Supply of Product 4.1 DAEWOONG shall manufacture and supply Product to AEON in a primary packaged and labeled form. Product packaging shall display the logo of DAEWOONG (to the extent required by applicable law) and AEON and the outer label shall be marked using English language in accordance with applicable laws and Product’s Regulatory Approvals.
4.2 AEON’s estimate sales forecast of the Product during the Term of Agreement in the Territory in the Field is set forth in Annex D. Within ninety (90) days after the Effective Date, AEON shall provide DAEWOONG with a non-binding twelve (12) month rolling forecast of its requirements of Product, which the Parties agree is not a commitment to buy any stated quantity. Thereafter, on at least a quarterly basis, AEON shall provide DAEWOONG with an updated twelve (12) month rolling forecast, together with a binding six (6) month forecast to the extent AEON has requested Safety Stock as described in Article 4.10 below. Each such forecast shah be referred to herein as a “Forecast.”
4.3 AEON may from time to time submit Purchase Orders to DAEWOONG for Product in accordance with the forecasting requirements in Article 4.2. Orders will be shipped on CIF Los Angeles port.
4.4 Once a Purchase Order for Product and Product Samples has been received by DAEWOONG, it shall be considered as irrevocable.
4.5 AEON agrees herein to place an Order for Product not later than [***] from receipt of Regulatory Approval.
4.6 Individual Purchase Orders of Product shall be placed at least [***] in advance of the required delivery date.
4.7 For the purpose of Commercialization, AEON will store and maintain the full quantity of Product in a clean, secured area in accordance with the reasonable directions and specifications provided by DAEWOONG in writing in connection thereof in the Territory. AEON will advise DAEWOONG on the applicable requirements specifically deriving from the laws and regulations in the Territory.
4.8 AEON agrees that DAEWOONG and its collaborators and agents, in DAEWOONG’s sole discretion, which collaborators and Agents will be subject to appropriate obligations of confidentiality, will have the right upon reasonable prior notice, to observe and to inspect and to audit AEON’s facility to ascertain compliance by AEON with the terms of this Agreement, including without limitation (a) the holding facilities for Product, and (b) AEON’s compliance with applicable law, including cGMP (if applicable). Following any such audit, DAEWOONG will discuss its observations and conclusions with AEON and corrective actions, if any, will be agreed upon by the Parties, and executed by AEON using Commercially Reasonable Efforts.
4.9 In addition to any other rights and remedies available to AEON, AEON shall have the right to recover lost profits in the event that DAEWOONG fails to deliver at least [***] in any [***] (a “Supply Default Event”). For purposes of this provision, lost profits would be equal to [***] of AEON operating profit (sales less direct expenses and the puce paid by AEON for such Products) on Products that have not been shipped against firm Purchase Orders during the period leading up to the Supply Default Event and bona fide Purchase Orders submitted by AEON that are consistent with the Forecast during the Supply Default Period (as defined below). Such payment shall be made with respect to all Product not shipped in the period giving rise to the Supply Default and for the period until DAEWOONG is again timely shipping Product to meet AEON’s needs (the “Supply Default Period”). The first such payment shall be made within [***] of the Supply Default Event, and every [***] thereafter. AEON agrees to permit full disclosure to DAEWOONG of AEON’s accounting records, solely related to the calculation of lost profits, for the [***] ending on the first day of the month in which the Supply Event Default occurred. In the event that DAEWOONG is unable to supply both AEON’s requirements of Product and its own and third parties’ requirements for Product, DAEWOONG shall allocate Product that DAEWOONG has in inventory and that DAEWOONG is able to Product, so that AEON receives its requirements of Product in priority to DAEWOONG and third parties.
4.10 At the request of AEON, DAEWOONG shall at its own cost and expense during the Term, maintain an amount of inventory of Product equal to AEON’s requirements for Product for [***] based on AEON’s most recent forecast (“Safety Stock”). The Safety Stock shall be (i) maintained for the sole benefit of AEON and its Affiliates, (ii) shall be stored at a secure facility in compliance with GMP, and (iii) shall not be used for the benefit of any other customer of DAEWOONG. DAEWOONG shall rotate the Safety Stock on a “First Expiry-First Out” basis for routine fulfillment of firm orders, subject to Article 7.
