Sufficient Space. Landlord reasonably determines that there is sufficient space in the Property for the placement of all of the Provider’s equipment and materials (the “Equipment Space”);
Sufficient Space Sample Clauses
Related to Sufficient Space
Storage Space A. During the initial Term and any renewal thereof, Landlord agrees to lease to Tenant and Tenant accepts the space containing approximately (a) 800 square feet on the ground floor of the Building, (b) 400 square feet on the ground floor of the Building, and 65 square feet on the ground floor of the Building, as shown on EXHIBIT A-5 attached hereto (collectively, the "Storage Space"). However, notwithstanding the foregoing, the portion of the Storage Space described above containing approximately 400 rentable square feet shall not be leased to Tenant until such space becomes available, which is scheduled to occur on or about February 1, 2000. Further, the portion of the Storage Space containing 65 square feet described above is available for lease to Tenant only if Tenant pays Landlord the reasonable cost to install a demising wall and door to separately demise such space. In addition to the Storage Space described above, Tenant shall have an option to lease an additional approximately 800 square feet of storage space, located on the ground floor of the Building as shown on EXHIBIT A-6 attached hereto (the "Option Storage Space") when such Option Storage Space becomes available. Tenant shall exercise the foregoing option as follows: When Landlord informs Tenant that the Option Storage Space is available for lease by Tenant (but prior to leasing the Option Storage Space to any party other than the current occupant of such space or its successors or assigns), Tenant may elect to lease such space, upon the terms and conditions contained in this Section VII (in which event, the Option Storage Space shall be included within the definition of Storage Space hereunder), by providing written notice to Landlord within 7 days after Tenant's receipt of the notice from Landlord. Failure to provide such written notice to Landlord within the 7 day period shall be deemed a waiver of Tenant's option rights with respect to the Option Storage Space. The Storage Space shall be used by Tenant for the storage of equipment, inventory or other non-perishable items normally used in Tenant's business, and for no other purpose whatsoever. Tenant agrees to keep the Storage Space in a neat and orderly fashion and to keep all stored items in cartons, file cabinets or other suitable containers. All items stored in the Storage Space shall be elevated at least 6 inches above the floor on wooden pallets, and shall be at least 18 inches below the bottom of all sprinklers located in the ceiling of the Storage Space, if any. Tenant shall not store anything in the Storage Space which is unsafe or which otherwise may create a hazardous condition, or which may increase Landlord's insurance rates, or cause a cancellation or modification of Landlord's insurance coverage. Without limitation, Tenant shall not store any flammable, combustible or explosive fluid, chemical or substance nor any perishable food or beverage products, except with Landlord's prior written approval. Landlord reserves the right to adopt and enforce reasonable rules and regulations governing the use of the Storage Space from time to time. Upon expiration or earlier termination of this Lease or Tenant's rights under this Section, Tenant shall completely vacate and surrender the Storage Space to Landlord in accordance with the terms of this Lease. Without limitation, Tenant shall leave the Storage Space in the condition in which it was delivered to Tenant, reasonable wear and tear excepted, broom-clean and empty of all personalty and other items placed therein by or on behalf of Tenant.
LESSOR'S ACCESS; SHOWING PREMISES; REPAIRS Lessor and Lessor's agents shall have the right to enter the Premises at any time, in the case of an emergency, and otherwise at reasonable times for the purpose of showing the same to prospective purchasers, lenders, or lessees, and making such alterations, repairs, improvements or additions to the Premises or to the Building, as Lessor may reasonably deem necessary. Lessor may at any time place on or about the Premises or Building any ordinary "For Sale" signs and Lessor may at any time during the last one hundred eighty (180) days of the term hereof place on or about the Premises any ordinary "For Lease" signs. All such activities of Lessor shall be without abatement of rent or liability to Lessee.
Construction In First Offer Space Tenant shall take the First Offer Space in its “as is” condition, subject to any improvement allowance granted as a component of the Fair Rental Value, and the construction of improvements in the First Offer Space shall comply with the terms of Article 8 of this Lease.
Subleased Premises Sublandlord does hereby sublease to Subtenant, and Subtenant subleases and rents from Sublandlord, the Premises (the “Subleased Premises”).
