Performance Bank Guarantee 4.2.1 The Performance Bank Guarantee furnished by Power Producer to GUVNL shall be for guaranteeing the commissioining / commercial operation of the project up to the Contracted Capacity within SCOD.
4.2.2 If the Power Producer fails to commission the project on or before Scheduled Commercial Operation Date, GUVNL shall have the right to encash the Performance Bank Guarantee without prejudice to the other rights of the Power Producer under this Agreement as per Article 3.3.
4.2.3 GUVNL shall release the Performance Bank Guarantee upon successful commissioning of full contracted capacity after adjusting Liquidated Damages (if any) as per Article 3.3.
Suspension of Performance Disbursement Into Court If at any time, there shall exist any dispute between the Company and the Investor(s) with respect to holding or disposition of any portion of the Escrow Funds or any other obligations of Escrow Agent hereunder, or if at any time Escrow Agent is unable to determine, to Escrow Agent's sole satisfaction, the proper disposition of any portion of the Escrow Funds or Escrow Agent's proper actions with respect to its obligations hereunder, or if the parties have not within thirty (30) days of the furnishing by Escrow Agent of a notice of resignation pursuant to Section 9 hereof, appointed a successor Escrow Agent to act hereunder, then Escrow Agent may, in its sole discretion, take either or both of the following actions:
a. suspend the performance of any of its obligations (including without limitation any disbursement obligations) under this Escrow Agreement until such dispute or uncertainty shall be resolved to the sole satisfaction of Escrow Agent or until a successor Escrow Agent shall be appointed (as the case may be); provided however, Escrow Agent shall continue to invest the Escrow Funds in accordance with Section 8 hereof; and/or
b. petition (by means of an interpleader action or any other appropriate method) any court of competent jurisdiction in any venue convenient to Escrow Agent, for instructions with respect to such dispute or uncertainty, and to the extent required by law, pay into such court, for holding and disposition in accordance with the instructions of such court, all funds held by it in the Escrow Funds, after deduction and payment to Escrow Agent of all fees and expenses (including court costs and attorneys' fees) payable to, incurred by, or expected to be incurred by Escrow Agent in connection with performance of its duties and the exercise of its rights hereunder.
c. Escrow Agent shall have no liability to the Company, the Investor(s), or any person with respect to any such suspension of performance or disbursement into court, specifically including any liability or claimed liability that may arise, or be alleged to have arisen, out of or as a result of any delay in the disbursement of funds held in the Escrow Funds or any delay in with respect to any other action required or requested of Escrow Agent.
Release of Performance Security (i) The Authority shall return the Performance Security to the Contractor within 60 (sixty) days of the expiry of the Maintenance Period or the Defects Liability Period, whichever is later, under this Agreement. Notwithstanding the aforesaid, the Parties agree that the Authority shall not be obliged to release the Performance Security until all Defects identified during the Defects Liability Period have been rectified.
(ii) The Authority shall return the Additional Performance Security to the Contractor within 28 (twenty eight) days from the date of issue of Completion Certificate under Article 12 of this Agreement.
(iii) The Authority shall be liable to pay interest @ 9% (nine per cent) per annum for any delay in the return of Performance Security and Additional Performance Security, if any, beyond the period prescribed above for the period of delay.
Guaranty of Performance Each Guarantor also guarantees the full, prompt and unconditional performance of all obligations and agreements of every kind owed or hereafter to be owed by the Companies and the Guarantors to Purchasers and Agent under the Purchase Agreement, the Notes, and the other Transaction Documents. Every provision for the benefit of Purchasers and Agent contained in this Guaranty shall apply to the guaranty of performance given in this paragraph.
Suspension of Performance or Disbursement Into Court If, at any time, (i) there shall exist any dispute between Broker, Issuer, NCPS, any Subscriber or any other person with respect to the holding or disposition of all or any portion of the Escrow Funds or any other obligations of NCPS hereunder, or (ii) if at any time NCPS is unable to determine, to NCPS’s reasonable satisfaction, the proper disposition of all or any portion of the Escrow Funds or NCPS’s proper actions with respect to its obligations hereunder, or (iii) if Broker and Issuer have not within 30 days of the furnishing by NCPS of a notice of resignation pursuant to Section 7 hereof appointed a successor NCPS to act hereunder, then NCPS may, in its reasonable discretion, take either or both of the following actions:
a. suspend the performance of any of its obligations (including without limitation any disbursement obligations) under this Escrow Agreement until such dispute or uncertainty shall be resolved to the sole satisfaction of NCPS or until a successor NCPS shall have been appointed (as the case may be).
b. petition (by means of an interpleader action or any other appropriate method) any court of competent jurisdiction in any venue convenient to NCPS, for instructions with respect to such dispute or uncertainty, and to the extent required or permitted by law, pay into such court all funds held by it in the Escrow Funds for holding and disposition in accordance with the instructions of such court. NCPS shall have no liability to Broker, Issuer, any Subscriber or any other person with respect to any such suspension of performance or disbursement into court, specifically including any liability or claimed liability that may arise, or be alleged to have arisen, out of or as a result of any delay in the disbursement of the Escrow Funds or any delay in or with respect to any other action required or requested of NCPS.
Appropriation of Performance Security (i) Upon occurrence of a Contractor’s Default, the Authority shall, without prejudice to its other rights and remedies hereunder or in law, be entitled to encash and appropriate the relevant amounts from the Performance Security as Damages for such Contractor’s Default.
(ii) Upon such encashment and appropriation from the Performance Security, the Contractor shall, within 30 (thirty) days thereof, replenish, in case of partial appropriation, to its original level the Performance Security, and in case of appropriation of the entire Performance Security provide a fresh Performance Security, as the case may be, and the Contractor shall, within the time so granted, replenish or furnish fresh Performance Security as aforesaid failing which the Authority shall be entitled to terminate the Agreement in accordance with Article 23. Upon replenishment or furnishing of a fresh Performance Security, as the case may be, as aforesaid, the Contractor shall be entitled to an additional Cure Period of 30 (thirty) days for remedying the Contractor’s Default, and in the event of the Contractor not curing its default within such Cure Period, the Authority shall be entitled to encash and appropriate such Performance Security as Damages, and to terminate this Agreement in accordance with Article 23.
Review of Performance The Board of Directors shall periodically review and evaluate the performance of Employee under this Employment Agreement with Employee.
Suspension of Performance Notwithstanding any other provision hereof, if an Event of Default or a Potential Event of Default has occurred and is continuing, the Non-Defaulting Party, upon written notice to the Defaulting Party, has the right (i) to suspend performance under any or all Transactions and (ii) to the extent an Event of Default has occurred and is continuing, to exercise any remedy available at law or in equity, except as limited be Section 5.7.
Continuity of Performance In the event of a dispute between the Party and the State, each party will continue to perform its obligations under this Agreement during the resolution of the dispute until this Agreement is terminated in accordance with its terms.
Standard and Manner of Performance Contractor shall perform its obligations under this Agreement in accordance with the highest standards of care, skill and diligence in Contractor’s industry, trade, or profession. Not Exclusive. Contractor is not guaranteed any work except as expressly stated herein, and this Agreement does not create an exclusive contract for the Work.
