Majeure means any cause, which is beyond the control of the Implementation Partner or MSEGS as the case may be, which such party could not foresee or with a reasonable amount of diligence could not have foreseen, and which substantially affect the performance of the Contract, such as:- - War / hostilities - Riot or civil commotion - Earth Quake, Flood, Fire, Tempest, Epidemics, Lightning or other natural physical Disaster, Quarantine restricts and Freight embargoes - Restrictions imposed by the Government or other statutory bodies, beyond the control of the Implementation Partner, which prevent or delay the execution of the order by the Implementation Partner.
Majeure and shall include, but not limited to, earthquake, fire, explosion, storm, flood, lightning or war.
9.2 Neither Party shall bear any liability for breach of contract if it fails to perform all or any of its obligations hereunder as a result of an event of Force Majeure. However, the Party or Parties affected by an event of Force Majeure shall, within fifteen days of the occurrence of such event, notify the other Party of the details of such event of Force Majeure along with the relevant proof.
9.3 A Party/the Parties shall resume the performance of its/their obligations hereunder after the effects of such event of Force Majeure have been eliminated.
Majeure means acts of God, strikes, explosions, fires, flood, embargo, storm, or acts of war or terrorism that directly prevent the Company from conducting its business. Upon the occurrence of an event of Force Majeure, the Shareholders shall immediately provide the Parent with written notice thereof (the "FORCE MAJEURE NOTICE"). The Earn-Out Period shall be suspended from the date on which the Force Majeure Notice is received by Parent until such condition no longer prevents the Company from conducting its business. The Earn-Out Period shall be extended by the number of days such Earn-Out Period is suspended hereunder. Notwithstanding the foregoing, in no event shall any Earn-Out Period be extended pursuant to this Subsection 1.4.1 for more than an aggregate of ninety (90) days. The Shareholders shall use all reasonable efforts to prevent and reduce to a minimum and mitigate the effect of any event of Force Majeure, and to ensure resumption of normal business operations after the termination of any event of Force Majeure.
Examples of Majeure in a sentence
If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon.
Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch.
In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.
Without limiting any other rights or obligations of the parties hereunder, if the Supplier will be unable to deliver the goods by the delivery date(s) stipulated in this Purchase Order, the Supplier shall (i) immediately consult with UNDP to determine the most expeditious means for delivering the goods and (ii) use an expedited means of delivery, at the Supplier's cost (unless the delay is due to Force Majeure), if reasonably so requested by UNDP.
The State and the Contractor shall not be excused from their obligation to Perform in accordance with the Contract except in the case of Force Majeure events and as otherwise provided for in the Contract.
More Definitions of Majeure
Majeure. Neither SOVEREIGN OIL nor NORTH AMERICAN shall be construed to be in default of this Agreement to the extent either party fails to perform its obligations or duties due to forces beyond its control, including but not limited to, acts of nature, floods, fire, explosions, strikes or other labor disturbances, failure in, or inability to obtain on reasonable terms raw materials, finished products, transportation, storage and/or manufacturing facilities, breakage or malfunction, governmental, or interruptions of operations caused by acts of war or other government restraint, law or regulation. Should SOVEREIGN OIL or NORTH AMERICAN believe that a Force Majeure conditions exists, the other party shall be notified within 5-business days of such event. If such condition(s) arise that causes work stoppage, and/or reduced site use, and cannot be remedied within forty-five (45) days from the date of notice, the other party may terminate this Agreement by providing written notice of termination.
Majeure means any acts or omissions of any civil or military authority, acts of God, wars, hostilities, terrorism, acts or omissions of the Company, fires, strikes or other labor disturbances, equipment failures, fluctuations or non availability of electrical power, heat, light, air conditioning or telecommunications equipment, or any other act, omission or occurrence beyond the Administrator’s reasonable control, irrespective of whether similar to the foregoing enumerated acts, omissions or occurrences.