Xxxxx Period After payment of the first Dues, the Subscriber is entitled to a grace period of 30 days for the payment of any Dues due. During this grace period, the Agreement will remain in force. However, the Subscriber will be liable for payment of Dues accruing during the period the Agreement continues in force.
Contract Year A twelve (12) month period during the term of the Agreement commencing on the Effective Date and each anniversary thereof.
Discontinued Products If a product or model is discontinued by the manufacturer, Contractor may substitute a new product or model if the replacement product meets or exceeds the specifications and performance of the discontinued model and if the discount is the same or greater than the discontinued model.
Commercial Milestones (a) Within [*****] calendar days after the end of the first Calendar Year in which aggregate annual Net Sales for that Calendar Year for the Licensed Product in the Territory reach any threshold indicated in the Commercial Milestone Events listed below, EverInsight shall notify VistaGen of the achievement of such Commercial Milestone Event and VistaGen shall invoice EverInsight for the corresponding non-refundable, non-creditable Milestone Payment set forth below and EverInsight shall remit payment to VistaGen within [*****] Business Days after the receipt of the invoice, as described in Section 8.6 (Currency; Exchange Rate; Payments). Annual Net Sales Milestones for Licensed Product Milestone Payments (in Dollars) (each a “Commercial Milestone Event”):
(1). [*****]
(2). [*****]
(3). [*****]
(4). [*****]
(5). [*****]
(b) For the purposes of determining whether a Net Sales Milestone Event has been achieved, Net Sales of Licensed Product(s) in the Territory shall be aggregated. For clarity, the annual Net Sales Milestone Payments set forth in this Section 8.3 (Commercial Milestones) shall be payable only once, upon the first achievement of the applicable Commercial Milestone Event, regardless of how many times such Commercial Milestone Event is achieved.
(c) If a Commercial Milestone Event in Section 8.3 (Commercial Milestones) is achieved and payment with respect to any previous Commercial Milestone Event in Section 8.3 has not been made, then such previous Commercial Milestone Event shall be deemed achieved and EverInsight shall notify VistaGen within fifteen (15) calendar days of such achievement. VistaGen shall then invoice EverInsight for such unpaid previous Commercial Milestone Event(s) and EverInsight shall pay VistaGen such unpaid previous milestone payment(s) within thirty (30) Business Days of receipt of such invoice.
(d) In the event that, VistaGen believes any Commercial Milestone Event under Section 8.3(a) has occurred but EverInsight has not given VistaGen the notice of the achievement of such Commercial Milestone Event, it shall so notify EverInsight in writing and shall provide to EverInsight data, documentation or other information that supports its belief. Any dispute under this Section 8.3(d) (Commercial Milestones - subsection (d)) that relates to whether or not a Commercial Milestone Event has occurred shall be referred to the JSC to be resolved in accordance with ARTICLE 3 (Governance) and shall be subject to resolution in accordance with Section 14.10 (Dispute Resolution). The Milestone Payments made for each Commercial Milestone Event shall be non-creditable and non-refundable.
Supply of Products
3.1 The Supplier warrants that the Products shall:
(a) correspond with their description and any applicable Product Specification;
(b) conform in all respects with the Order and any relevant sample;
(c) be of satisfactory quality and fit for any purpose held out by the Supplier or made known to the Supplier by Ornua, expressly or by implication, and in this respect Ornua relies on the Supplier's skill and judgement;
(d) be manufactured by properly trained and qualified personnel using all reasonable skill, care and diligence and in a good and workmanlike manner;
(e) where they are manufactured products, be free from defects in design, materials and workmanship and remain so for the period set out in the Product Specification or, if none is specified, for at least 12 months after delivery;
(f) comply with all applicable statutory and regulatory requirements relating to the manufacture, labelling, packaging, storage, handling and delivery of the Products;
(g) comply with all relevant standards including any UK Standards, European Standards or International Standards applicable in the UK and the country or State where the Products are to be used; and
(h) in the case of Products containing food stuffs, when delivered to Ornua, comply with all applicable food and hygiene legislation and regulations and best industry practice.
