Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.
Transfer of Servicing Between Master Servicer and Special Servicer; Record Keeping (a) Upon determining that any Serviced Loan has become a Specially Serviced Loan, the Master Servicer shall promptly give written notice thereof to the Special Servicer, any related Serviced Companion Loan Holder (in the case of a Serviced Loan Combination), the Operating Advisor, the Certificate Administrator, the Trustee, the related Directing Holder (prior to the occurrence and continuance of a Consultation Termination Event with respect to the related Mortgage Loan) and, for posting to the Rule 17g-5 Information Provider’s Website pursuant to Section 12.13 of this Agreement, the Rule 17g-5 Information Provider and shall promptly deliver a copy of the Servicing File to the Special Servicer and concurrently provide a copy of such Servicing File to the Operating Advisor and shall use its reasonable efforts to provide the Special Servicer with all information, documents (but excluding the original documents constituting the Mortgage File, but including copies thereof) and records (including records stored electronically on computer tapes, magnetic discs and the like) relating to such Serviced Loan and reasonably requested by the Special Servicer to enable it to assume its duties hereunder with respect thereto without acting through a Sub-Servicer. The Master Servicer shall use its reasonable efforts to comply with the preceding sentence within five (5) Business Days of the date such Serviced Loan became a Specially Serviced Loan and in any event shall continue to act as Master Servicer and administrator of such Serviced Loan until the Special Servicer has commenced the servicing of such Serviced Loan, which shall occur upon the receipt by the Special Servicer of the Servicing File. With respect to each such Serviced Loan that becomes a Specially Serviced Loan, the Master Servicer shall instruct the related Mortgagor to continue to remit all payments in respect of such Serviced Loan to the Master Servicer. The Master Servicer shall forward any notices it would otherwise send to the Mortgagor of such a Specially Serviced Loan to the Special Servicer who shall send such notice to the related Mortgagor. Upon determining that a Specially Serviced Loan has become a Corrected Loan, the Special Servicer shall promptly give written notice thereof to the Master Servicer, the Trustee, the Operating Advisor, the Certificate Administrator, any related Serviced Companion Loan Holder, the related Directing Holder (prior to the occurrence and continuance of a Consultation Termination Event with respect to the related Mortgage Loan) and, for posting to the Rule 17g-5 Information Provider’s Website pursuant to Section 12.13 of this Agreement, the Rule 17g-5 Information Provider and, upon giving such notice and the return of the Servicing File to the Master Servicer, such Serviced Loan shall cease to be a Specially Serviced Loan in accordance with the first proviso of the definition of Specially Serviced Loans, the Special Servicer’s obligation to service such Serviced Loan shall terminate and the obligations of the Master Servicer to service and administer such Serviced Loan as a Serviced Loan that is not a Specially Serviced Loan shall resume. In addition, if the related Mortgagor has been instructed, pursuant to the preceding paragraph, to make payments to the Special Servicer, upon such determination, the Special Servicer shall instruct the related Mortgagor to remit all payments in respect of such Specially Serviced Loan directly to the Master Servicer. (b) In servicing any Specially Serviced Loan, the Special Servicer shall provide to the Custodian originals of documents included within the definition of “Mortgage File” for inclusion in the related Mortgage File (to the extent such documents are in the possession of the Special Servicer) and copies of any additional related Serviced Loan information, including correspondence with the related Mortgagor, and the Special Servicer shall promptly provide copies of all of the foregoing to the Master Servicer as well as copies of any analysis or internal review prepared by or for the benefit of the Special Servicer. (c) Notwithstanding the provisions of subsections (a) and (b) of this Section 3.22, the Master Servicer shall maintain ongoing payment records with respect to each of the Specially Serviced Loans and, upon request, shall provide the Special Servicer and the Operating Advisor with any information reasonably required by the Special Servicer or the Operating Advisor to perform its duties under this Agreement to the extent such information is within the Master Servicer’s possession. Upon request, the Special Servicer shall provide the Master Servicer and the Operating Advisor with any information reasonably required by the Master Servicer or the Operating Advisor to perform its duties under this Agreement to the extent such information is within the Special Servicer’s possession.
