the same. The company issuing the policies required by Section 2.1(a) hereof shall be rated “A” or better by A.M. Best Co., Inc. in Best’s Key Rating Guide. Such insurance may be written with deductible amounts comparable to those on similar policies carried by other companies engaged in businesses similar in size, character and other respects to those in which the procuring entity is engaged. All policies of insurance required by Section 2.1 hereof shall provide for at least thirty (30) days prior written notice to the Agency of the restriction, cancellation or modification thereof. The policy evidencing the insurance required by Section 2.1(c) hereof shall name the Agency as an additional insured. All policies evidencing the insurance required by Section 2.1 (d)(ii) and (iv) shall name the Agency and the Tenant as additional insureds.
(b) The certificate of insurance required by Section 2.1(c) hereof shall be delivered to the Agency on or before the date hereof. A copy of the certificates of insurance required by Section 2.1(d)(ii) and (iv) hereof shall be delivered to the Agency on or before the commencement of any construction or renovation of the Demised Premises. The Tenant shall deliver to the Agency before the first Business Day of each calendar year thereafter a certificate dated not earlier than the immediately preceding month reciting that there is in full force and effect, with a term covering the current year of the Tenant’s insurance policy, insurance of the types and in the amounts required by Section 2.1 hereof and complying with the additional requirements of Section 2.2(a) hereof. Prior to the expiration of each such policy or policies, the Tenant shall furnish to the Agency and any other appropriate Person a new policy or policies of insurance or evidence that such policy or policies have been renewed or replaced or are no longer required by this Tenant Agency Compliance Agreement. The Tenant shall provide such further information with respect to the insurance coverage required by this Tenant Agency Compliance Agreement as the Agency may from time to time reasonably require.
Additional Provisions Concerning the Collateral (a) To the maximum extent permitted by applicable law, and for the purpose of taking any action that the Collateral Agent may deem necessary or advisable to accomplish the purposes of this Agreement, each Grantor hereby (i) authorizes the Collateral Agent to execute any such agreements, instruments or other documents in such Grantor’s name and to file such agreements, instruments or other documents in such Grantor’s name and in any appropriate filing office, (ii) authorizes the Collateral Agent at any time and from time to time to file, one or more financing or continuation statements, and amendments thereto, relating to the Collateral (including, without limitation, any such financing statements that (A) describe the Collateral as “all assets” or “all personal property” (or words of similar effect) or that describe or identify the Collateral by type or in any other manner as the Collateral Agent may determine regardless of whether any particular asset of such Grantor falls within the scope of Article 9 of the Code or whether any particular asset of such Grantor constitutes part of the Collateral, and (B) contain any other information required by Part 5 of Article 9 of the Code for the sufficiency or filing office acceptance of any financing statement, continuation statement or amendment, including, without limitation, whether such Grantor is an organization, the type of organization and any organizational identification number issued to such Grantor) and (iii) ratifies such authorization to the extent that the Collateral Agent has filed any such financing or continuation statements, or amendments thereto, prior to the date hereof. A photocopy or other reproduction of this Agreement or any financing statement covering the Collateral or any part thereof shall be sufficient as a financing statement where permitted by law.
(b) Each Grantor hereby irrevocably appoints the Collateral Agent as its attorney-in-fact and proxy, with full authority in the place and stead of such Grantor and in the name of such Grantor or otherwise, from time to time in the Collateral Agent’s discretion, to take any action and to execute any instrument which the Collateral Agent may deem necessary or advisable to accomplish the purposes of this Agreement, including, without limitation, (i) to obtain and adjust insurance required to be paid to the Collateral Agent pursuant to Section 6(e) hereof, (ii) to ask, demand, collect, sue for, recover, compound, receive and give acquittance and receipts for moneys due and to become due under or in respect of any Collateral, (iii) to receive, endorse, and collect any drafts or other Instruments, Documents and Chattel Paper in connection with clause (i) or (ii) above, (iv) to file any claims or take any action or institute any action, suit or proceedings which the Collateral Agent may deem necessary or desirable for the collection of any Collateral or otherwise to enforce the rights of the Collateral Agent and the Noteholders with respect to any Collateral, (v) to execute assignments, licenses and other documents to enforce the rights of the Collateral Agent and the Noteholders with respect to any Collateral, and (vi) to verify any and all information with respect to any and all Accounts. This power is coupled with an interest and is irrevocable until all of the Obligations are fully performed and Paid in Full.