3.2 The Supplier shall ensure that at all times it has and maintains all licences, permissions, authorisations, consents and permits needed to carry out its obligations under the Contract in respect of the supply of Products. Breach of this Condition shall be deemed a material breach of the Contract.
3.3 Ornua may inspect and test the Products at any time before delivery. The Supplier shall remain fully responsible for the Products despite any such inspection or testing and any such inspection or testing shall not reduce or otherwise affect the Supplier's obligations under the Contract.
3.4 If following such inspection or testing Ornua considers that the Products do not comply or are unlikely to comply with the Supplier's undertakings at clause 3.1, Ornua shall inform the Supplier and the Supplier shall immediately take such remedial action as is necessary to ensure compliance.
3.5 Ornua may conduct further inspections and tests after the Supplier has carried out its remedial actions.
Development Milestone Payments (i) In addition to the Closing Date Merger Consideration (less the Remaining Option Consideration and Rights Proceeds Amount, if any) and any Net TNF Sales Payments (as defined below), upon the attainment of the development ** Portions of the Exhibit have been omitted and have been filed separately pursuant to an application for confidential treatment filed with the Securities and Exchange Commission pursuant to Rule 24b-2 under the Securities Exchange Act of 1934, as amended. milestones set forth below (each, a “Development Milestone”), Parent shall, or shall cause the Surviving Corporation to, [**] after the occurrence of each Development Milestone, deliver to the Paying Agent (for further payment to the holders of Stock Certificates and Stock Agreements outstanding immediately prior to the Effective Time), via wire transfer of immediately available funds, the respective amounts set forth below minus, in each case, the applicable Contingent Consideration Distribution Fee associated therewith and any amount designated by the Stockholders’ Representatives to be placed in the Administrative Expense Account (each, a “Development Milestone Payment” and collectively, the “Development Milestone Payments”):
(A) Upon FDA approval of Reslizumab for the treatment of eosinophilic esophagitis, a cash payment of [**];
(B) Upon marketing authorization of Reslizumab for the treatment of eosinophilic esophagitis being granted by the European Commission in accordance with Regulation (EC) No. 726/2004, a cash payment of [**];
(C) If Res 5-0010 Asthma Study Completion has not occurred on or prior to the Closing Date, then upon the occurrence of the Res 5-0010 Asthma Study Completion, a cash payment of $50,000,000 (fifty million dollars) (the “Res 5-0010 Asthma Payment”);
(D) Upon FDA approval of Reslizumab for any asthma indication, a cash payment of [**];
(E) Upon marketing authorization of Reslizumab for the treatment of any asthma indication being granted by the European Commission in accordance with Regulation (EC) No. 726/2004, a cash payment of [**]; and
(F) Upon FDA approval of an Oral Anti-TNF Product, a cash payment of [**].
EVENTS OUTSIDE OUR CONTROL 10.1 We will not be liable or responsible for any failure to perform, or delay in performance of, any of our obligations under this XXXX that is caused by any act or event beyond our reasonable control, including failure of public or private telecommunications networks (Event Outside Our Control).
10.2 If an Event Outside Our Control takes place that affects the performance of our obligations under this XXXX:
(a) our obligations under this XXXX will be suspended and the time for performance of our obligations will be extended for the duration of the Event Outside Our Control; and
(b) we will use our reasonable endeavours to find a solution by which our obligations under this XXXX may be performed despite the Event Outside Our Control.
Development Milestones In addition to its obligations under Paragraph 7.1, LICENSEE specifically commits to achieving (either itself or through the acts of a SUBLICENSEE) the following development milestones in its diligence activities under this AGREEMENT: (a) (b).
Commercialization Reports Throughout the term of this Agreement and during the Sell-Off Period, and within thirty (30) days of December 31st of each year, Company will deliver to University written reports of Company’s and Sublicensees’ efforts and plans to develop and commercialize the innovations covered by the Licensed Rights and to make and sell Licensed Products. Company will have no obligation to prepare commercialization reports in years where (a) Company delivers to University a written Sales Report with active sales, and (b) Company has fulfilled all Performance Milestones. In relation to each of the Performance Milestones each commercialization report will include sufficient information to demonstrate achievement of those Performance Milestones and will set out timeframes and plans for achieving those Performance Milestones which have not yet been met.
