Abandonment of Premises If the property becomes vacant during the term of this lease, and if at the time of the vacancy Tenant are in default in the payment of any installment of rent, then the rent for the entire term shall become at once due and payable and Landlord may proceed to collect rent for said entire premises, with or without process of law, to take possession thereof, to remove any and all property there from and store as required by law, to lease the premises as agent of Tenant, and to apply the proceeds received from such letting toward the payment of Tenant' rent under this lease; such re-entry and re-letting shall not discharge Tenant from liability for rent, nor from any other obligation under the terms of this lease.
POSSESSION OF PREMISES Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.
Demise of Premises Landlord hereby demises and lets to Tenant and Tenant hereby takes and leases from Landlord, for the term and upon the provisions hereinafter specified, the Leased Premises.
Expansion of Premises (a) Effective as of the Expansion Date the Premises (and the definition of the “Premises”) shall be modified to mean and include both the Initial Premises and the Expansion Premises. As a result of such expansion, effective upon the Expansion Date, the deemed square footage of the Premises shall be and become 31,684 square feet and Tenant’s Prorata Share and Tenant’s Share of Expenses and Real Estate Taxes shall be one hundred percent (100.00%). (b) If Landlord, for any reason whatsoever, cannot deliver possession of the Expansion Premises to Tenant on before August 1, 2012 for the purpose specified in Section 3(c), this Amendment shall not be void or voidable, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and Tenant shall have no obligation to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises until the day following the date on which possession of the Expansion Premises is delivered to Tenant (such date thereupon becoming the “Expansion Date” for purposes of this Amendment). Notwithstanding the foregoing, if Landlord is unable to deliver the Expansion Premises by August 1, 2012 (as extended day-for-day for each day of Force Majeure Delay) (the “Expansion Premises Outside Delivery Date”), then Tenant shall have the right, as its sole remedy, to terminate this Amendment to Lease by providing written notice to Landlord within fifteen (15) business days following the Expansion Premises Outside Delivery Date, in which event the Lease shall continue in full force and effect as if the parties had not entered into this Amendment and Landlord shall promptly return to Tenant the August, 2012 Base Rent for the Expansion Premises paid by Tenant pursuant to the provisions of Section 6(d). For purposes hereof, the failure of the existing tenant of the Expansion Premises to vacate the Expansion Premises shall not be an event of Force Majeure Delay. (c) Notwithstanding the above, Tenant shall be entitled to early occupancy of the Expansion Premises at any time after the Expansion Premises Delivery Date for the sole purposes of (1) installing Tenant’s furniture and telephone and other communications cabling and (2) performing Tenant’s Expansion Work (defined below), provided that (i) Tenant covenants and agrees that Tenant and Tenant’s employees, agents or contractors will cooperate with Landlord to coordinate the performance and completion of the Landlord’s Expansion Work concurrently with Tenant’s Expansion Work, (ii) Landlord shall have no liability to Tenant for delays in completing the Landlord’s Expansion Work which result from, are caused by or arise out of the interference by Tenant or Tenant’s employees, agents or contractors in the performance of the Landlord’s Expansion Work, (iii) Tenant and Tenant’s employees, agents and contractors shall promptly comply with any and all requests made by Landlord or Landlord’s contractor(s) that Tenant remove its property from those areas in or around which Landlord is performing the Landlord’s Expansion Work, and (iv) Landlord shall not be liable for, Tenant hereby waives all claims which Tenant may have against the Landlord Parties, and Tenant shall indemnify and hold harmless Landlord from and defend Landlord against any and all claims or liability for any injury or damage to any person or property in or about the Expansion Premises resulting from or arising out of or in connection with the performance of Tenant’s Expansion Work (except to the extent arising from the negligence or willful misconduct of Landlord). Tenant’s early occupancy of the Expansion Premises for the sole purpose provided in this Section shall be subject to all of the terms and conditions of the Lease, provided that (x) the Premises shall not include the Expansion Premises until the Expansion Date, and (y) Tenant shall not be obligated to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises for the period from the Expansion Premises Delivery Date until the Expansion Date. (d) Within five (5) business days after the Expansion Date, the parties shall execute a letter confirming the Expansion Date and certifying that Tenant has accepted delivery of the Premises, in form substantially similar to EXHIBIT “D” attached to the Lease (the “Expansion Date Memorandum”). Either party’s failure to request execution of, or to execute, the Expansion Date Memorandum shall not in any way alter the Expansion Date.
