Notice of Commencement A Notice of Commencement shall be filed by the Contractor with the Clerk of the Superior Court in the county in which the Project is located, pursuant to O.C.G.A. §13-10-62.
Date of Commencement This Agreement has commenced and shall be deemed to have commenced on and with effect from the date mentioned at the beginning of this Agreement.
TIME OF COMMENCEMENT AND COMPLETION 2.1 The Contractor shall commence the Work upon the date established in the Notice to Proceed. 2.2 The Contractor shall achieve Final Completion, as defined in Section 105.01, Contract Time, Notice of Contract Execution and Notice to Proceed of the Loudoun County Revisions to the 0000 XXXX Xxxx & Bridge Specifications, Division I - General Provisions, within one hundred and eighty (180) calendar days from the date specified in the Notice to Proceed. This time period shall be designated the Contract Time. The Notice to proceed will be issued approximately than thirty (30) days after the execution of this agreement. The Contractor agrees that the time for completion of the Work as described in the Contract Documents shall govern unless specifically amended in writing by the County, and that no claims for early completion are allowed to be presented by the Contractor to the County. 2.3 The County specifies that time is of the essence under this Contract. Time being of the essence, it is essential to the County that Contract work will be completed within the Contract Time. The County and the Contractor agree that damages for failure to complete the work within the Contract Time are not susceptible to exact determination but that $600 per day is in proportion to the actual loss that the County would suffer from such delay. Therefore, the Contractor will pay the County on demand $600 per day for each and every day beyond the one hundred and eighty (180) calendar days, or modified date of completion, that the County determines that work is not complete, as damages caused by such delay and not as a penalty. The County shall be entitled to offset liquidated damages against any sum owed by the County to the Contractor under this Contract. 2.4 The amount of liquidated damages set forth in Articles 2.3 above shall be assessed cumulatively. This provision for liquidated damages does not bar County's right to enforce other rights and remedies against Contractor, which are otherwise legally enforceable, including but not limited to, specific performance or injunctive relief. 2.5 The Contractor hereby waives any defense as to the validity of any liquidated damages stated in this Agreement as they may appear on grounds that such liquidated damages are void as penalties or are not reasonably related to actual damages.
DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be: § 3.2 The Contract Time shall be measured from the date of commencement of the Work.
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
Final Space Plan Tenant shall supply Landlord with four (4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord.
Construction Commencement The Connecting Transmission Owner shall commence construction of the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades for which it is responsible as soon as practicable after the following additional conditions are satisfied: 5.6.1 Approval of the appropriate Governmental Authority has been obtained for any facilities requiring regulatory approval; 5.6.2 Necessary real property rights and rights-of-way have been obtained, to the extent required for the construction of a discrete aspect of the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades; 5.6.3 The Connecting Transmission Owner has received written authorization to proceed with construction from the Developer by the date specified in Appendix B hereto; and 5.6.4 The Developer has provided security to the Connecting Transmission Owner in accordance with Article 11.5 by the dates specified in Appendix B hereto.
Commencement and Completion of Work The professional services to be performed pursuant to this Agreement shall commence within five (5) days from the Effective Date of this Agreement. Failure to commence work in a timely manner and/or diligently pursue work to completion may be grounds for termination of this Agreement.
Service Commencement Date The date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Section 15.3 or Section 29.1 under the Tariff.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
