Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants:
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions (a) The prospective lower tier participant certifies, by submission of this proposal, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any federal department or agency.
CERTIFICATION REGARDING DEBARMENT, SUSPENSION, INELIGIBILITY AND VOLUNTARY EXCLUSION This provision is applicable to all Federal-aid construction contracts, design-build contracts, subcontracts, lower-tier subcontracts, purchase orders, lease agreements, consultant contracts or any other covered transaction requiring FHWA approval or that is estimated to cost $25,000 or more – as defined in 2 CFR Parts 180 and 1200.
Certification Regarding Debarment, Suspension, and Ineligibility (i) Paragraph 16.2, Governing Law;
Termination or Suspension for Convenience The District reserves the right, in its sole discretion, to terminate or suspend all or part of the Contract for convenience following three (3) days written notice to the Contractor. In the event of termination or suspension for convenience, Contractor shall have no claims against the District, except:
Notification of Delay The Design Professional shall immediately notify the City in writing if Design Professional experiences or anticipates experiencing a delay in performing the Professional Services within the time frames set forth in the Task Order. The written notice shall include an explanation of the cause for, and a reasonable estimate of the length of, the delay. If in the opinion of the City, the delay affects a material part of the Task, the City may exercise its rights under Sections 2.5-2.7 of this Agreement.
Surrender of Confidential Information upon Termination Upon termination of this Contract or a Statement of Work, in whole or in part, each party must, within 5 calendar days from the date of termination, return to the other party any and all Confidential Information received from the other party, or created or received by a party on behalf of the other party, which are in such party’s possession, custody, or control; provided, however, that Contractor must return State Data to the State following the timeframe and procedure described further in this Contract. Should Contractor or the State determine that the return of any Confidential Information is not feasible, such party must destroy the Confidential Information and must certify the same in writing within 5 calendar days from the date of termination to the other party. However, the State’s legal ability to destroy Contractor data may be restricted by its retention and disposal schedule, in which case Contractor’s Confidential Information will be destroyed after the retention period expires.
Termination or Suspension for Convenience of City City may suspend or terminate this Agreement, or any portion of the Required Services, at any time and for any reason, with or without cause, by giving specific written notice to Consultant of such termination or suspension at least fifteen (15) days prior to the effective date thereof. Upon receipt of such notice, Consultant shall immediately cease all work under the Agreement and promptly deliver all “Work Product” (defined in Section 7 below) to City. Such Work Product shall be City's sole and exclusive property as provided in Section 7 hereof. Consultant shall be entitled to receive just and equitable compensation for this Work Product in an amount equal to the amount due and payable under this Agreement for work satisfactorily performed as of the date of the termination/suspension notice plus any additional remaining Required Services requested or approved by City in advance that would maximize City’s value under the Agreement.
Termination by ICANN (a) ICANN may, upon notice to Registry Operator, terminate this Agreement if: (i) Registry Operator fails to cure (A) any fundamental and material breach of Registry Operator’s representations and warranties set forth in Article 1 or covenants set forth in Article 2, or (B) any breach of Registry Operator’s payment obligations set forth in Article 6 of this Agreement, each within thirty (30) calendar days after ICANN gives Registry Operator notice of such breach, which notice will include with specificity the details of the alleged breach, (ii) an arbitrator or court of competent jurisdiction has finally determined that Registry Operator is in fundamental and material breach of such covenant(s) or in breach of its payment obligations, and (iii) Registry Operator fails to comply with such determination and cure such breach within ten (10) calendar days or such other time period as may be determined by the arbitrator or court of competent jurisdiction.
Exchange of Information Upon Request 1. The competent authority of the requested Party shall provide upon request information for the purposes referred to in Article 1. Such information shall be exchanged without regard to whether the conduct being investigated would constitute a crime under the laws of the requested Party if such conduct occurred in the requested Party.
