Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Equipment List 1. All items of equipment to be purchased with funds under this Contract must be itemized in Grantee’s equipment list as finally approved by the System Agency in the executed Contract. The equipment list must include: i. Description of the property; ii. Serial number or other identification number; iii. Source of funding for the property (including the Federal Assistance Identification Number); iv. Who holds title, v. Acquisition date and cost of the property;
Holiday Schedule The Parents agree to divide holiday visitation as follows: (check all that apply) New Year’s: ☐ Mother ☐ Father
Recovery Schedule If the initial schedule or any current updates fail to reflect the Work’s actual plan or method of operation, or a contractual milestone date is more than fifteen (15) days behind, Owner may require that a recovery schedule for completion of the remaining Work be submitted. The Recovery Schedule must be submitted within seven (7) calendar days of Owner’s request. The Recovery Schedule shall describe in detail Construction Contractor’s plan to complete the remaining Work by the required Contract milestone date. The Recovery Schedule submitted shall meet the same requirements as the original Construction Schedule. The narrative submitted with the Recovery Schedule should describe in detail all changes that have been made to meet the Contract milestone dates.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Interest Rates and Letter of Credit Fee Rates Payments and Calculations (a) Interest Rates. Except as provided in Section 2.13(c) and Section 2.15(a), all Obligations (except for the undrawn portion of the face amount of Letters of Credit) that have been charged to the Loan Account pursuant to the terms hereof shall bear interest at a per annum rate equal to the lesser of (i) the LIBOR Rate plus the Applicable Margin, or (ii) the maximum rate of interest allowed by applicable laws; provided, that following notice to Borrower in accordance with Section 2.15(a) hereof, all Obligations that have been charged to the Loan Account pursuant to the terms hereof shall bear interest at a per annum rate equal, during the duration of the circumstances described in Section 2.15(a), to the lesser of (A) the Base Rate plus the Applicable Margin as calculated pursuant to Section 2.15(a) or (B) the maximum rate of interest allowable by applicable laws.
Wage Schedule The pay rate (including increments and stated extras) as agreed to and hereinafter in this Schedule provided, shall be in effect during the term of the Agreement, from April 1, 2019 to March 31, 2022.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Calculations Respecting Mortgage Loans Calculations required to be made pursuant to this Agreement with respect to any Mortgage Loan in the Trust Fund shall be made based upon current information as to the terms of the Mortgage Loans and reports of payments received from the Mortgagor on such Mortgage Loans and payments to be made to the Securities Administrator as supplied to the Securities Administrator by the Master Servicer. The Securities Administrator shall not be required to recompute, verify or recalculate the information supplied to it by the Master Servicer or any Servicer.