Majeure means the following events or circumstances, but only to the extent that they delay or preclude the City or Contractor from performing any of its obligations (other than payment obligation) under this Agreement: (a) a hurricane, tornado, flood, fire, explosion (except those caused by the negligence of Contractor, its agents, and assigns), land slide, earthquake, or epidemic; (b) acts of a public enemy, acts of war, terrorism, insurrection, riots, civil disturbances, or national or international calamities; (c) suspension, termination, or interruption of utilities necessary to a Party's operations or duties under this Agreement; (d) an injunction, or a legal or equitable proceeding brought against the City or Contractor, or a Change in Law; and (e) any act, event, or condition, which is determined by mutual agreement of the City and the Contractor to be of the same general type as the events of Force Majeure identified in Sections 1.44 (a) through (d), above. Disaster Declaration
Majeure as used herein shall mean circumstances not reasonably within the control of the parties, such as without limitation, acts of God, strikes, lockouts or other industrial disturbances; war; acts of public enemies; mobilization or military conscription on a large scale; order of any kind of the government of the United States or any State, or any civil or military authority other than the County Council; insurrections; riots; landslides; earthquakes; fires; lightning; storms; droughts; floods; requisitions, confiscation, or commandeering of property; fuel restrictions; general shortages of transport, goods, or energy; or
Majeure as used herein shall include the following: acts of God; strikes, lockouts or other industrial disturbances; acts of public enemies; orders of any kind of the government of the United States or of the State of New York or any of their departments, agencies, or officials, or any civil or military authority; insurrections; riots; epidemics; landslides; lightning; earthquake; fire; typhoons; storms; floods; washouts; droughts; arrests; civil disturbances; explosions; breakage or accident to machinery, transmission pipes or canals; partial or entire failure of utilities; or any other cause or event not reasonably within the control of the Company. The Company agrees, however, to remedy with all reasonable dispatch the cause or causes preventing the Company from carrying out its agreements; provided, that the settlement of strikes, lockouts and other industrial disturbances shall be entirely within the discretion of the Company, and the Company shall not be required to make settlement of strikes, lockouts and other industrial disturbances by acceding to the demands of the opposing party or parties when such course is in the judgment of the Company unfavorable to the Company.
Majeure shall include any delay due to building permits for the Improvement Work being issued more than eight (8) business days after an application for such building permits is submitted to the issuing agency. Landlord grants Tenant permission to access the Leased Premises commencing on June 20, 2001 for the purpose of preparing the Leased Premises for Tenant's occupancy, provided that Tenant has provided Landlord with satisfactory proof of insurance in accordance with the requirements Article 9, and provided further that Tenant shall not interfere with any ongoing performance of the Improvement Work. During such early access period, until Landlord actually delivers possession of the Leased Premises to Tenant in the agreed condition, Tenant shall not be obligated to pay any Base Monthly Rent or Additional Rent (as hereinafter defined), but Tenant shall be obligated to comply with all other terms and conditions of this Lease.
Majeure means any act, event, cause or condition that (i) prevents a Party from performing its obligations, and (ii) is beyond the affected Party's reasonable control, except that no act, event, cause or condition shall be considered to be an event of Force Majeure:
(1) if and to the extent the Party seeking to invoke Force Majeure has caused or contributed to the applicable act, event, cause or condition by its act, fault or negligence or has failed to use Commercially Reasonable Efforts to prevent or remedy such act, event, cause, or condition and, so far as possible and within a reasonable time period, remove it (except in the case of strikes, lockouts and other labor disturbances, the settlement of which shall be wholly within the discretion of the party involved);
(2) if the act, event, cause or condition involves a failure or delay on the party of the Interconnecting Utility or its agents to complete network or system upgrades or otherwise perform responsibilities under an Interconnection Agreement, and such failure or delay is attributable to a change in specifications of the interconnection point or the Project by the Producer;
(3) if the act, event, cause or condition is the result of a violation of law or the terms of any regulatory approval by the Party seeking to invoke Force Majeure; or
(4) if the act, event, cause or condition was caused by a lack of funds or other financial cause.