Adjustments for Combinations, Etc If the outstanding Shares are combined or consolidated, by reclassification or otherwise, into a lesser number of shares, the Warrant Price shall be proportionately increased.
Equitable Adjustment Trading volume amounts, price/volume amounts and similar figures in the Transaction Documents shall be equitably adjusted (but without duplication) to offset the effect of stock splits, similar events and as otherwise described in this Agreement and Warrants.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Instructions for Certification – First Tier Participants a. By signing and submitting this proposal, the prospective first tier participant is providing the certification set out below. b. The inability of a person to provide the certification set out below will not necessarily result in denial of participation in this covered transaction. The prospective first tier participant shall submit an explanation of why it cannot provide the certification set out below. The certification or explanation will be considered in connection with the department or agency's determination whether to enter into this transaction. However, failure of the prospective first tier participant to furnish a certification or an explanation shall disqualify such a person from participation in this transaction. c. The certification in this clause is a material representation of fact upon which reliance was placed when the contracting agency determined to enter into this transaction. If it is later determined that the prospective participant knowingly rendered an erroneous certification, in addition to other remedies available to the Federal Government, the contracting agency may terminate this transaction for cause of default. d. The prospective first tier participant shall provide immediate written notice to the contracting agency to whom this proposal is submitted if any time the prospective first tier participant learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances. e. The terms "covered transaction," "debarred," "suspended," "ineligible," "participant," "person," "principal," and "voluntarily excluded," as used in this clause, are defined in 2 CFR Parts 180 and 1200. “First Tier Covered Transactions” refers to any covered transaction between a grantee or subgrantee of Federal funds and a participant (such as the prime or general contract). “Lower Tier Covered Transactions” refers to any covered transaction under a First Tier Covered Transaction (such as subcontracts). “First Tier Participant” refers to the participant who has entered into a covered transaction with a grantee or subgrantee of Federal funds (such as the prime or general contractor). “Lower Tier Participant” refers any participant who has entered into a covered transaction with a First Tier Participant or other Lower Tier Participants (such as subcontractors and suppliers).
Cost Recovery for RSTEP Requests by Registry Operator for the approval of Additional Services pursuant to Section 2.1 may be referred by ICANN to the Registry Services Technical Evaluation Panel (“RSTEP”) pursuant to that process at xxxx://xxx.xxxxx.xxx/en/registries/rsep/. In the event that such requests are referred to RSTEP, Registry Operator shall remit to ICANN the invoiced cost of the RSTEP review within fourteen (14) calendar days of receipt of a copy of the RSTEP invoice from ICANN, unless ICANN determines, in its sole and absolute discretion, to pay all or any portion of the invoiced cost of such RSTEP review.
Performance Adjustment One-twelfth of the annual Performance Adjustment Rate will be applied to the average of the net assets of the Portfolio (computed in the manner set forth in the Fund's Declaration of Trust or other organizational document) determined as of the close of business on each business day throughout the month and the performance period.
Adjustments for Stock Splits and Combinations If the Maker shall at any time or from time to time after the Closing Date (but whether before or after the Issuance Date) effect a split of the outstanding Common Stock, the applicable Conversion Price in effect immediately prior to the stock split shall be proportionately decreased. If the Maker shall at any time or from time to time after the Closing Date (but whether before or after the Issuance Date), combine the outstanding shares of Common Stock, the applicable Conversion Price in effect immediately prior to the combination shall be proportionately increased. Any adjustments under this Section 3.4(a)(i) shall be effective at the close of business on the date the stock split or combination occurs.
Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-- (i) In the contract price or delivery schedule or both; and (ii) In such other provisions of the contract as may be affected. (2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.