SPECIFIC ACT OF GOD OR FORCE MAJEURE Sample Clauses

SPECIFIC ACT OF GOD OR FORCE MAJEURE. Exclusively, when an Act of God or Force Majeure takes place, existing of hydro meteorological events (excessive generalized rain or generalized anticipation of rain) that have as consequence that the Contractor (i) cannot divert the river before November 30, 2003 or (ii) cannot make the Final Closing before July 1st, 2006, and that take place curing the thirty Days preceding the dates mentioned in items (i) and (ii) above, the Contractor, besides complying with the obligations provided in clauses 27.1 and 27.2, must agree with the Commission which are the affected Works and the measures to secure them, as well as the actions that the Contractor must consider as regards its personnel, machinery and construction equipment related with the affected Works and the adjustments 165 that, tentatively, will have to be made to the Execution Schedule, once the Act of God or Force Majeure comes to an end, drawing up to that effect a minute that shall be signed by both parties. The Dates of affected Critical Events shall be extended in equal proportion to the period that comprises the Act of God or of Force Majeure describe above and its effects, without this signifying to amend the originally agreed Execution Term. The formalization of said extension shall be made through an agreement. Once the works are resumed, the Contractor may request, only, the payment of: (i) rehabilitation or replacement of the damaged or destroyed Works, in case these exist; (ii) the non recoverable expenses that are generated during the suspension of the affected Works, limited to the payroll or watchmen and conservation and vigilance personnel of the affected Works, assigned during the suspension, the costs of work management as to fees, wages and fringe benefits of the strictly necessary technical and management personnel and who have a specific function during the suspension; the strictly necessary labor and that has a specific function during the suspension and who has not been transferred to another work front; and (iii) the reasonable, documented and directly related with the affected Works financial expenses during the period of the suspension, in terms of the provisions of article 119 of the Regulations to the Law of Public Works and Services Related to Them. The respective payments shall be agreed upon in an agreement entered into subject to article 59 of the Law of Public Works and Services Related with Them.
Sample 1
AutoNDA by SimpleDocs

Related to SPECIFIC ACT OF GOD OR FORCE MAJEURE

  • No Force Majeure Event There shall not have been any delay, error, failure or interruption in the conduct of the business of the Acquiror Company, or any loss, injury, delay, damage, distress, or other casualty, due to force majeure including but not limited to (a) acts of God; (b) fire or explosion; (c) war, acts of terrorism or other civil unrest; or (d) national emergency.

  • Force Majeure In no event shall the Trustee be responsible or liable for any failure or delay in the performance of its obligations hereunder arising out of or caused by, directly or indirectly, forces beyond its control, including, without limitation, strikes, work stoppages, accidents, acts of war or terrorism, civil or military disturbances, nuclear or natural catastrophes or acts of God, and interruptions, loss or malfunctions of utilities, communications or computer (software and hardware) services; it being understood that the Trustee shall use reasonable efforts which are consistent with accepted practices in the banking industry to resume performance as soon as practicable under the circumstances.

  • Force Majeure Events The Parties shall be excused from any failure to perform any obligation hereunder to the extent such failure is caused by a Force Majeure Event. A Force Majeure Event shall operate to excuse a failure to perform an obligation hereunder only for the period of time during which the Force Majeure Event renders performance impossible or infeasible and only if the Party asserting Force Majeure as an excuse for its failure to perform has provided written notice to the other Party specifying the obligation to be excused and describing the events or conditions constituting the Force Majeure Event. As used herein, “Force Majeure Event” means the occurrence of an event or circumstance beyond the reasonable control of the party failing to perform, including, without limitation, (a) explosions, fires, flood, earthquakes, catastrophic weather conditions, or other elements of nature or acts of God; (b) acts of war (declared or undeclared), acts of terrorism, insurrection, riots, civil disorders, rebellion or sabotage; (c) acts of federal, state, local or foreign governmental authorities or courts; (d) labor disputes, lockouts, strikes or other industrial action, whether direct or indirect and whether lawful or unlawful; (e) failures or fluctuations in electrical power or telecommunications service or equipment; and (f) delays caused by the other Party’s nonperformance hereunder.

  • Termination for Force Majeure In the event of a force majeure that lasts longer than thirty (30) days from the date that a Party claiming relief due to the force majeure event gives notice to the other Party, the Party not claiming relief under the force majeure event may terminate this Agreement upon written notice to the other Party. For the avoidance of doubt, the COVID-19 pandemic does not constitute a force majeure event.

  • Force Majeur Except with respect to obligations to make payments hereunder, neither party shall be deemed in default hereunder, nor shall it hold the other party responsible for, any cessation, interruption or delay in the performance of its obligations hereunder due to causes beyond its reasonable control including, but not limited to: earthquake, flood, fire, storm or other natural disaster, act of God, labor controversy or threat thereof, civil disturbance or commotion, disruption of the public markets, war or armed conflict or the inability to obtain sufficient material, supplies, labor, transportation, power or other essential commodity or service required in the conduct of its business, including internet access, or any change in or the adoption of any law, ordinance, rule, regulation, order, judgment or decree.

  • Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:—

  • MAJEURE A party is not liable for failure to perform the party’s obligations if such failure is as a result of acts of God (including fire, flood, earthquake, storm, hurricane or other natural disaster), pandemic, war, invasion, act of foreign enemies, hostilities (regardless of whether war is declared), civil war, rebellion, revolution, insurrection, military or usurped power or confiscation, terrorist activities, nationalization, decrees of a court, tribunal or governmental authority, government sanction, blockage, embargo, labor dispute, strike, or lockout. If a party asserts any force majeure as an excuse for failure to perform, such non-performing party must prove that it took reasonable steps to minimize delay or damages caused by foreseeable events and that the other Party was timely notified of the likelihood or actual occurrence of a force majeure event. In the event of non-performance and/or termination pursuant to this Section 8.16, notwithstanding any other provision of this Agreement, the Xxxxxxx Money shall be returned to the Operating Partnership in full.

  • Event of Force Majeure The Recipient will not be in default by reason only of any failure in the performance of the Project in accordance with Schedule 1 – Statement of Work if such failure arises without the fault or negligence of the Recipient and is caused by any event of Force Majeure.

  • Events of Force Majeure Neither Party shall be held liable or responsible to the other Party nor be deemed to be in default under, or in breach of any provision of, this Agreement for failure or delay in fulfilling or performing any obligation of this Agreement when such failure or delay is due to force majeure, and without the fault or negligence of the Party so failing or delaying. For purposes of this Agreement, force majeure is defined as causes beyond the control of the Party, including, without limitation, acts of God; acts, regulations, or laws of any government; war; civil commotion; destruction of production facilities or materials by fire, flood, earthquake, explosion or storm; labor disturbances; epidemic; and failure of public utilities or common carriers. In such event Medistem or Licensee, as the case may be, shall immediately notify the other Party of such inability and of the period for which such inability is expected to continue. The Party giving such notice shall thereupon be excused from such of its obligations under this Agreement as it is thereby disabled from performing for so long as it is so disabled and the 30 days thereafter. To the extent possible, each Party shall use reasonable efforts to minimize the duration of any force majeure.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!