Condition of Premises Landlord shall deliver the Premises and Landlord’s Work shall be good and workmanlike using first class materials. Landlord’s Work is hereby warranted for one year from the Rent Commencement Date and no costs to effect the same shall be included in Operating Expenses. All Building systems including, but not limited to, HVAC, mechanical and electrical, elevators and the structure of the Building shall be in good working order and/or good repair, as the case may be, at the time Tenant occupies the Premises. The Premises shall be initially improved as provided in, and subject to, the Tenant Work Letter attached hereto as Exhibit “B” and made a part hereof. The existing leasehold improvements in the Premises as of the date of this Lease, together with the Tenant Improvements (as defined in the Tenant Work Letter) may be collectively referred to herein as the “Tenant Improvements.” Landlord reserves the right from time to time, but subject to payment by and/or reimbursement from Tenant as otherwise provided herein: (i) to install, use, maintain, repair, replace and relocate for service to the Premises and/or other parts of the Building pipes, ducts, conduits, wires, appurtenant fixtures, and mechanical systems, wherever located in the Premises or the Building, (ii) to alter, close or relocate any facility in the Premises or the Common Areas or otherwise conduct any of the above activities for the purpose of complying with legal requirements for fire/life safety for the Building or otherwise and (iii) to comply with any federal, state or local law, rule or order with respect thereto or the regulation thereof not currently in effect. Landlord shall use reasonable efforts to perform any such work with the least inconvenience to Tenant as possible, but in no event shall Tenant be permitted to withhold or reduce Rent or other charges due hereunder as a result of same or otherwise make claim against Landlord for interruption or interference with Tenant’s business and/or operations. No incursion into or through the Premises shall be made without Tenant’s consent except in the case of an emergency. Notwithstanding the foregoing, in the event Landlord requires entry into the Premises for the purpose of performing any of its obligations contained in this Lease and such entry is denied, Landlord shall not be deemed in default hereunder for failing to perform such obligations.
SURRENDER OF PREMISES; REMOVAL OF PROPERTY Upon the Expiration Date or upon any earlier termination of this Lease, Tenant shall quit and surrender possession of the Premises to Landlord in as good order, condition and repair as when received or as hereafter may be improved by Landlord or Tenant, reasonable wear and tear and repairs which are Landlord's obligation excepted, and shall, without expense to Landlord, remove or cause to be removed from the Premises all personal property and debris, except for any items that Landlord may by written authorization allow to remain. Tenant shall repair all damage to the Premises resulting from the removal, which repair shall include the patching and filling of holes and repair of structural damage, provided that Landlord may instead elect to repair any structural damage at Tenant's expense. If Tenant shall fail to comply with the provisions of this Section, Landlord may effect the removal and/or make any repairs, and the cost to Landlord shall be additional rent payable by Tenant upon demand. If Tenant fails to remove Tenant's personal property from the Premises upon the expiration of the Term, Landlord may remove, store, dispose of and/or retain such personal property, at Landlord's option, in accordance with then applicable laws, all at the expense of Tenant. If requested by Landlord, Tenant shall execute, acknowledge and deliver to Landlord an instrument in writing releasing and quitclaiming to Landlord all right, title and interest of Tenant in the Premises.
Sale of Premises by Landlord In the event of any sale of the Building, Landlord shall be and is hereby entirely freed and relieved of all liability under any and all of its covenants and obligations contained in or derived from this Lease arising out of any act, occurrence or omission occurring after the consummation of such sale; and the purchaser, at such sale or any subsequent sale of the Premises shall be deemed, without any further agreement between the parties or their successors in interest or between the parties and any such purchaser, to have assumed and agreed to carry out any and all of the covenants and obligations of the Landlord under this Lease.
Restoration of Premises Upon termination of this lease, CSU shall have the option to require Auxiliary, at its own expense and risk, to restore the demised premises as nearly as possible to the condition existing prior to the execution of the lease, with the exception of normal wear and tear. But, if Auxiliary shall fail to do so within 90 days after CSU’s option, CSU may restore the property at the risk of the Auxiliary and all costs and expenses of such removal or restoration shall be paid by Auxiliary upon demand of State. CSU shall have the right to exercise this option within 30 days after the expiration of this lease, but not thereafter.
Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
Surrender of Premises No act or thing done by Landlord or any agent or employee of Landlord during the Lease Term shall be deemed to constitute an acceptance by Landlord of a surrender of the Premises unless such intent is specifically acknowledged in writing by Landlord. The delivery of keys to the Premises to Landlord or any agent or employee of Landlord shall not constitute a surrender of the Premises or effect a termination of this Lease, whether or not the keys are thereafter retained by Landlord, and notwithstanding such delivery Tenant shall be entitled to the return of such keys at any reasonable time upon request until this Lease shall have been properly terminated. The voluntary or other surrender of this Lease by Tenant, whether accepted by Landlord or not, or a mutual termination hereof, shall not work a merger, and at the option of Landlord shall operate as an assignment to Landlord of all subleases or subtenancies affecting the Premises or terminate any or all such sublessees or subtenancies.
