Stadium Authority Undertakings
Stadium Authority Undertakings Sample Clauses
Related to Stadium Authority Undertakings
Outage Authority and Coordination Developer and Connecting Transmission Owner may each, in accordance with NYISO procedures and Good Utility Practice and in coordination with the other Party, remove from service any of its respective Attachment Facilities or System Upgrade Facilities and System Deliverability Upgrades that may impact the other Party’s facilities as necessary to perform maintenance or testing or to install or replace equipment. Absent an Emergency State, the Party scheduling a removal of such facility(ies) from service will use Reasonable Efforts to schedule such removal on a date and time mutually acceptable to both the Developer and the Connecting Transmission Owner. In all circumstances either Party planning to remove such facility(ies) from service shall use Reasonable Efforts to minimize the effect on the other Party of such removal.
E1 Authority Data E1.1 The Contractor shall not delete or remove any proprietary notices contained within or relating to the Authority Data.
Developer Authority Consistent with Good Utility Practice and this Agreement, the Developer may take whatever actions or inactions with regard to the Large Generating Facility or the Developer Attachment Facilities during an Emergency State in order to (i) preserve public health and safety, (ii) preserve the reliability of the Large Generating Facility or the Developer Attachment Facilities, (iii) limit or prevent damage, and (iv) expedite restoration of service. Developer shall use Reasonable Efforts to minimize the effect of such actions or inactions on the New York State Transmission System and the Connecting Transmission Owner’s Attachment Facilities. NYISO and Connecting Transmission Owner shall use Reasonable Efforts to assist Developer in such actions.
Authority of Contractor The Contractor shall have no right or authority, express or implied, to commit or otherwise obligate the Company in any manner whatsoever except to the extent specifically provided herein or specifically authorized in writing by the Company.
Capacity; Authority; Validity Allseas has all necessary capacity, power and authority to enter into this Agreement and to perform all the obligations to be performed by Allseas’ hereunder; this Agreement and the consummation by Allseas of the transactions contemplated hereby has been duly and validly authorized by all necessary action of Allseas; this Agreement has been duly executed and delivered by Allseas; and assuming the due execution and delivery of this Agreement by the Company, this Agreement constitutes the legal, valid and binding obligation of the Company enforceable against Allseas in accordance with its terms.
Governing Law, Regulatory Authority, and Rules The validity, interpretation and enforcement of this Agreement and each of its provisions shall be governed by the laws of the state of New York, without regard to its conflicts of law principles. This Agreement is subject to all Applicable Laws and Regulations. Each Party expressly reserves the right to seek changes in, appeal, or otherwise contest any laws, orders, or regulations of a Governmental Authority.
Authority; No Conflicts (i) Oryx has all requisite corporate power and authority to enter into this Agreement and the Stock Option Agreements and to consummate the transactions contemplated hereby and thereby, subject, in the case of the consummation of the Reverse Split and the Merger, to the approval of the Reverse Split and the adoption of this Agreement by the stockholders of Oryx by the Required Oryx Vote (as defined in Section 3.2(g)). The execution and delivery of this Agreement and the Stock Option Agreements and the consummation of the transactions contemplated hereby and thereby have been duly authorized by all necessary corporate action on the part of Oryx, subject, in the case of the consummation of the Reverse Split and the Merger, to the approval of the Reverse Split and the adoption of this Agreement by the stockholders of Oryx by the Required Oryx Vote. Each of this Agreement and the Stock Option Agreements has been duly executed and delivered by Oryx and constitutes a valid and binding agreement of Oryx, enforceable against it in accordance with its terms, except as such enforceability may be limited by bankruptcy, insolvency, reorganization, moratorium and similar laws relating to or affecting creditors generally or by general equity principles (regardless of whether such enforceability is considered in a proceeding in equity or at law). (ii) The execution and delivery of this Agreement and the Stock Option Agreements by Oryx does not or will not, as the case may be, and the consummation by Oryx of the Merger and the other transactions contemplated hereby and thereby will not, result in a Violation of or pursuant to: (A) any provision of the certificate of incorporation or by-laws of Oryx, or any similar organizational documents of any material Subsidiary of Oryx, or (B) except as would not reasonably be expected to have a Material Adverse Effect on Oryx, subject to obtaining or making the consents, approvals, orders, authorizations, registrations, declarations and filings referred to in paragraph (iii) below, any loan or credit agreement, note, mortgage, bond, indenture, lease, benefit plan or other agreement, obligation, instrument, permit, concession, franchise, license, judgment, order, decree, statute, law, ordinance, rule or regulation applicable to Oryx or any Subsidiary of Oryx or their respective properties or assets. (iii) No consent, approval, order or authorization of, or registration, declaration or filing with, any Governmental Entity is required by or with respect to Oryx or any Subsidiary of Oryx in connection with the execution and delivery of this Agreement or the Stock Option Agreements by Oryx or the consummation by Oryx of the Merger and the other transactions contemplated hereby and thereby, except the Necessary Consents and such consents, approvals, orders, authorizations, registrations, declarations and filings the failure of which to make or obtain would not reasonably be expected to have a Material Adverse Effect on Oryx.
Corporate Authority; No Conflicts The execution, delivery and performance by such Credit Party of this Amendment and all documents, instruments and agreements contemplated herein are within such Credit Party’s corporate or other organizational powers, have been duly authorized by all necessary action, require no action by or in respect of, or filing with, any court or agency of government and do not violate or constitute a default under any provision of any applicable law or other agreements binding upon such Credit Party or result in the creation or imposition of any Lien upon any of the assets of such Credit Party except for Liens permitted under Section 7.02 of the Credit Agreement.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Authority, Etc The execution and delivery by Borrower of this Amendment and the performance by Borrower of all of its agreements and obligations under the Loan Agreement and the other Loan Documents, as amended hereby, are within the corporate authority of Borrower and have been duly authorized by all necessary corporate action on the part of Borrower. With respect to Borrower, the execution and delivery by Borrower of this Amendment does not and will not require any registration with, consent or approval of, or notice to any Person (including any governmental authority).