(c) For the purpose of enabling the Collateral Agent to exercise rights and remedies hereunder, at such time as the Collateral Agent shall be lawfully entitled to exercise such rights and remedies, and for no other purpose, each Grantor hereby grants to the Collateral Agent, to the extent assignable, an irrevocable, non-exclusive license (exercisable without payment of royalty or other compensation to any Grantor) to use, assign, license or sublicense any Intellectual Property in which such Grantor now or hereafter has any right, title or interest, wherever the same may be located, including, without limitation, in such license reasonable access to all media in which any of the licensed items may be recorded or stored and to all computer programs used for the compilation or printout thereof. Notwithstanding anything contained herein to the contrary, but subject to the provisions of the Securities Purchase Agreement that limit the right of any Grantor to dispose of its property, and Section 6(g) and Section 6(h) hereof, so long as no Event of Default shall have occurred and be continuing, any Grantor may exploit, use, enjoy, protect, license, sublicense, assign, sell, dispose of or take other actions with respect to the Intellectual Property in the ordinary course of its business and as otherwise expressly permitted by any of the other Transaction Documents. In furtherance of the foregoing, unless an Event of Default shall have occurred and be continuing, the Collateral Agent shall from time to time, upon the request of any Grantor, execute and deliver any instruments, certificates or other documents, in the form so requested, which such Grantor shall have certified are appropriate (in such Grantor’s judgment) to allow it to take any action permitted above (including relinquishment of the license provided pursuant to this clause (c) as to any Intellectual Property). Further, upon the full performance and Payment in Full of all of the Obligations, the Collateral Agent (subject to Section 11(e) hereof) shall release and reassign to any Grantor all of the Collateral Agent’s right, title and interest in and to the Intellectual Property, and the Licenses, all without recourse, representation or warranty whatsoever. The exercise of rights and remedies hereunder by the Collateral Agent shall not terminate the rights of the holders of any licenses or sublicenses theretofore granted by each Grantor in accordance with the second sentence of this clause (c). Each Grantor hereby releases the Collateral Agent from any claims, causes of action and demands at any time arising out of or with respect to any actions taken or omitted to be taken by the Collateral Agent under the powers of attorney granted herein other than actions taken or omitted to be taken through the Collateral Agent’s gross negligence or willful misconduct, as determined by a final judgment of a court of competent jurisdiction no longer subject to appeal.
(d) If any Grantor fails to perform any agreement or obligation contained herein, the Collateral Agent may itself perform, or cause performance of, such agreement or obligation, in the name of such Grantor or the Collateral Agent, and the expenses of the Collateral Agent incurred in connection therewith shall be payable by such Grantor pursuant to Section 9 hereof and such obligation shall be secured by the Collateral.
(e) The powers conferred on the Collateral Agent hereunder are solely to protect its interest in the Collateral and shall not impose any duty upon it to exercise any such powers. Except for the safe custody of any Collateral in its possession and the accounting for moneys actually received by it hereunder, the Collateral Agent shall have no duty as to any Collateral or as to the taking of any necessary steps to preserve rights against prior parties or any other rights pertaining to any Collateral.
(f) Anything herein to the contrary notwithstanding (i) each Grantor shall remain liable under the Licenses and otherwise with respect to any of the Collateral to the extent set forth therein to perform all of its obligations thereunder to the same extent as if this Agreement had not been executed, (ii) the exercise by the Collateral Agent of any of its rights or remedies hereunder shall not release any Grantor from any of its obligations under the Licenses or otherwise in respect of the Collateral, and (iii) the Collateral Agent shall not have any obligation or liability by reason of this Agreement under the Licenses or with respect to any of the other Collateral, nor shall the Collateral Agent be obligated to perform any of the obligations or duties of any Grantor thereunder or to take any action to collect or enforce any claim for payment assigned hereunder.
(g) As long as no Event of Default shall have occurred and be continuing and, other than in the case of a Bankruptcy Event of Default, until written notice shall be given to the applicable Grantor:
(i) Each Grantor shall have the right, from time to time, to vote and give consents with respect to the Pledged Equity, or any part thereof for all purposes not inconsistent with the provisions of this Agreement, the Securities Purchase Agreement or any other Transaction Document; provided, however, that no vote shall be cast, and no consent shall be given or action taken, which would have the effect of impairing the position or interest of the Collateral Agent in respect of the Pledged Equity or which would authorize, effect or consent to (unless and to the extent expressly permitted by the Securities Purchase Agreement):
(A) the dissolution or liquidation, in whole or in part, of a Pledged Entity;
(B) the consolidation or merger of a Pledged Entity with any other Person;
(C) the sale, disposition or encumbrance of all or substantially all of the assets of a Pledged Entity, except for Liens in favor of the Collateral Agent;
(D) any change in the authorized number of shares, the stated capital or the authorized share capital of a Pledged Entity or the issuance of any additional shares of its Capital Stock; or
(E) the alteration of the voting rights with respect to the Capital Stock of a Pledged Entity.
(i) Each Grantor shall be entitled, from time to time, to collect and receive for its own use all cash dividends and interest paid in respect of the Pledged Equity to the extent not in violation of the Securities Purchase Agreement other than any and all: (A) dividends and interest paid or payable other than in cash in respect of any Pledged Equity, and instruments and other property received, receivable or otherwise distributed in respect of, or in exchange for, any Pledged Equity; (B) dividends and other distributions paid or payable in cash in respect of any Pledged Equity in connection with a partial or total liquidation or dissolution or in connection with a reduction of capital, capital surplus or paid-in capital of a Pledged Entity; and (C) cash paid, payable or otherwise distributed, in respect of principal of, or in redemption of, or in exchange for, any Pledged Equity; provided, however, that until actually paid all rights to such distributions shall remain subject to the Lien created by this Agreement; and
(ii) all dividends and interest (other than such cash dividends and interest as are permitted to be paid to any Grantor in accordance with clause (i) above) and all other distributions in respect of any of the Pledged Equity, whenever paid or made, shall be delivered to the Collateral Agent to hold as Pledged Equity and shall, if received by any Grantor, be received in trust for the benefit of the Collateral Agent (for the ratable benefit of the Collateral Agent and the Noteholders), be segregated from the other property or funds of such Grantor, and be forthwith delivered to the Collateral Agent as Pledged Equity in the same form as so received (with any necessary endorsement).