Tenant’s Entry Into the Premises Prior to Substantial Completion Subject to the terms hereof and provided that Tenant and its agents do not interfere with, or delay, Contractor’s work in the Building and the Premises, at Landlord’s reasonable discretion, Contractor shall allow Tenant access to the Premises prior to the Substantial Completion of the Premises for the purpose of Tenant installing any necessary furniture, equipment or fixtures (including Tenant’s data and telephone equipment) in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 6.01, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry, and Landlord will reasonably cooperate with Tenant to coordinate Landlord’s Contractor’s work of constructing the Tenant Improvements with such access by Tenant for the installation of Tenant’s furniture, equipment and fixtures. In connection with any such entry, Tenant acknowledges and agrees that Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees shall fully cooperate, work in harmony and not, in any manner, interfere with Landlord or Landlord’s Contractor, agents or representatives in performing work in the Building and the Premises, or interfere with the general operation of the Building and/or the Project; and such entry shall be subject to the site management rules of Landlord and Landlord’s Contractor. If at any time any such person representing Tenant shall not be cooperative or shall otherwise cause or threaten to cause any such disharmony or interference, including, without limitation, labor disharmony, and Tenant fails to immediately institute and maintain corrective actions as directed by Landlord, then Landlord may revoke Tenant’s entry rights upon twenty-four (24) hours’ prior written notice to Tenant. Tenant acknowledges and agrees that any such entry into and occupancy of the Premises or any portion thereof by Tenant or any person or entity working for or on behalf of Tenant shall be deemed to be subject to all of the terms, covenants, conditions and provisions of the Lease, excluding only the covenant to pay Rent (until the occurrence of the Lease Commencement Date). Tenant further acknowledges and agrees that Landlord shall not be liable for any injury, loss or damage which may occur to any of Tenant’s work made in or about the Premises in connection with such entry or to any property placed therein prior to the Lease Commencement Date, the same being at Tenant’s sole risk and liability. Tenant shall be liable to Landlord for any damage to any portion of the Premises, including the Tenant Improvement work, caused by Tenant or any of Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees. If the performance of Tenant’s work in connection with such entry causes extra costs to be incurred by Landlord or requires the use of any Building services, Tenant shall promptly reimburse Landlord for such extra costs and/or shall pay Landlord for such Building services at Landlord’s standard rates then in effect. In addition, Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Premises and against injury to any persons caused by Tenant’s actions pursuant to this Section 6.01.
Sublease Premises On and subject to the terms and conditions below, Sublandlord hereby leases to Subtenant, and Subtenant hereby leases from Sublandlord, the Sublease Premises.
Expansion Space As used in this paragraph, the term “Expansion Space” means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.
Delivery of Premises If the Landlord shall be unable to give possession of the Premises, exclusively the Suite 200 Premises and the Suite 246 Premises, on the Fourth Expansion Premises Commencement Date by reason of (i) the Landlord work is not substantially complete, (ii) the holding over or retention of possession of any tenant, tenants or occupants, or (iii) for any other reason, then Landlord shall not be subject to any liability for the failure to give possession on said date. Under such circumstances the Base Rent to be paid herein shall not commence until the Premises (exclusively the Suite 200 Premises and the Suite 246 Premises) are made available to Tenant by Landlord, and no such failure to give possession on the Fourth Expansion Premises Commencement Date shall affect the validity of this Sixth Amendment to Office Building Lease or the obligations of the Tenant hereunder. The Base Rents due hereunder will be adjusted at the time that any or all of the Fourth Expansion Premises are delivered to Tenant substantially complete to reflect the same underlying effective rent of the rent structure specific to each suite with the lease expiration dates to remain unchanged. Notwithstanding the foregoing, if the Fourth Expansion Premises Commencement Date for the Suite 200 Premises together with the Suite 246 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the Sixth Amendment to Office Building Lease without any liability to the Landlord. Separately, if the Fourth Expansion Premises Commencement Date-Suite 240 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date-Suite 240 Premises, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease for the Suite 240 Premises not delivered in said time frame without any liability to the Landlord. If Landlord’s failure to complete Tenant’s improvements within ninety (90) days after the Fourth Expansion Premises Commencement Date and/or Fourth Expansion Premises Commencement Date-Suite 240 Premises is result of Tenant Delay, Tenant shall not have the option to terminate the Sixth Amendment to Office Building Lease or the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease.
Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.
